Arbitration Language definition

Arbitration Language means the arbitration language identified in the Key Information Table.
Sample 1Sample 2Sample 3
Arbitration Language shall be the language specified in the Key Information Table.
Sample 1Sample 2Sample 3
Arbitration Language shall be the language specified in the Key Information Table. 8User Note: Pursuant to Article 10 of the ICC Rules, the ICC International Court of Arbitration may also, at the request of a party, consolidate two or more arbitrations pending under the Rules into a single arbitration, if: a) the parties have agreed to consolidation; or b) all of the claims in the arbitrations are made under the same arbitration agreement; or c) the claims in the arbitrations are made under more than one arbitration agreement, the arbitrations are between the same parties, the disputes in the arbitrations arise in connection with the same legal relationship, and the Court finds the arbitration agreements to be compatible. 9User Note: In light of the limited resources of the Project Company and additional delay caused by resolving related disputes in separate proceedings, the right to consolidate with other proceedings should typically be in the interests of all parties. As a practical matter, some parties may object to consolidation on policy grounds. The parties should note that not consolidating related disputes in a single arbitration amplifies the claims risk for the Project Company which may have an adverse effect on the risk profile of the Project. In any case, where consolidation cannot be accepted in one agreement it is still beneficial to include the Cause in all other Project Agreements where it can be accepted and the reference to the agreement that does not contain the consolidation Cause should not be omitted from the list contained in the consolidation Causes included in the remainder of the Project Agreements. 10User Note: Signature blocks will need to be confirmed based on laws applicable to the execution of documents from each party's country of incorporation 0User Note: It is anticipated that a detailed matrix shall be inserted here. The matrix will be common to both the Supply Agreement and the Installation Agreement. It should detail all of the Works and services required to complete the Facility and allocate responsibility for each of them as either "Supply Works" or "Installation Works" between the Supplier the Installation Contractor and/or to the Project Company. Care should be taken to avoid conflict with the general conditions of contract. 0User Note: Include pass down of requirements from Implementation Agreement.
Sample 1Sample 2

Examples of Arbitration Language in a sentence

  • Arbitration5 Unless resolved amicably or in the case of a Technical Dispute by Expert Determination and subject to the requirements in this Clause 18 (Dispute Resolution), all Disputes shall be finally settled by international arbitration under the Rules of the Arbitration of the International Chamber of Commerce by one or more arbitrators appointed in accordance with the said Rules.6 The arbitration shall be conducted in the Arbitration Language.

  • Arbitration5 Unless resolved amicably or in the case of a Technical Dispute by Expert Determination and subject to the requirements in this Clause 22.5 (Arbitration), all Disputes shall be finally settled by international arbitration under the Rules of the Arbitration of the International Chamber of Commerce by one or more arbitrators appointed in accordance with the said Rules.6 The arbitration shall be conducted in the Arbitration Language.

  • Delay Liquidated Damages Cap4 12.4 [●] Commercial Operation Longstop Date 12.5 [●] Minimum Guaranteed Capacity 15.2 [●] Default Rate 23.1(f) [●] Termination Fee 26.3 [●] Maximum Liability 24.1(a)(vi) [●] Cost or Savings Threshold 1.1 [●] Governing Law5 37.14 [●] Mediation Rules 38.2 [●] Expert Appointing Authority6 38.3(c) [●] Arbitration Language 38.4(b) [●] Arbitration Seat7 38.4(c) [●] Lender Direct Agreement 4.4(a) [Applicable] [Not Applicable].

  • Delay Liquidated Damages Cap4 12.4 [●] Commercial Operation Longstop Date 12.5 [●] Minimum Guaranteed Capacity 15.2 [●] Default Rate 23.1(f) [●] Termination Fee 26.3 [●] Maximum Liability 24.1(a)(vi) [●] Cost or Savings Threshold 1.1 [●] Governing Law5 37.15 [●] Mediation Rules 38.2 [●] Expert Appointing Authority6 38.3(c) [●] Arbitration Language 38.4(b) [●] Arbitration Seat7 38.4(c) [●] Lender Direct Agreement 4.4(a) [Applicable] [Not Applicable].

  • Arbitration48 Unless resolved amicably or in the case of a Technical Dispute, by Expert Determination and subject to the requirements in Clause 20.1 (Senior Manager Discussions) (and Clause 20.3(a) (Expert Determination), all Disputes shall be finally settled49 by international arbitration under the Rules of the Arbitration of the International Chamber of Commerce by one or more arbitrators appointed in accordance with the said Rules.50 The arbitration shall be conducted in the Arbitration Language.


More Definitions of Arbitration Language

Arbitration Language is defined in the Key Information Table.
Sample 1Sample 2

Related to Arbitration Language

  • Arbitration means any arbitration whether or not administered by a permanent arbitral institution;

  • Arbitration Act means the Arbitration and Conciliation Act, 1996 and shall include any amendment to or any re-enactment thereof as in force from time to time.

  • Arbitration Tribunal means an organ composed of an odd number of persons known as arbitrators, who decide on the solution of a conflict in which the parties have expressly waived recourse to the ordinary civil courts

  • plain language means language that can be understood by a reasonable person, applying a reasonable effort;

  • Arbitration Panel shall have the meaning set forth in Section 3 hereof.

  • Mediation means any process in which a mediator facilitates communication and negotiation between the parties to assist them in reaching a voluntary agreement regarding their dispute.

  • Notice of Arbitration means the formal notice from the CONTRACTOR or the CUSTOMER to the other party referring a dispute to arbitration in accordance with the provisions of Schedule 2-9.

  • Arbitration Award shall have the meaning given such term in Section 22.5.

  • Arbitration Rules means the AAA’s Commercial Arbitration Rules and Mediation Procedures.

  • English Language French Language:

  • Primary language means the dominant language used by a person for communication.

  • Compulsory arbitration means the procedure whereby parties involved in a labor dispute

  • Dispute Resolution means the procedure set forth in this LGIP for resolution of a dispute between the Parties.

  • Alternative dispute resolution means mediation, arbitration, conciliation, or other nonjudicial procedure that involves a neutral party in the decisionmaking process. The form of alternative dispute resolution chosen pursuant to this article may be binding or nonbinding, with the voluntary consent of the parties.

  • UNCITRAL Arbitration Rules means the arbitration rules of the United Nations Commission on International Trade Law.

  • Arbitration Notice has the meaning set forth in Section 9.13.

  • Dispute Resolution Procedure means the procedure for resolving disputes as set out in Clause 17 (Dispute Resolution);

  • English language learner means limited English proficient pupils who speak a language other than English as their primary language and have difficulty speaking, reading, writing, or understanding English as reported to the center.

  • Arbitration Request shall have the meaning set forth in Section 7.3(a).

  • Agreement Disputes shall have the meaning set forth in Section 10.1.

  • Arbitrators has the meaning set forth in Section 9.2(iii).

  • Panel means the Panel on Takeovers and Mergers;

  • JAMS means JAMS, Inc. or its successor entity, a judicial arbitration and mediation service.

  • Arbitral Tribunal means a sole arbitrator or a panel of arbitrators;

  • Speech-language pathology means the care and services provided by a licensed speech-language pathologist as set forth in the member state's statutes and rules.

  • arbitration agreement means an agreement by the parties to submit to arbitration all or certain disputes which have arisen or which may arise between them in respect of a defined legal relationship, whether contractual or not;