KEY INFORMATION TABLE Sample Clauses

KEY INFORMATION TABLE. Commercial Information Subject Clause Key information
Sample 1Sample 2
AutoNDA by SimpleDocs
KEY INFORMATION TABLE. Commercial Information Subject Clause Key Information (a) [the modules, support structures, inverters, transformers, switchgear, SCADA System, monitoring and site surveillance system, the Spares Stock (if applicable) and all other equipment required for the Facility, save to the extent any of this equipment and materials forms part of the Balance of Plant]. PV System Delivery Point 4.14(b) [●]2 Scheduled Equipment Acceptance Date 4.14(b) [●] Lender's Performance Standards3 5.1 [insert required performance standards of the Lender e.g. "Equator Principles" and/or "IFC Performance Standards" or] [Not applicable]. Industry Standards 5.4(b) [IEC standard 62446 (Photovoltaic (PV) systems - requirements for testing, documentation and maintenance)]. Defects Warranty Period 11.2(a) [●] commencing on the Commercial Operation Date as may be extended in accordance with this Agreement. Modules Breakage Threshold 11.2(b) [insert number or percentage of Modules]. Scheduled COD 12.2 [●] Delay Liquidated Damages Rate 12.3 [●] per day of delay. Delay Liquidated Damages Cap4 12.4 [●] Commercial Operation Longstop Date 12.5 [●] Minimum Guaranteed Capacity 15.2 [●] Default Rate 23.1(f) [●] Termination Fee 26.3 [●] Maximum Liability 24.1(a)(vi) [●] Cost or Savings Threshold 1.1 [●] Governing Law5 37.15 [●] Mediation Rules 38.2 [●] Expert Appointing Authority6 38.3(c) [●] Arbitration Language 38.4(b) [●] Arbitration Seat7 38.4(c) [●] Lender Direct Agreement 4.4(a) [Applicable] [Not Applicable]. Man-Made Underground Structures as a Relevant Event entitling time relief8 6.3 and 13.3(b) [Applicable] [Not Applicable]. Man-Made Underground Structures entitling cost relief9 6.3 and 13.3(b) [Applicable] [Not Applicable].
Sample 1
KEY INFORMATION TABLE. Commercial Information Options Subject Clause Key Information Project Information Subject Clause Key Information Government 1.1 [●] Insolvency Event paragraph (e) 1.1 [●] Installation Contractor 1.1 [●] Landowner 1.1 [●] Network Operator 1.1 [●] Nominated Account 1.1 [●] Project Agreements 1.1 [Implementation Agreement Supply Agreement, O&M Agreement, Grid Connection Agreement, Land Agreement, Finance Agreements, any meter operating agreement and any electricity supply agreement]. Relevant Jurisdiction 1.1 [●] Site 1.1 [●] Buyer Notice Details 20.1 For the attention of: [●] Address: [●] Tel. No: [●] Fax No. [●] Email: [●] Project Company Notice Details 20.1 For the attention of: [●] Address: [●] Tel. No: [●] Fax No. [●] Email: [●]
Sample 1
KEY INFORMATION TABLE. Subject Clause Key Information (a) [ICC arbitration in [insert seat of arbitration]8 [non-exclusive jurisdiction of the courts of [insert jurisdiction]9]10. DSRA Funding Period 27 [insert period of months e.g. 6 or 12 months]. Final Maturity Date 15 [insert agreed date]. (d) [means any indebtedness for or in respect of: moneys borrowed; any amount raised by acceptance under any acceptance credit facility or dematerialised equivalent; any amount raised pursuant to any note purchase facility or the issue of bonds, notes, debentures, loan stock or any similar instrument; the amount of any liability in respect of any lease or hire purchase contract which would in accordance with [IFRS]11, be treated as a finance or capital lease; receivables sold or discounted (other than any receivables to the extent they are sold on a non-recourse basis); any amount raised under any other transaction (including any forward sale or purchase agreement) of a type not referred to in any other paragraph of this definition having the commercial effect of a borrowing; any derivative transaction entered into in connection with protection against or benefit from fluctuation in any rate or price (and when calculating the value of any derivative transaction, only the marked to market value (or if any actual amount is due as a result of the termination or close-out of that derivative transaction, that amount) shall be taken into account); any counter-indemnity obligation in respect of a guarantee, indemnity, bond, standby or documentary letter of credit or any other instrument issued by a bank or financial institution; and the amount of any liability in respect of any guarantee or indemnity for any of the items referred to in paragraphs (a) to (h) above.] Governing Law of the Finance Agreements 43 [insert governing law]. Hedging Strategy 46 [Applicable] [Not Applicable]. [IFRS 3712 Means the International Financial Reporting Standards (formerly International Accounting Standards), which are the standards issued by the International Accounting Standards Board together with the interpretations issued by the International Financial Reporting Interpretations Committee of the International Accounting Standards Board (as amended, supplemented or re-issued from time to time) applied on a consistent basis both as to classification of items and amounts.] Information Covenants – threshold amounts for reporting details of any damage or destruction to the Project assets or of any insurance claim 35...
Sample 1
KEY INFORMATION TABLE. Lead Applicant
Sample 1
KEY INFORMATION TABLE. Application Name Cost total for eligible activity (A) supplemental action plan activities in support of an existing Action Plan
Sample 1

Related to KEY INFORMATION TABLE

  • News/Information Release The Contractor agrees that it will not issue any news releases in connection with either the award of this Contract or any subsequent amendment of or effort under this Contract without first obtaining review and written approval of said news releases from the County through the County’s Project Manager.

