Unilateral extensions Sample Clauses

Unilateral extensions. ‌ (a) Subject to Clause 12.4(b), the State may, by notice to the Operator, unilaterally extend any Date for Completion where the State considers that any act or omission of the State or a State Associate will, or is likely to, delay the Date for Completion.‌ (b) The State is not required to exercise the State’s discretion in accordance with Clause 12.4(a) for the benefit of the Operator or at all.‌ (c) The exercise or failure to exercise the State’s discretion in accordance with this Clause 12.4 is not capable of being the subject of a Dispute in accordance with Clause 34 or otherwise subject to review.
Sample 1Sample 2
AutoNDA by SimpleDocs
Unilateral extensions. Whether or not the Managing Contractor has made, or is entitled to make, a claim for an EOT to any relevant date for completion, or is entitled to be, or has been, granted an EOT to any relevant date for completion, under subclause 23.3, the Principal's Representative may, in its absolute discretion, for any reason and at any time, from time to time by written notice to the Managing Contractor and the Principal, unilaterally extend any date for completion by any period specified in a notice to the Managing Contractor and the Principal. The Principal's Representative is not required to exercise its discretion under this subclause 23.5 for the benefit of the Managing Contractor. Without limiting subclause 16.1, the discretion to grant an EOT under this subclause 23.5 may only be exercised by the Principal's Representative and: (a) the Principal's Representative may or may not (as the case may be) exercise this discretion in accordance with the instructions of the Principal; and (b) the exercise or failure to exercise that discretion is not a "direction" which can be the subject of a dispute pursuant to clause 30 or in any other way opened up, reviewed or exercised by any other person in any forum (including by any expert, arbitration or litigation proceedings).
Sample 1
Unilateral extensions. If Lessee is not then in Default under the Lease, Lessee shall have the option to extend the Term of the Lease for ( ) additional terms of ( ) years each (“Unilateral Renewal Terms”), on the same terms and conditions provided for in this Lease. Each such extension shall automatically be exercised unless Lessee delivers written notice of termination to Lessor no later than ninety (90) days before the date on which this Lease would otherwise extend. [Note: proposals are to specify initial term, number of unilateral extensions, and lengths of unilateral extensions, provided that the initial term and extensions in the aggregate are not to exceed fifty-five (55) years.]
Sample 1
Unilateral extensions. (a) Whether or not the Contractor has made, or is entitled to make, a Claim for an extension of time under this clause 10, the Principal's Representative may, in its absolute discretion at any time and from time to time by written notice to the Contractor, unilaterally extend the Date for Practical Completion or LD Milestone Date. (b) The power to extend any Date for Practical Completion or LD Milestone Date under this clause 10.11: (i) may only be exercised by the Principal's Representative and the Principal's Representative is not required to exercise its discretion under this clause 10.11 for the benefit of the Contractor; and (ii) is not a Direction which can be the subject of a dispute pursuant to clause 15 or in any other way opened up or reviewed by any other person (including any expert, arbitrator or court).
Sample 1
Unilateral extensions. Whether or not the Operator has made, or is entitled to make, a claim for an extension of time under this Clause 14, the State may, in its absolute discretion at any time by written notice to the Operator, unilaterally extend the Date for Completion.
Sample 1
Unilateral extensions. (a) The Commonwealth may, at any time, in its absolute and unfettered discretion and whether or not for any reason stated in this Agreement, grant an extension of any Condition Precedent Date, the CP Target Date, the CP Sunset Date, the COD (Target), the COD (Sunset) or any Milestone Date (Scheduled), or any other date by which any obligation is required to be performed under this Agreement. (b) An extension granted by the Commonwealth under this clause 8.3 must be granted in writing to be effective
Sample 1

Related to Unilateral extensions

  • Renewal, Extension The renewal or extension of any Letter of Credit shall, for purposes hereof, be treated in all respects the same as the issuance of a new Letter of Credit hereunder.

  • Modification, Extension The issuance of any supplement, modification, amendment, renewal, or extension to any Letter of Credit shall, for purposes hereof, be treated in all respects the same as the issuance of a new Letter of Credit hereunder.

