Guaranteed Delivery Date has the meaning set forth in Section 5.2.

Guaranteed Delivery Date means the dates specified in the Purchase Order in accordance with the Cell Delivery Schedule specified in Annexure B or any such other date which is mutually agreed between the Parties, by which date the agreed quantity of Cells is required to be delivered by Supplier at the Designated Delivery Point.

Guaranteed Delivery Date has the meaning set forth in Section 5.2. “Hazardous Materials” has the meaning set forth in Section 19.1. “Indemnified Party” has the meaning set forth in Section 15.1. “Indemnifying Party” has the meaning set forth in Section 15.1. “Infringement Claim Costs” means any and all judgments, damages, fines, awards, penalties, and interest associated with any of the foregoing, that, in each case, are finally awarded in a claim for which an Indemnifying Party is obligated to indemnify an Indemnified Party under Section 15.2 or 15.3, as applicable, and costs and expenses, including reasonable attorneys’ fees, court costs and other reasonable costs of suit, arbitration, dispute resolution or other similar proceedings, associated with such claim. “Integrated Solution” means an integrated, stationary, battery based energy storage solution, comprised of inverters, a control system including software, and electrical battery. Notwithstanding the foregoing, the following will not be considered Integrated Solutions:

Examples of Guaranteed Delivery Date in a sentence

If an event of Force Majeure occurs that adversely affects Supplier’s Delivery obligations hereunder and provided that Supplier complies with the terms and conditions of this Article 17, Supplier may request a Change Order reflecting an extension of the Guaranteed Delivery Date of Cells.
Should Supplier fail to respond to BUYER’s request, within the foregoing (ten) 10 days period, Supplier and BUYER shall execute a written change order (“Change Order”) which shall reflect the proposed adjustments, if any, in the Purchase Order Price and the Guaranteed Delivery Date.
If Supplier proposes any changes, then it shall submit a proposal to BUYER with details of the change suggested and its impact on the on the Contract Price, the Guaranteed Delivery Date.
Within (fifteen)15 days after receiving such Discrepancy Notice, Supplier shall notify [BUYER CO] in writing of the Guaranteed Delivery Date of such make up or replacement Cells which shall be no later than the Guaranteed Replacement Delivery Period (as calculated from the date of the Discrepancy Notice).
If Supplier proposes any changes, then it shall submit a proposal to [BUYER CO] with details of the change suggested and its impact on the on the Contract Price, the Guaranteed Delivery Date.

More Definitions of Guaranteed Delivery Date

Guaranteed Delivery Date has the meaning set forth in Section 3(a).

Guaranteed Delivery Date means January 15, 2010 as to Building One and February 15, 2010 as to Building Two and Building Three, subject as to each date to extension as follows: (i) on a day-for-day basis for each day that the Closing Date is delayed beyond May 26, 2008, (ii) based on Permitted Changes to the Project Schedule, or (iii) as provided in Section 4.5 in connection with Owner’s failure to fund requisitioned amounts.

Guaranteed Delivery Date means the final date of delivery of all Equipment purchased from Seller under the terms of this Agreement to the Destination, as set forth on Exhibit A hereto.

Guaranteed Delivery Date means the “Guaranteed Delivery Date” or “Agreed to Dates (by GE & Kiewit)” indicated on Exhibit A, Attachment 02-01f corresponding to each Major Component and Minor Component as provided in the Milestone Schedule (which Guaranteed Delivery Date may be adjusted in accordance with the terms and provisions of this Agreement).

Guaranteed Delivery Date means those date/s for delivery confirmed in writing to Purchaser as fixed by the Company “Liquidated Damages Cap" shall mean the maximum agreed amount (if any) for payment of liquidated and ascertained damages “Normal Working Hours" shall mean 0800 to 1700 Monday to Friday

Guaranteed Delivery Date means, in relation to each lot of Line Pipe, the date by which Provisional Acceptance of the Line Pipe comprised in that lot is required to be achieved by the Line Pipe Supplier under the Line Pipe Supply Agreement, as set out in appendix 4 of the Line Pipe Supply Agreement which is attached to the Technical Specification, and as may be amended from time to time by the Employer and notified to the Contractor, and "Guaranteed Delivery Dates" means all of such dates.