When Premises Deemed Ready Sample Clauses

When Premises Deemed Ready. The Premises shall be conclusively deemed ready for Tenant’s occupancy as soon as Landlord’s Work has been Substantially Completed, but in no event prior to January 1, 2016. Landlord shall notify Tenant of the anticipated date of Substantial Completion for the Premises at least ten (10) business days prior to the anticipated date of Substantial Completion. Landlord and Tenant shall thereupon set a mutually convenient time on or before such date for Tenant, the Architect, Landlord, and Lxxxxxxx’s contractor to inspect the Premises and Landlord’s Work therein. With respect to Landlord’s Work, not later than five (5) business days after such inspection, Landlord shall cause Landlord’s Architect to prepare and submit to Landlord and Tenant a list of Punch List Items and other items to be completed with respect to such space. Subject to Tenant Delay and Force Majeure, Landlord shall use diligent efforts to complete such Punch List Items as promptly as possible and in any event (subject to extension for Force Majeure and Tenant Delay) within sixty (60) days following such inspection (unless particular Punch List Items cannot be completed within the sixty (60) day period, in which case such sixty (60) day period shall be extended for such time as may be reasonably necessary to enable Landlord to complete such Punch List Items). Notwithstanding any other provisions of this Article 4, if the delay in the Substantial Completion of the Premises is due to a Tenant Delay, then the Commencement Date shall be the date that the Premises would have been Substantially Completed but for any Tenant Delay, but in no event earlier than January 1, 2016. If, pursuant to the foregoing, the Commencement Date occurs before the Premises is in fact Substantially Completed, Tenant shall not (except with Landlord’s consent) be entitled to take possession of such space until the Premises is in fact Substantially Completed. Any of Landlord’s Work in the Premises not fully completed on the Commencement Date shall thereafter be so completed with reasonable diligence by Landlord. Any dispute as to whether any portion of the Premises is Substantially Complete shall be determined by arbitration in accordance with the provisions of Section 27.5 hereof, except that, with respect to disputes under this Section 4.6, such arbitration shall be conducted under the Fast Track Procedures provisions (currently, Rules F-1 through F-13) of the Arbitration Rules of the Construction Industry of the American...
Sample 1Sample 2See All (7)
AutoNDA by SimpleDocs
When Premises Deemed Ready. The Premises shall be conclusively deemed ready for LESSEE'S occupancy as soon as the initial installations to be done by LESSOR referred to in Exhibit 3 ("Building Standard Work") annexed hereto and made a part hereof (hereinafter referred to as "BUILDING STANDARD WORK") in the Premises have been substantially completed by LESSOR insofar as is practicable in view of delays or defaults, if any, of LESSOR or his contractors, and the
Sample 1Sample 2
When Premises Deemed Ready. The premises shall be conclusively deemed ready for Tenant's occupancy as soon as the initial installations and painting to be done by Landlord (referred to the Exhibit 3, "Memorandum of Work and Installations to be Initially Performed and Furnished in the Premises", annexed hereto and made a part hereof) in the premises have been substantially completed by Landlord insofar as is practicable in view of delays or defaults, if any, of Tenant or its contractors, as hereinafter specified, and the elevator, plumbing, air conditioning and electric facilities are initially substantially available to Tenant, in accordance with the obligations assumed
Sample 1
When Premises Deemed Ready. The Demised Premises shall be conclusively deemed ready for Tenant’s occupancy after Landlord gives notice to Tenant, together with a certificate from Landlord’s Architect, that the installations to be done by Landlord in the Demised Premises (as hereinafter set forth in this Article) have been substantially completed by Landlord insofar as is practicable in view of delays or defaults, if any, of Tenant. Such work shall not be deemed incomplete if only minor or insubstantial details of construction or mechanical adjustments remain to be done, or if a delay is caused in whole or in part by Tenant through the delay of Tenant in submitting any plans and/or specifications, supplying information, approving plans, specifications or estimates, giving authorization or otherwise. Landlord’s Architect’s certificate of substantial completion, as hereinabove stated, given in good faith, or of any other facts pertinent to this Article, shall be deemed conclusive of the statements therein contained and binding upon Tenant. Following the completion of the work to be performed by Landlord pursuant to this Article, Landlord shall obtain from the Boston Inspectional Services Department a certificate authorizing the use and occupancy of the Demised Premises pursuant to the applicable provisions of the Massachusetts State Building Code. Landlord will save Tenant harmless, and will exonerate and indemnify Tenant from and against, any claims, liabilities, penalties, damages, losses, costs and expenses (including without limitation reasonable attorneys’ fees) resulting from Landlord’s failure to obtain such certificate.