  • Eligibility Information Group shall provide timely and accurate eligibility information, including Medicare status, and identify all persons subject to the Medicare Secondary Payer statutes and regulations. Group acknowledges that BCN will rely upon the accuracy of all eligibility information Group provides, and Group shall indemnify and hold BCN harmless against any loss, claim or action, including costs, penalties and reasonable attorney fees, arising from the provision of inaccurate eligibility information.

  • Exclusions from Confidential Information Receiving Party's obligations under this Agreement do not extend to information that is: (a) publicly known at the time of disclosure or subsequently becomes publicly known through no fault of the Receiving Party; (b) discovered or created by the Receiving Party before disclosure by Disclosing Party; (c) learned by the Receiving Party through legitimate means other than from the Disclosing Party or Disclosing Party's representatives; or (d) is disclosed by Receiving Party with Disclosing Party's prior written approval.

  • How Do I Get More Information? This Notice summarizes the Action, the terms of the Settlements, and your rights and options in connection with the Settlements. More details are in the Settlement Agreements, which are available for your review at xxx.XxxxxxxxxXxxXxxxxxxxxXxxxxxxxxx.xxx. The Settlement Website also has the Second Amended Complaint and other documents relating to the Settlements. You may also call toll-free 0-000-000-0000 or write the Claims Administrator at: Financial Aid Antitrust Settlements, c/o Claims Administrator, 0000 Xxxx Xxxxxx, Xxxxx 0000, Xxxxxxxxxxxx, XX 00000. To: Settlement Class Member Email Address From: Claims Administrator Subject: Notice of Proposed Class Action Settlement – Xxxxx, et al. x. Xxxxx University, et al. Please visit xxx.XxxxxxxxxXxxXxxxxxxxxXxxxxxxxxx.xxx for more information. • The Court has preliminarily approved proposed settlements (“Settlements”) with the following ten schools: Brown University, the University of Chicago, the Trustees of Columbia University in the City of New York, Trustees of Dartmouth College, Duke University, Emory University, Northwestern University, Xxxxxxx Xxxxx Xxxx University, Vanderbilt University, and Yale University (collectively the “Settling Universities”). • The Court has also preliminarily approved a class of students who attended one or more of the Settling Universities during certain time periods. This is referred to as the “Settlement Class,” which is defined in more detail below.

  • - CLEC INFORMATION 3.1 Except as otherwise required by law, CenturyLink will not provide or establish Interconnection, Unbundled Network Elements, ancillary services and/or resale of Telecommunications Services in accordance with the terms and conditions of this Agreement prior to CLEC's execution of this Agreement. The Parties shall complete CenturyLink's "New Customer Questionnaire," as it applies to CLEC's obtaining of Interconnection, Unbundled Network Elements, ancillary services, and/or resale of Telecommunications Services hereunder. 3.2 Prior to placing any orders for services under this Agreement, the Parties will jointly complete the following sections of CenturyLink's "New Customer Questionnaire:" General Information Billing and Collection (Section 1) Credit Information Billing Information Summary Billing OSS and Network Outage Notification Contact Information System Administration Contact Information Ordering Information for LIS Trunks, Collocation, and Associated Products (if CLEC plans to order these services) Design Layout Request – LIS Trunking and Unbundled Loop (if CLEC plans to order these services) 3.2.1 The remainder of this questionnaire must be completed within two (2) weeks of completing the initial portion of the questionnaire. This questionnaire will be used to: Determine geographical requirements; Identify CLEC identification codes; Determine CenturyLink system requirements to support CLEC's specific activity; Collect credit information; Obtain Billing information; Create summary bills; Establish input and output requirements; Create and distribute CenturyLink and CLEC contact lists; and Identify CLEC hours and holidays. 3.2.2 CLECs that have previously completed a Questionnaire need not fill out a New Customer Questionnaire; however, CLEC will update its New Customer Questionnaire with any changes in the required information that have occurred and communicate those changes to CenturyLink. Before placing an order for a new product, CLEC will need to complete the relevant New Product Questionnaire and amend this Agreement.

  • KYC Information (i) Upon the reasonable request of the Lender made at least 1 day prior to the Closing Date, the Borrower shall have provided to the Lender the documentation and other information so requested in connection with applicable “know your customer” and anti-money-laundering rules and regulations, including the PATRIOT Act, in each case at least five days prior to the Closing Date. (ii) [reserved].

