Union Jurisdictional Claims Sample Clauses

Union Jurisdictional Claims. 26 Union jurisdictional claims arising under the provisions of Section 27 1.1 of this Agreement, shall be handled pursuant to the provisions 28 of Section 7.4 and Sections 7.6 through 7.14, inclusive, except that 29 the following requirements shall apply:
Sample 1Sample 2
AutoNDA by SimpleDocs
Union Jurisdictional Claims. 11 Union jurisdictional claims arising under the provisions of Section 1.3 of 12 this Agreement, except those identified in Section 1.3(f), shall be handled 13 pursuant to the provisions of Section 19.4 and Sections 19.6 through 19.14, 14 inclusive, except that the following requirements shall apply: (a) The written statement of grievance shall identify the job 16 involved, state the Union's contention or contentions in detail, and shall 17 contain a detailed statement of the reasons for the position taken by the 18 Union. (b) If the Company and the Union are unable to agree upon the 20 contents and scope of the record to be presented to the arbiter, either 21 party may present to the arbiter whatever evidence, testimony and 22 written argument it deems relevant to the question to be submitted to 23 the arbiter. A written summary of such evidence, testimony and written 24 argument will be submitted to the other side at least ten (10) days in 25 advance of the hearing. (c) If the parties are unable to agree upon the question that it is to 27 be submitted to the arbiter for decision, the question to be submitted to, 28 and answered by, the arbiter shall be: 29 "On the basis of the evidence, information, and arguments 30 submitted by the parties in reference to the Union's contention in 31 this case, is the Company violating Article 1, Section 1.1, 32 paragraphs 1.1(a), 1.1(b), 1.1(c), or 1.1(d)?" (d) The arbiter shall answer the question submitted to him/her 34 under Section 19.15(c) or the agreed statement of the issue presented 35 by both parties. The arbiter's answer shall either be in the affirmative 36 or the negative. The arbiter shall confine the proceedings before 37 him/her to the questions presented to him/her in accordance with this 38 Section 19.15 and he/she shall not have authority to specify any change 39 in a job or any change in the work assignments under a job or the 40 creation of a new job or any other remedy or type of award. (e) If the arbiter's answer sustains the Union's contention, the 2 Company shall, within thirty (30) days (or any longer period to which 3 the parties may mutually agree) after receiving the arbiter's decision, 4 take whatever corrective action is necessary to eliminate the basis for 5 the Union's jurisdictional claim in the particular case. (f) Any resolution of any claim or controversy under Section 1.3, 7 whether by mutual agreement or by arbitration, that requires corrective 8 action on the part of the Company s...
Sample 1
Union Jurisdictional Claims. 24 Union jurisdictional claims arising under the provisions of Section 1.1 of 25 this Agreement, shall be handled pursuant to the provisions of Section 7.4 26 and Sections 7.6 through 7.14, inclusive, except that the following 27 requirements shall apply: 28 A. The written statement of grievance shall identify the job involved, state 29 the Union’s contention or contentions in detail, and shall contain a 30 detailed statement of the reasons for the position taken by the Union. 31 B. If the Company and the Union are unable to agree upon the contents 32 and scope of the record to be presented to the arbiter, either party may 33 present to the arbiter whatever evidence, testimony and written 34 argument it deems relevant to the question to be submitted to the 35 arbiter. A written summary of such evidence, testimony and written 36 argument will be submitted to the other side at least ten (10) days in 37 advance of the hearing. 38 C. If the parties are unable to agree upon the question that is to be 39 submitted to the arbiter for decision, the question to be submitted to, 40 and answered by, the arbiter shall be: "On the basis of the evidence, 1 information, and arguments submitted by the parties in reference to 2 the Union's contention in this case, is the Company violating Article 1, 4 D. The arbiter shall answer the question submitted to him under Section 5 7.15(c) or the agreed statement of the issue presented by both parties.
Sample 1
Union Jurisdictional Claims. 2 Union jurisdictional claims arising under the provisions of Section 1.3 of 3 this Agreement, except those identified in Section 1.3(f), shall be handled 4 pursuant to the provisions of Section 19.4 and Sections 19.6 through 19.14, 5 inclusive, except that the following requirements shall apply: (a) The written statement of grievance shall identify the job 7 involved, state the Union's contention or contentions in detail, and shall 8 contain a detailed statement of the reasons for the position taken by the
Sample 1