Sample 1
When Premises Deemed Ready. The Demised Premises shall be -------------------------- conclusively deemed ready for Tenant's occupancy after Landlord gives notice to Tenant that the fit-up work to be done by Landlord in the Demised Premises pursuant to the Approved Plans have been substantially completed by Landlord insofar as is practicable in view of delays or defaults, if any, of Tenant. Such work shall not be deemed incomplete if only minor or insubstantial details of construction or mechanical adjustments remain to be done, or if a delay is caused in whole or in part by Tenant through the delay of Tenant in submitting any plans, and/or specifications. supplying information, approving plans, specifications or estimates, giving authorization or otherwise. Landlord's Architect's certificate of substantial completion as hereinabove stated, given in good faith, or of any other facts pertinent to this Section 4.2 shall be deemed conclusive of the statements therein contained and binding upon Tenant.
Sample 1
When Premises Deemed Ready. The Demised Premises shall be conclusively deemed ready for Tenant’s occupancy after Landlord gives notice to Tenant that the installations to be done by Landlord in the Demised Premises (as set forth in Section 4.1) have been substantially completed by Landlord. Such work shall not be deemed incomplete if only minor or insubstantial details of construction or mechanical adjustments remain to be done, or if a delay is caused in whole or in part by Tenant. Landlord’s Architect’s certificate of substantial completion, as hereinabove stated, given in good faith, or of any other facts pertinent to such work, shall be deemed conclusive of the statements therein contained and binding upon Tenant.
Sample 1
When Premises Deemed Ready. The Premises shall be conclusively deemed ready for LESSEE'S occupancy as soon as the initial installations to be done by LESSOR referred to in Exhibit 3 ("Building Standard Work") annexed hereto and made a part hereof (hereinafter referred to as "BUILDING STANDARD WORK,") in the Premises have been substantially completed by LESSOR insofar as is practicable in view of delays or defaults, if any, of LESSOR or his contractors, and the facilities specified in Exhibit 3 are substantially available to LESSEE, in accordance with the obligations assumed by LESSOR hereunder. The Premises shall be not deemed to be unready for LESSEE'S occupancy or incomplete if only minor insubstantial details of construction or mechanical adjustments remain to be done in the Premises or any part thereof (provided that LESSOR shall diligently continue to complete all work required of him hereunder), or if the delay in the availability of the Premises for occupancy is (i) due to special work, changes, alterations, or additions required or made by LESSEE in the layout or finish of the Premises or any part thereof other than as specified under Building Standard Work (provided that LESSOR shall diligently continue to complete all work required of him hereunder); or, (ii) caused in whole or in part by delay and/or default on the part of LESSEE or its contractors.
Sample 1
AutoNDA by SimpleDocs
When Premises Deemed Ready. The Demised Premises shall be conclusively deemed ready for Tenant's occupancy after Landlord gives notice to Tenant that the Premises Work (as such term is hereinafter defined) has been substantially completed by Landlord insofar as is practicable in view of delays or defaults, if any, of Tenant, and furnishes to Tenant a copy of a certificate authorizing the use and occupancy of the Demised Premises in accordance with the applicable provisions of the Massachusetts State Building Code. Such work shall in no event be deemed incomplete if only minor or insubstantial details of construction or mechanical adjustments remain to be done (so long as Tenant is able to conduct Tenant’s permitted business activities in the Demised Premises without unreasonable interference), or if a delay is caused in whole or in part by Tenant, including without limitation through the delay of Tenant in supplying any information requested by Landlord, Landlord’s Architect or any other representative of Landlord. Landlord’s Architect’s certificate of substantial completion, as hereinabove stated, given in good faith, or of any other facts pertinent to this Article, shall be deemed conclusive of the statements therein contained and binding upon Tenant.
Sample 1