  • Disclosure Updates Promptly and in no event later than 5 Business Days after obtaining knowledge thereof, notify Agent if any written information, exhibit, or report furnished to the Lender Group contained, at the time it was furnished, any untrue statement of a material fact or omitted to state any material fact necessary to make the statements contained therein not misleading in light of the circumstances in which made. The foregoing to the contrary notwithstanding, any notification pursuant to the foregoing provision will not cure or remedy the effect of the prior untrue statement of a material fact or omission of any material fact nor shall any such notification have the effect of amending or modifying this Agreement or any of the Schedules hereto.

  • Confidential Information Definition Grantee acknowledges it and its employees or agents may, in the course of performing its responsibilities, be exposed to or acquire information that is: (i) confidential to Agency or Project participants or (ii) the disclosure of which is restricted under federal or state law, including without limitation: (a) personal information, as that term is used in ORS 646A.602(12), (b) social security numbers, and (c) information protected by the federal Family Educational Rights and Privacy Act under 20 USC § 1232g (items (i) and (ii) separately and collectively “Confidential Information”).

  • Verizon OSS Information 8.5.1 Subject to the provisions of this Section 8 and Applicable Law, Verizon grants to Reconex a non-exclusive license to use Verizon OSS Information. 8.5.2 All Verizon OSS Information shall at all times remain the property of Verizon. Except as expressly stated in this Section 8, Reconex shall acquire no rights in or to any Verizon OSS Information. 8.5.2.1 The provisions of this Section 8.5.2 shall apply to all Verizon OSS Information, except (a) Reconex Usage Information, (b) CPNI of Reconex, and (c) CPNI of a Verizon Customer or a Reconex Customer, to the extent the Customer has authorized Reconex to use the Customer Information. 8.5.2.2 Verizon OSS Information may be accessed and used by Reconex only to provide Telecommunications Services to Reconex Customers. 8.5.2.3 Reconex shall treat Verizon OSS Information that is designated by Verizon, through written or electronic notice (including, but not limited to, through the Verizon OSS Services), as “Confidential” or “Proprietary” as Confidential Information of Verizon pursuant to Section 10 of the Agreement. 8.5.2.4 Except as expressly stated in this Section 8, this Agreement does not grant to Reconex any right or license to grant sublicenses to other persons, or permission to other persons (except Reconex’s employees, agents or contractors, in accordance with Section 8.5.2.5 below, to access, use or disclose Verizon OSS Information. 8.5.2.5 Reconex’s employees, agents and contractors may access, use and disclose Verizon OSS Information only to the extent necessary for Reconex’s access to, and use and disclosure of, Verizon OSS Information permitted by this Section 8. Any access to, or use or disclosure of, Verizon OSS Information by Reconex’s employees, agents or contractors, shall be subject to the provisions of this Agreement, including, but not limited to, Section 10 of the Agreement and Section 8.5.2.3 above. 8.5.2.6 Reconex’s license to use Verizon OSS Information shall expire upon the earliest of: (a) the time when the Verizon OSS Information is no longer needed by Reconex to provide Telecommunications Services to Reconex Customers; (b) termination of the license in accordance with this Section 8; or (c) expiration or termination of the Agreement. 8.5.2.7 All Verizon OSS Information received by Reconex shall be destroyed or returned by Reconex to Verizon, upon expiration, suspension or termination of the license to use such Verizon OSS Information. 8.5.3 Unless sooner terminated or suspended in accordance with the Agreement or this Section 8 (including, but not limited to, Section 2.2 of the Agreement and Section 8.6.1 below), Reconex’s access to Verizon OSS Information through Verizon OSS Services shall terminate upon the expiration or termination of the Agreement. 8.5.3.1 Verizon shall have the right (but not the obligation) to audit Reconex to ascertain whether Reconex is complying with the requirements of Applicable Law and this Agreement with regard to Reconex’s access to, and use and disclosure of, Verizon OSS Information. 8.5.3.2 Without in any way limiting any other rights Verizon may have under the Agreement or Applicable Law, Verizon shall have the right (but not the obligation) to monitor Reconex’s access to and use of Verizon OSS Information which is made available by Verizon to Reconex pursuant to this Agreement, to ascertain whether Reconex is complying with the requirements of Applicable Law and this Agreement, with regard to Reconex’s access to, and use and disclosure of, such Verizon OSS Information. The foregoing right shall include, but not be limited to, the right (but not the obligation) to electronically monitor Reconex’s access to and use of Verizon OSS Information which is made available by Verizon to Reconex through Verizon OSS Facilities. 8.5.3.3 Information obtained by Verizon pursuant to this Section 8.5.3.3 shall be treated by Verizon as Confidential Information of Reconex pursuant to Section 10 of the Agreement; provided that, Verizon shall have the right (but not the obligation) to use and disclose information obtained by Verizon pursuant to this Section 8.5.3.3 to enforce Verizon’s rights under the Agreement or Applicable Law.

  • Employee Information The Company agrees to supply each employee with a copy of this Agreement.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!