  • Territorial Extension At the time of signature of this Agreement, or at any time thereafter, the provisions of this Agreement may be extended to such territories for whose international relations the Government of the United Kingdom are responsible as may be agreed between the Contracting Parties in an Exchange of Notes.

  • Time Extensions 2.03.1 If Contractor requests an extension of time to complete its performance, then the Director, in consultation with the CPO, may, in his or her sole discretion, extend the time so long as the extension does not exceed 90 days. The extension must be in writing but does not require amendment of this Agreement. Contractor is not entitled to damages for delay(s) regardless of the cause of the delay(s).

  • Interim Extension Amendment a. Prior to or on the expiration date of this Contract, the Parties agree that this Contract can be extended as provided under this Section. b. The System Agency will provide written notice of interim extension amendment to the Grantee under one of the following circumstances: 1. Continue provision of services in response to a disaster declared by the governor; or 2. To ensure that services to clients continue without interruption. c. The System Agency will provide written notice of the interim extension amendment that specifies the reason and length of time for the extension. d. Grantee will provide and invoice for services in the same manner as stated in the Contract. e. An interim extension under Section (b)(1) above will extend the term of the contract not longer than 30 days after governor's disaster declaration is declared unless the Parties agree to a shorter period of time. f. An interim extension under Section (b)(2) above will be a one-time extension for time determined by the System Agency.

  • Modification, Extension and Renewal of Options The Board or a duly appointed committee thereof, may modify, extend or renew this Option or accept the surrender thereof (to the extent not theretofore exercised) and authorize the granting of a new option in substitution therefore (to the extent not theretofore exercised), subject at all times to the Code and applicable securities laws. Notwithstanding the foregoing provisions of this Section 12, no modification shall, without the consent of the Recipient, alter to the Recipient’s detriment or impair any rights of Recipient hereunder.

  • Term Extension It is understood and agreed that the State may extend the Term an additional period of time, not to exceed one hundred-eighty (180) days beyond the expiration date of this Grant Contract, under the same terms and conditions. In no event, however, shall the maximum Term, including all extensions or renewals, exceed a total of sixty (60) months.

  • Amendment; Extension; Waiver (a) This Agreement may be amended by the parties hereto at any time prior to the Offer Closing Time. At any time prior to the Offer Closing Time, the parties hereto may (i) extend the time for the performance of any of the obligations or other acts of the other parties hereto, (ii) waive any inaccuracies in the representations and warranties contained in this Agreement or in any document delivered pursuant to this Agreement or (iii) waive compliance with any of the agreements or conditions contained in this Agreement (subject to Section 2.01). This Agreement may not be amended or supplemented after the Offer Closing Time. (b) This Agreement may not be amended except by an instrument in writing signed on behalf of each of the parties hereto. Any agreement on the part of a party hereto to any extension or waiver with respect to this Agreement shall be valid only if set forth in an instrument in writing signed on behalf of such party. The failure of any party hereto to assert any of its rights under this Agreement or otherwise shall not constitute a waiver of such rights.

  • Time Extension CONTRACTOR shall provide a time extension request on completion of Task Order for delays caused by others (Permitting Agencies, COUNTY or Contract Cities, or unforeseen conditions such as inclement weather, etc.) and at no fault by CONTRACTOR, subject to approval by COUNTY. COUNTY will review the request and determine in its sole discretion whether the situation warrant a time extension at no-cost or with costs. If CONTRACTOR completes the Task Order beyond the stipulated completion date without COUNTY’s specific written approval for time extension, CONTRACTOR will be subject to liquidated damages and may be construed as non-responsive, which may affect CONTRACTOR for considerations for future Task Orders or projects.

  • Contract Extension The City may, in its sole discretion, unilaterally exercise an option to extend the Contract as described in the Contract Documents. In addition, the City may, in its sole discretion, unilaterally extend the Contract on a month-to-month basis following contract expiration if authorized under Charter section 99 and the Contract Documents. Contractor shall not increase its pricing in excess of the percentage increase described in the Contract.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!