The Seller shall pay any COD Delay LDs owing by the Seller to the Buyer within 30 days following the date specified in paragraph (b) above.
Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.
Excusable Delays means delays due to acts of terrorism, acts of war or civil insurrection, strikes, riots, floods, earthquakes, fires, tornadoes, casualties, acts of God, labor disputes, governmental restrictions or priorities, embargoes, national or regional material shortages, failure to obtain regulatory approval from any Federal or State regulatory body, unforeseen site conditions, extraordinary rainfall or snowfall, or any other condition or circumstances beyond the reasonable or foreseeable control of the applicable Party using reasonable diligence to overcome which prevents such Party from performing its specific duties or obligation hereunder in a timely manner; provided, however, Excusable Delay does not include lack of financing, unanticipated or unexpected increases in the costs of construction, or errors in business judgment by a Party; and provided further that Excusable Delay shall only extend the time of performance for the period of such Excusable Delay, which shall begin on the date which the event of Excusable Delay first occurs and extend until the date which the event which has caused the Excusable Delay has been corrected or performed, or reasonably should have been corrected or performed.
Tenant Delay means (i) any request by Tenant that Landlord delay in the commencement or completion of the Premises Base Building Work, or the Common Facilities Base Building Work, as applicable, for any reason; (ii) any delay in the Base Building Substantial Completion Date caused by Tenant’s contractors, agents and employee’s interference with Landlord and Landlord’s contractor’s, agents, and employees; or (iii) any other act or omission of Tenant or its officers, agents, servants or contractors which causes a delay in the Premises Base Building Work, or the Common Facilities Base Building Work, as applicable. If a delay shall occur in the Base Building Work as a result of Tenant Delay, then Tenant shall, within thirty (30) days after determination of the Rent Commencement Date, and only to the extent that such amount exceeds the rent credit, if any, due to Tenant, pay to Landlord for each day of Tenant’s Delay the amount of Basic Rent, Additional Rent and other charges that would have been payable hereunder had Tenant’s Delay not occurred to the extent that such Tenant Delay caused the Rent Commencement Date to be later than the date such date would have occurred had such Tenant Delay not occurred. Landlord shall give Tenant written notice of a Tenant Delay under clauses (ii) and (iii) above within twenty-four (24) hours after Landlord learns of such Tenant Delay. Subject to Tenant Delay and Force Majeure, if Landlord shall have failed to substantially complete the Premises Base Building Work on or before March 1, 2002, Tenant shall have the right to terminate the Lease by written notice to Landlord prior to March 15, 2002, whereupon this Lease shall terminate and be of no further force or effect thirty (30) days after the date of such notice unless Landlord shall have substantially completed the Premises Base Building Work prior to, or within such period.
Service Failure means a failure by the Contractor to provide the Services in accordance with any individual service level described above (measured on a monthly/quarterly/annual basis)
Reduced leave schedule means a leave schedule that reduces the usual number of hours per workweek, or hours per workday, of an employee.