Adverse Weather Condition definition

Adverse Weather Condition means heavy rains, extreme cold, snow, ice, Environmental Protection Agency designated “Clean Air Action Days”, or any other inclement weather conditions which, in the opinion of the Director, requires emergency, additional sweeps in order to protect the public health, safety, and welfare.
Sample 1Sample 2Sample 3
Adverse Weather Condition has the meaning set forth in Section 22.2.
Sample 1Sample 2
Adverse Weather Condition means any weather condition which reasonably prevents BCCK from being able to perform on any day four (4) or more hours of Work on a critical path item in BCCK’s construction schedule). A delay of either party will not constitute a default hereunder or be the basis for, or give rise to, any claim for damages, if and to the extent such delay is caused by Force Majeure and to the extent the other provisions of this Section 22.2 are satisfied. In the event of Force Majeure, the time for performance of an obligation of Linn and the time for performance of an obligation of BCCK, including any specific date for completion of all or any part of the Work, will be extended for a period equal to the delay in obtaining Mechanical Completion occasioned by Force Majeure, except that the time for the obligation of Linn to pay for the cost of Work (or portion thereof that is due) will be made as soon as possible, but in no event later than fifteen (15) days after cessation of the event of Force Majeure. As a condition to claiming a delay caused by Force Majeure, the party who is prevented from performing by Force Majeure (i) will be obligated, within a reasonable period not to exceed five (5) Days after the occurrence or detection of Xxxx Xxxxxxxx Trail Cryogenic Gas Plant Page 38 Engineering and Construction Agreement # BK17056EC 18261184v.16 139990/00005 any such event, to give notice to the other party setting forth in reasonable detail the nature thereof and the anticipated extent of the delay, and (ii) will use all reasonable efforts to remedy such cause as soon as reasonably possible. If any Force Majeure event prevents, hinders, or delays performance by BCCK hereunder for more than one hundred twenty (120) consecutive days for reasons other than the following:
Sample 1

Examples of Adverse Weather Condition in a sentence

  • Adverse Weather Condition #1: Unusually Heavy Precipitation - Figure 1 illustrates the anticipated monthly inclement weather due to precipitation (Rain Days).

  • Average days with precipitation of 0.1” or more Adverse Weather Condition #2: Temperature – The Contractor may be entitled to an additional day for every day that the recorded high temperature at Washington Reagan National Airport is 40 degrees Fahrenheit or less, that has not already been claimed under Weather Condition #1 above.‌L.

  • Average days with precipitation of 0.1” or more Adverse Weather Condition #2: Temperature – The Contractor may be entitled to an additional day for every day that the recorded high temperature at Washington Reagan National Airport is 40 degrees Fahrenheit or less, that has not already been claimed under Weather Condition #1 above.

  • Findings No findings of significance were identified..4 Readiness For Impending Adverse Weather Condition – Heavy Rainfall/External Flooding Conditions a.

  • Readiness for Impending Adverse Weather Condition – Tornado Watch a.

  • No findings of significance were identified..2 Readiness for Impending Adverse Weather Condition – Tornado Watch a.

  • No findings were identified..2 Readiness for Impending Adverse Weather Condition – High Wind Conditions a.

  • No findings were identified..2 Readiness for Impending Adverse Weather Condition – Heavy Snowfall Conditions a.


More Definitions of Adverse Weather Condition

Adverse Weather Condition means weather and/or sea conditions actually experienced that are sufficiently severe to prevent an LNG Vessel from proceeding safely to berth, loading or unloading (as the case may be) and/or departing safely from the berth in accordance with the weather standards prescribed in published regulations in effect at the Loading Location or the Unloading Location (as the case may be), or by the order of the relevant harbour master.
Sample 1

Related to Adverse Weather Condition

  • OTHER CONDITIONS Any subsequent contracts shall supersede the provisions of this contract. PARTIES: The Fort Xxxxx School District 100, Party of the First Part, and XXXXXXX X XXXXXXX Party of the Second Part, agree as follows:

  • Normal Operating Conditions means those Service conditions which are within the control of Grantee. Those conditions which are not within the control of Grantee include, but are not limited to, natural disasters, civil disturbances, power outages, telephone network outages, and severe or unusual weather conditions. Those conditions which are ordinarily within the control of Grantee include, but are not limited to, special promotions, pay-per-view events, rate increases, regular peak or seasonal demand periods, and maintenance or upgrade of the Cable System.