Related to Union Jurisdictional Claims

  • Jurisdictional Disputes 17.01 A xxxx-up meeting will be held with each Contractor not later than the commencement of the Contractor's work on all projects and no assignments shall be made before this xxxx- up. Xxxx-up assignments shall also apply to all sub-contractors. If a jurisdictional dispute arises once the work has commenced, assignments will be made in accordance with procedures, rules and regulations of the National Joint Board Building Trades Department, A.F.L. & C.I.O. The work assignment shall not be completed until a meeting on site has been convened with all Parties involved and until a subsequent meeting (not later than twenty-four (24) hours) has taken place, at which the Contractor shall present the work assignment on paper to all Parties. 17.02 In the event such jurisdictional dispute cannot be settled on a Local basis by the Unions involved, such dispute shall be submitted to the International Unions involved for settlement without permitting it to interfere in any way with the progress of the work at any time. In the event the dispute is not settled by the International Unions involved, it shall then be submitted to the National Joint Board for resolution. It is understood and agreed, however, that if the dispute causes any delay in the progress of the work or gives rise to an apprehended delay, any of the Parties hereto may apply to the Labour Relations Board (Nova Scotia) Construction Panel for an Interim Order under Section 50 of the Trade Union Act, Chapter 311, R.S.N.S. 1967, amended.

  • Non-Jurisdictional Entities LIPA and NYPA do not waive their exemptions, pursuant to Section 201(f) of the FPA, from Commission jurisdiction with respect to the Commission’s exercise of the FPA’s general ratemaking authority.

  • Litigation; Jurisdiction; Other Matters; Waivers (a) EACH PARTY HERETO ACKNOWLEDGES THAT ANY DISPUTE OR CONTROVERSY BETWEEN OR AMONG THE BORROWER, THE AGENT OR ANY OF THE LENDERS WOULD BE BASED ON DIFFICULT AND COMPLEX ISSUES OF LAW AND FACT AND WOULD RESULT IN DELAY AND EXPENSE TO THE PARTIES. ACCORDINGLY, TO THE EXTENT PERMITTED BY APPLICABLE LAW, EACH OF THE LENDERS, THE AGENT AND THE BORROWER HEREBY WAIVES ITS RIGHT TO A TRIAL BY JURY IN ANY ACTION OR PROCEEDING OF ANY KIND OR NATURE IN ANY COURT OR TRIBUNAL IN WHICH AN ACTION MAY BE COMMENCED BY OR AGAINST ANY PARTY HERETO ARISING OUT OF THIS AGREEMENT, THE NOTES, OR ANY OTHER LOAN DOCUMENT OR BY REASON OF ANY OTHER SUIT, CAUSE OF ACTION OR DISPUTE WHATSOEVER BETWEEN OR AMONG THE BORROWER, THE AGENT OR ANY OF THE LENDERS OF ANY KIND OR NATURE. (b) THE BORROWER, THE AGENT AND EACH LENDER HEREBY AGREES THAT THE UNITED STATES DISTRICT COURT FOR THE NORTHERN DISTRICT OF GEORGIA, ATLANTA DIVISION OR, AT THE OPTION OF THE AGENT, ANY STATE COURT LOCATED IN ATLANTA, GEORGIA, SHALL HAVE JURISDICTION TO HEAR AND DETERMINE ANY CLAIMS OR DISPUTES BETWEEN OR AMONG THE BORROWER, THE AGENT OR ANY OF THE LENDERS, PERTAINING DIRECTLY OR INDIRECTLY TO THIS AGREEMENT, THE LOANS AND LETTERS OF CREDIT, THE NOTES OR ANY OTHER LOAN DOCUMENT OR TO ANY MATTER ARISING HEREFROM OR THEREFROM. THE BORROWER AND EACH OF THE LENDERS EXPRESSLY SUBMITS AND CONSENTS IN ADVANCE TO SUCH JURISDICTION IN ANY ACTION OR PROCEEDING COMMENCED IN SUCH COURTS. EACH PARTY FURTHER WAIVES ANY OBJECTION THAT IT MAY NOW OR HEREAFTER HAVE TO THE VENUE OF ANY SUCH ACTION OR PROCEEDING IN ANY SUCH COURT OR THAT SUCH ACTION OR PROCEEDING WAS BROUGHT IN AN INCONVENIENT FORUM AND EACH AGREES NOT TO PLEAD OR CLAIM THE SAME. THE CHOICE OF FORUM SET FORTH IN THIS SECTION SHALL NOT BE DEEMED TO PRECLUDE THE BRINGING OF ANY ACTION BY THE AGENT OR ANY LENDER OR THE ENFORCEMENT BY THE AGENT OR ANY LENDER OF ANY JUDGMENT OBTAINED IN SUCH FORUM IN ANY OTHER APPROPRIATE JURISDICTION. (c) THE PROVISIONS OF THIS SECTION HAVE BEEN CONSIDERED BY EACH PARTY WITH THE ADVICE OF COUNSEL AND WITH A FULL UNDERSTANDING OF THE LEGAL CONSEQUENCES THEREOF, AND SHALL SURVIVE THE PAYMENT OF THE LOANS AND ALL OTHER AMOUNTS PAYABLE HEREUNDER OR UNDER THE OTHER LOAN DOCUMENTS, THE TERMINATION OR EXPIRATION OF ALL LETTERS OF CREDIT AND THE TERMINATION OF THIS AGREEMENT.