Related to When Premises Deemed Ready

  • LESSOR'S ACCESS; SHOWING PREMISES; REPAIRS Lessor and Lessor's agents shall have the right to enter the Premises at any time, in the case of an emergency, and otherwise at reasonable times for the purpose of showing the same to prospective purchasers, lenders, or lessees, and making such alterations, repairs, improvements or additions to the Premises or to the Building, as Lessor may reasonably deem necessary. Lessor may at any time place on or about the Premises or Building any ordinary "For Sale" signs and Lessor may at any time during the last one hundred eighty (180) days of the term hereof place on or about the Premises any ordinary "For Lease" signs. All such activities of Lessor shall be without abatement of rent or liability to Lessee.

  • Lease of Premises for Lease Term Landlord hereby leases the Premises to Tenant, and Tenant hereby rents the Premises from Landlord, for the Term and subject to the conditions of this Lease.

  • Expansion Premises In addition to the Original Premises, commencing on the Expansion Premises Commencement Date (as defined below), Landlord leases to Tenant, and Tenant leases from Landlord, the Expansion Premises.

  • Delivery; Acceptance of Premises; Commencement Date Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date, with Landlord’s Work Substantially Completed (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 90 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Landlord or Tenant by written notice to the other, and if so terminated by either: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms “Landlord’s Work,” “Tenants’ Work,” and “Force Majeure Delays” shall have the meanings set forth for such terms in the Work Letter. If neither Landlord nor Tenant elects to void this Lease within 10 business days of the lapse of such 90 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect; provided, however, that if Landlord does not Deliver the Premises within 150 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Tenant by written notice to Landlord, in which case subsections (a) and (b) of this paragraph shall apply. If Tenant does not elected to void this Lease within 10 business days of the lapse of such 150 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect.

  • SURRENDER OF PREMISES; HOLDING OVER (a) Upon expiration or earlier termination of this Lease, Tenant shall surrender to Landlord the Premises and all of Tenant's improvements and alterations thereon in good operating order, condition, and state of repair, clean and free of debris (except for ordinary wear and tear occurring after Tenant's last necessary maintenance, and subject to the provisions of Paragraph 18, relating to the destruction or partial destruction of the Premises), except for alterations and improvements that Tenant is required to remove by written election of the Landlord pursuant to Paragraph 10(e), above. Tenant shall remove all of its personal property and trade fixtures from the Premises prior to the expiration or earlier termination of this Lease. Tenant shall perform at its sole cost and expense all restoration made necessary by its removal of alterations and improvements, personal property, and trade fixtures. Landlord may elect to retain or to dispose of in any manner any alterations or improvements that Tenant is required to remove pursuant to Paragraph 10(e) above, or Tenant's trade fixtures or personal property that Tenant does not remove from the Premises on expiration or earlier termination of this Lease by giving at least ten (10) days written notice to Tenant. Title to any such alterations, improvements, trade fixtures, or personal property that Landlord elects to retain or to dispose of on expiration of the aforesaid ten (10) day period shall vest in Landlord. Tenant waives all claims against Landlord and Landlord's agents for any damage to Tenant resulting from Landlord's retention or disposition of any such alterations, improvements, trade fixtures, and/or personal property, and Tenant shall be liable to Landlord for Landlord's costs and expenses for storing, removing, and disposing of same, and for the cost of restoring the Premises thereafter to the condition required by subparagraph (a), above.

  • Tenant’s Entry Into the Premises Prior to Substantial Completion Subject to the terms hereof and provided that Tenant and its agents do not interfere with, or delay, Contractor’s work in the Building and the Premises, at Landlord’s reasonable discretion, Contractor shall allow Tenant access to the Premises prior to the Substantial Completion of the Premises for the purpose of Tenant installing any necessary furniture, equipment or fixtures (including Tenant’s data and telephone equipment) in the Premises. Prior to Tenant’s entry into the Premises as permitted by the terms of this Section 6.01, Tenant shall submit a schedule to Landlord and Contractor, for their approval, which schedule shall detail the timing and purpose of Tenant’s entry, and Landlord will reasonably cooperate with Tenant to coordinate Landlord’s Contractor’s work of constructing the Tenant Improvements with such access by Tenant for the installation of Tenant’s furniture, equipment and fixtures. In connection with any such entry, Tenant acknowledges and agrees that Tenant’s employees, agents, contractors, consultants, workmen, mechanics, suppliers and invitees shall fully cooperate, work in harmony and not, in any manner, interfere with Landlord or Landlord’s Contractor, agents or representatives in performing work in the Building and the Premises, or interfere with the general operation of the Building and/or the Project; and such entry shall be subject to the site management rules of Landlord and Landlord’s Contractor. If at any time any such person representing Tenant shall not be cooperative or shall otherwise cause or threaten to cause any such disharmony or interference, including, without limitation, labor disharmony, and Tenant fails to immediately institute and maintain corrective actions as directed by Landlord, then Landlord may revoke Tenant’s entry rights upon twenty-four (24) hours’ prior written notice to Tenant. Tenant acknowledges and agrees that any such entry into and occupancy of the Premises or any portion thereof by Tenant or any person or entity working for or on behalf of Tenant shall be deemed to be subject to all of the terms, covenants, conditions and provisions of the Lease, excluding only the covenant to pay Rent (until the occurrence of the Lease Commencement Date). Tenant further acknowledges and agrees that Landlord shall not be liable for any injury, loss or damage which may occur to any of Tenant’s work made in or about the Premises in connection with such entry or to any property placed therein prior to the Lease Commencement Date, the same being at Tenant’s sole risk and liability. Tenant shall be liable to Landlord for any damage to any portion of the Premises, including the Tenant Improvement work, caused by Tenant or any of Tenant’s employees, agents, contractors, consultants, workmen, mechanics, suppliers and invitees. If the performance of Tenant’s work in connection with such entry causes extra costs to be incurred by Landlord or requires the use of any Building services, Tenant shall promptly reimburse Landlord for such extra costs and/or shall pay Landlord for such Building services at Landlord’s standard rates then in effect. In addition, Tenant shall hold Landlord harmless from and indemnify, protect and defend Landlord against any loss or damage to the Building or Premises and against injury to any persons caused by Tenant’s actions pursuant to this Section 6.01.