  • Nonconforming zoning condition means a physical improvement on a property that does not conform with current zoning standards.

  • Review Conditions means (i) the Delinquency Percentage for any Payment Date exceeds the Delinquency Trigger for that Payment Date and (ii) the Noteholders or Note Owners, as applicable, have voted, pursuant to Section 2.03(d) of the Receivables Purchase Agreement, to direct an Asset Representations Review of the Subject Receivables.

  • Business Condition means the financial condition, business, assets, liabilities and operations of a Person.

  • Specified Conditions means, at any time of determination thereof, (a) no Incremental Term Loans in the form of an institutional term loan B facility have been issued and are outstanding pursuant to Section 2.20 of the Credit Agreement and (b) (i) the Company’s “corporate credit rating” from S&P (or such other term as S&P may from time to time use to describe the Company’s senior unsecured non-credit enhanced long term indebtedness, such rating, the “S&P Rating”) shall be at least BBB- (with a stable outlook) and the Company’s “corporate family rating” from Xxxxx’x (or such other term as Xxxxx’x may from time to time use to describe the Company’s senior unsecured non-credit enhanced long term indebtedness, such rating, the “Xxxxx’x Rating”) shall be at least Baa3 (with a stable outlook) or (ii) (x) the Company’s S&P Rating shall be at least BBB- (with a stable outlook) or the Company’s Xxxxx’x Rating shall be at least Baa3 (with a stable outlook) and (y) the Leverage Ratio is less than or equal to 2.50 to 1.00.

  • Unsafe condition as used in this clause means the actual or potential exposure of contractor or Government employees to a hazardous material as defined in Federal Standard No. 313, and any revisions thereto during the term of this contract, or any other material or working condition designated by the Contracting Officer's Technical Representative (COTR) as potentially hazardous and requiring safety controls.

  • Offer Conditions has the meaning set forth in Section 1.01(b).

  • Abnormal Condition means any condition on the Interconnection Facilities which, determined in accordance with Good Utility Practice, is: (i) outside normal operating parameters such that facilities are operating outside their normal ratings or that reasonable operating limits have been exceeded; and (ii) could reasonably be expected to materially and adversely affect the safe and reliable operation of the Interconnection Facilities; but which, in any case, could reasonably be expected to result in an Emergency Condition. Any condition or situation that results from lack of sufficient generating capacity to meet load requirements or that results solely from economic conditions shall not, standing alone, constitute an Abnormal Condition.

  • Specified Condition means, with respect to a party, any event specified as such for that party in Paragraph 13.

  • Abnormal Market Conditions means conditions contrary to Normal Markets Conditions e.g. when there is low liquidity in the market or rapid price movements in the market or Price Gaps.

  • Serious health condition means an illness, injury, impairment, or physical or mental condition that involves:

  • Obstetric condition means a condition that is listed under Group T4 (Obstetrics) in the Medicare Benefits Schedule.

  • Termination Conditions means, collectively, (a) the payment in full in cash of the Obligations (other than (i) contingent indemnification obligations not then due and (ii) Obligations under Secured Hedge Agreements and Secured Cash Management Agreements) and (b) the termination of the Commitments and the termination or expiration of all Letters of Credit under this Agreement (unless the Outstanding Amount of the L/C Obligations related thereto has been Cash Collateralized on terms reasonably acceptable to the applicable Issuing Bank, backstopped by a letter of credit reasonably satisfactory to the applicable Issuing Bank or deemed reissued under another agreement reasonably acceptable to the applicable Issuing Bank).