  • Tax Status Non Jurisdictional Entities Tax Status.‌‌ Each Party shall cooperate with the other Parties to maintain the other Parties’ tax status. Nothing in this Agreement is intended to adversely affect the tax status of any Party including the status of NYISO, or the status of any Connecting Transmission Owner with respect to the issuance of bonds including, but not limited to, Local Furnishing Bonds. Notwithstanding any other provisions of this Agreement, LIPA, NYPA and Consolidated Edison Company of New York, Inc. shall not be required to comply with any provisions of this Agreement that would result in the loss of tax-exempt status of any of their Tax-Exempt Bonds or impair their ability to issue future tax-exempt obligations. For purposes of this provision, Tax-Exempt Bonds shall include the obligations of the Long Island Power Authority, NYPA and Consolidated Edison Company of New York, Inc., the interest on which is not included in gross income under the Internal Revenue Code. LIPA and NYPA do not waive their exemptions, pursuant to Section 201(f) of the FPA, from Commission jurisdiction with respect to the Commission’s exercise of the FPA’s general ratemaking authority.

  • WORK JURISDICTION Par. 1. It is agreed by the parties to this Agreement that all work specified in Article IV shall be performed exclusively by Elevator Constructor Mechanics, Elevator Constructor Helpers, Elevator Constructor Apprentices and Elevator Constructor Assistant Mechanics in the employ of the Company. (a) The handling and unloading of all equipment coming under the jurisdiction of the Elevator Constructor, from the time such equipment arrives at or near the building site, shall be handled and unloaded by the Elevator Constructors. Mechanical equipment such as a fork lift or truck mounted swing boom may be used by the Elevator Constructors. A xxxxxxx, xxxxx or material hoist can be used under the supervision of Elevator Constructors to handle and unload the heavy material described in Par. 5(a). Where unusual conditions are expected to exist prior to delivery of equipment at or near the building site in regard to handling and unloading of equipment in the primary or secondary jurisdiction of the local union, the Company shall contact the Local's Business Representative to make appropriate arrangements for the handling and unloading of such equipment. In areas outside the jurisdiction of the local union, the Company shall contact the Regional Director. (b) The erecting and assembling of all elevator equipment to wit: electric, hydraulic, steam, belt, dumbwaiters, residence elevators, parking garage elevators (such as Xxxxxx, Pigeon Hole, or similar types of elevators), shuttles, compressed air and handpower, automatic people movers, monorails, airport shuttles and like-named devices used in the transportation of people for short distances of travel (less than 5 miles), as well as vertical reciprocating conveyor systems. (c) It is understood and agreed that the preassembly of all escalators, moving stairways and link belt carriers that may be done in the factory shall include the following: 1. Truss or truss sections with tracks, drive units, machines, handrail drive sheaves, drive chains, skirts on the incline sections but not curved sections, step chains and steps installed and permanently aligned. 2. Balustrade brackets may be shipped attached but not aligned. 3. Setting of all controllers and all wiring and conduit from the controller. All other work on escalators, moving stairways and link belt carriers shall be performed in the field by Elevator Constructor Mechanics, Helpers, Apprentices and Assistant Mechanics either before or after the truss or truss sections are joined and/or hoisted and placed in permanent position. This includes any and all work not done in the factory. The erecting and assembly of all theater stage and curtain elevator equipment and guides and rigging thereto, organ consoles and orchestra elevators shall be performed by Elevator Constructor Mechanics, Helpers, Apprentices and Assistant Mechanics. (d) All wiring, conduit, and raceways from main line feeder terminals on the controller to other elevator apparatus and operating circuits. Controllers are not to be shipped from the factory with extended wiring attached thereto. (e) The erecting of all guide rails. (f) The installation of all grating under the control of the Company. The installation of all counterweight screens, overhead work, either wood or iron, and all material used for mounting of elevator apparatus in machine room, overhead or below. (g) The drilling of overhead beams for attaching machines, sheaves, kick angles, and all other elevator equipment. (h) The setting of all templates. (i) All foundations, either of wood or metal, that should take the place of masonry. (j) The assembly of all cabs complete. (k) The installation of all indicators. (1) The erecting of all electrical or mechanical automatic or semi-automatic gates complete.