  • Lease of Premises Landlord hereby leases to Tenant and Tenant hereby leases from Landlord the Premises for the Term and upon the terms, covenants and conditions provided in this Lease.

  • Substitute Premises The “Substitute Premises” shall mean a parcel of land located by itself on a separate tax parcel with a completed building constructed thereon, with respect to which a certificate of occupancy has been issued and all other licenses and permits have been received, provided, however, that such land and building shall have a then-current appraised value at least equal to the current appraised value of the Premises (or in the case of damage or destruction the anticipated appraised value of the building) upon completion of the Building. Notwithstanding the immediately preceding sentence, the Substitute Premises shall not be required to be located in the same state as the Premises if Master Tenant pays to or for the benefit of Landlord all costs and expenses incurred by Landlord and Fee Mortgagee in connection with the acquisition and ownership of such property which would not have been incurred had the Substitute Premises been located in the same state as the Premises.

  • Construction In First Offer Space Tenant shall take the First Offer Space in its “as is” condition, subject to any improvement allowance granted as a component of the Fair Rental Value, and the construction of improvements in the First Offer Space shall comply with the terms of Article 8 of this Lease.

  • Additional Premises Landlord shall use commercially reasonable efforts to expand the Premises to include an additional fifteen thousand four hundred ten (15,410) square feet of Rentable Area located on the first (1st) floor, as shown on Exhibit A attached hereto (the “Additional Premises”) on July 1, 2012 (the “Additional Premises Delivery Date”). In the event Landlord determines the Additional Premises will be ready for delivery to Tenant in the Required Condition on the Additional Premises Delivery Date, within ten (10) business days prior to the Additional Premises Delivery Date, Landlord and Tenant shall enter into a written amendment to the Lease, which amendment shall provide, unless otherwise agreed in writing, (a) that the commencement date of the Additional Premises shall be the Additional Premises Delivery Date (the “Additional Premises Commencement Date”), (b) that, as of the Additional Premises Commencement Date, the Premises under the Lease shall be increased to include the Additional Premises for a total of sixty-one thousand four hundred forty-four (61,444) square feet of Rentable Area (together, the Premises and the Additional Premises shall be referred to hereinafter as the “Total Premises”), (c) the new Basic Annual Rent applicable to the Total Premises, which shall commence on the Additional Premises Commencement Date and shall be as further described in Section 4.2 of this Amendment, (d) Tenant’s new Pro Rata Share of Operating Expenses as of the Additional Premises Commencement Date, which Pro Rata Share shall equal one hundred percent (100%) of the Building and thirty-three and 51/100 percent (33.51%) of the Project and (e) that, in addition to the parking which Tenant is entitled to under the terms of the Lease with respect to the original Premises, Tenant, for so long as Tenant leases the Additional Premises, shall have a non-exclusive license to use the parking facilities serving the Building in common on an unreserved basis with other tenants of the Building and the Project at a ratio of 3.3 parking spaces per 1,000 rentable square feet of Additional Premises, which amounts to fifty-one (51) additional parking spaces, which number shall include three (3) additional Reserved Spaces. In the event the Additional Premises is not ready for delivery to Tenant in the Required Condition on the Additional Premises Delivery Date, then (x) this Amendment and the Lease shall not be void or voidable, (y) Landlord shall not be liable to Tenant for any loss or damage resulting therefrom and (z) the new Basic Annual Rent applicable to the Premises shall be as further described in Section 4.3 of this Amendment.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!