  • Step Down Conditions As of any Distribution Date on which any decrease in any Senior Prepayment Percentage may apply, (i) the outstanding Principal Balance of all Mortgage Loans 60 days or more Delinquent (including Mortgage Loans in REO and foreclosure), averaged over the preceding six month period, as a percentage of the aggregate of the Class Certificate Principal Balances of the Classes of Subordinate Certificates on such Distribution Date, does not equal or exceed 50% and (ii) cumulative Realized Losses with respect to all of the Mortgage Loans do not exceed: · for any Distribution Date on or after the seventh anniversary until the eighth anniversary of the first Distribution Date, 30% of the aggregate Certificate Principal Balance of the Subordinate Certificates as of the Closing Date, · for any Distribution Date on or after the eighth anniversary until the ninth anniversary of the first Distribution Date, 35% of the aggregate Certificate Principal Balance of the Subordinate Certificates as of the Closing Date, · for any Distribution Date on or after the ninth anniversary until the tenth anniversary of the first Distribution Date, 40% of the aggregate Certificate Principal Balance of the Subordinate Certificates as of the Closing Date, · for any Distribution Date on or after the tenth anniversary until the eleventh anniversary of the first Distribution Date, 45% of the aggregate Certificate Principal Balance of the Subordinate Certificates as of the Closing Date, and · for any Distribution Date on or after the eleventh anniversary of the first Distribution Date, 50% of the aggregate Certificate Principal Balance of the Subordinate Certificates as of the Closing Date.

  • Environmental Conditions means any conditions of the environment, including, without limitation, the work place, the ocean, natural resources (including flora or fauna), soil, surface water, ground water, any actual or potential drinking water supply sources, substrata or the ambient air, relating to or arising out of, or caused by the use, handling, storage, treatment, recycling, generation, transportation, Release or threatened Release or other management or mismanagement of Regulated Substances resulting from the use of, or operations on, the Property.

  • Regulatory Conditions means the conditions set out in paragraphs 3.3 to 3.5 (inclusive) of Part A of Appendix I to the Announcement;

  • Hazardous condition means any situation involving the actual, imminent or probable spillage, leakage, or release of a hazardous substance onto the land, into a water of the State or into the atmosphere which creates an immediate or potential danger to the public health or safety or to the environment.

  • Conditions means these terms and conditions;

  • Closing Conditions shall include, but are not limited to, SI Securities determining in its sole discretion that at the time of a closing, the Minimum Offering has been met, the investment remains suitable for investors, investors have successfully passed ID, KYC, AML, OFAC, and suitability screening, and that Issuer has completed all actions required by it as communicated by SI Securities at the time of a closing.

  • Associated Conditions means the symptoms or side effects associated with Stage-Four Advanced, Metastatic Cancer or its treatment and which, in the judgment of the health care practitioner, further jeopardize the health of a patient if left untreated.

  • Eligibility Conditions means the eligibility conditions specified in the Act and the Rules including all the eligibilityconditions listed in Clause [5] of the Tender Document.

  • Adverse Environmental Condition shall refer to (i) the existence or the continuation of the existence, of an Environmental Emission (including, without limitation, a sudden or non-sudden accidental or non-accidental Environmental Emission), of, or exposure to, any substance, chemical, material, pollutant, Contaminant, odor or audible noise or other release or emission in, into or onto the environment (including, without limitation, the air, ground, water or any surface) at, in, by, from or related to any Equipment, (ii) the environmental aspect of the transportation, storage, treatment or disposal of materials in connection with the operation of any Equipment or (iii) the violation, or alleged violation of any statutes, ordinances, orders, rules regulations, permits or licenses of, by or from any governmental authority, agency or court relating to environmental matters connected with any Equipment.

  • Specific Conditions means the conditions in addition or in variation to the general conditions which the Commission may lay down specifically for a distribution licensee;

  • Environmental Condition means any condition or circumstance, including the presence of Hazardous Substances which does or would (i) require assessment, investigation, abatement, correction, removal or remediation under any Environmental Law, (ii) give rise to any civil or criminal Liability under any Environmental Law, (iii) create or constitute a public or private nuisance or (iv) constitute a violation of or non-compliance with any Environmental Law.

  • Condition Satisfaction Date shall have the meaning set forth in Section 7.2.