  • Arbitrator's Jurisdiction The arbitrator shall take such evidence as in his judgment is appropriate for resolution of the dispute; however, he shall confine himself to the issues for arbitration and shall have no authority to determine any other issue not so submitted which is not directly essential to reaching a determination on the dispute at hand. The arbitrator shall have no power to recommend any right or relief for any period of time prior to the effective date of the Agreement under which the grievance was initiated. In those issues wherein the grievant’s relief sought involves back pay or lost wages covering a period of an Employee’s payroll separation due to suspension or discharge, the amount of the award shall be less any unemployment compensation or interim earnings, received by the aggrieved Employee. Second jobs or sources of income which the Employee received while under employment will not be considered interim income and will not be deducted when awarding lost wages or back pay. The decision of the arbitrator shall be submitted in writing to the parties within thirty (30) calendar days of the hearing’s conclusion unless the deadline is mutually extended by the parties. The decision and award of the arbitrator shall be final and binding on the Union, its members, the aggrieved Employee(s) and the CITY. With respect to grievances involving misapplication or misinterpretation of this Agreement, the grievance and arbitration procedure contained in this Article shall be the sole and exclusive remedy available to employees, and the parties hereto as this procedure is intended to supersede all conflicting provisions of the Ohio Revised Code regarding any and all matters subject to the grievance procedures of this Contract or otherwise made subject to this Agreement. With respect to grievances involving disciplinary suspensions, demotions or dismissals the election of remedies, as set forth above, shall be mutually exclusive. Choice of binding arbitration shall thereafter preclude appeal to Civil Service or to Court. Appeal to Civil Service shall preclude access to binding arbitration. With respect to cases of suspension, demotion and discharge, the arbitrator shall decide:

  • Governing Law; Venue; Jurisdiction This Agreement shall be construed and enforced in accordance with and governed by the laws of the State of New York, without reference to principles of conflicts or choice of law thereof. Each of the parties consents to the jurisdiction of the U.S. District Court in the Southern District of New York in connection with any dispute arising under this Agreement and hereby waives, to the maximum extent permitted by law, any objection, including any objection based on forum non conveniens. to the bringing of any such proceeding in such jurisdictions. Each party hereby agrees that if another party to this Agreement obtains a judgment against it in such a proceeding, the party which obtained such judgment may enforce same by summary judgment in the courts of any country having jurisdiction over the party against whom such judgment was obtained, and each party hereby waives any defenses available to it under local law and agrees to the enforcement of such a judgment. Each party to this Agreement irrevocably consents to the service of process in any such proceeding by the mailing of copies thereof by registered or certified mail, postage prepaid, to such party at it address set forth herein. Nothing herein shall affect the right of any party to serve process in any other manner permitted by law. Each party waives its right to a trial by jury.

  • Exclusive English jurisdiction Subject to Clause 30.3, the courts of England shall have exclusive jurisdiction to settle any disputes which may arise out of or in connection with this Agreement.

  • Applicable Laws and Consent to Jurisdiction The validity, construction, interpretation and enforceability of this Agreement shall be determined and governed by the laws of the State of Delaware without giving effect to the principles of conflicts of law. For the purpose of litigating any dispute that arises under this Agreement, the parties hereby consent to exclusive jurisdiction in Virginia and agree that such litigation shall be conducted in the courts of Fairfax County, Virginia or the federal courts of the United States for the Eastern District of Virginia.

  • Governing Law; Jurisdiction; Jury Trial All questions concerning the construction, validity, enforcement and interpretation of this Agreement shall be governed by the internal laws of the State of New York, without giving effect to any choice of law or conflict of law provision or rule (whether of the State of New York or any other jurisdictions) that would cause the application of the laws of any jurisdictions other than the State of New York. Each party hereby irrevocably submits to the exclusive jurisdiction of the state and federal courts sitting in The City of New York, Borough of Manhattan, for the adjudication of any dispute hereunder or in connection herewith or with any transaction contemplated hereby or discussed herein, and hereby irrevocably waives, and agrees not to assert in any suit, action or proceeding, any claim that it is not personally subject to the jurisdiction of any such court, that such suit, action or proceeding is brought in an inconvenient forum or that the venue of such suit, action or proceeding is improper. Each party hereby irrevocably waives personal service of process and consents to process being served in any such suit, action or proceeding by mailing a copy thereof to such party at the address for such notices to it under this Agreement and agrees that such service shall constitute good and sufficient service of process and notice thereof. Nothing contained herein shall be deemed to limit in any way any right to serve process in any manner permitted by law. EACH PARTY HEREBY IRREVOCABLY WAIVES ANY RIGHT IT MAY HAVE, AND AGREES NOT TO REQUEST, A JURY TRIAL FOR THE ADJUDICATION OF ANY DISPUTE HEREUNDER OR IN CONNECTION WITH OR ARISING OUT OF THIS AGREEMENT OR ANY TRANSACTION CONTEMPLATED HEREBY.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!