Permitted Force Majeure Delays definition

Permitted Force Majeure Delays means delays in the construction of a Project or in connection with the ability to obtain a temporary certificate of occupancy for a Project (or any portion thereof) caused by any of the following: strikes or other labor disputes, lock-outs, acts of God, shortage of or inability to obtain labor, materials or tools, lawsuits brought by plaintiffs unaffiliated with the Borrower, restrictions imposed or mandated by governmental or quasi-governmental entities in issuing requisite approvals or consents, enemy action, civil commotion, riots, fire, flood, earthquake, severe or inclement weather, each of which events or circumstances must be beyond the reasonable control of the Borrower or any Borrower Subsidiary.
Sample 1Sample 2Sample 3
Permitted Force Majeure Delays means an act or event, whether or not foreseen, that: (a) is beyond the reasonable control of, and is not due to the fault or negligence of, Property Owner, Common Member, Manager, Guarantor, or any of their respective Affiliates, and (ii) could not have been avoided by the exercise of due diligence, including, but not limited to, a labor controversy, strike, lockout, boycott, transportation stoppage, action of a court or public authority, fire, flood, earthquake, storm, war, civil strife, terrorist action, epidemic, inability to obtain raw materials, supplies or equipment through its usual and regular sources, including any actions instituted by Governmental Authority due such epidemic or act of God; provided that a Permitted Force Majeure Delay will not include economic hardship, changes in market conditions, or insufficiency of funds. San Xxxxxx XX LLC
Sample 1
Permitted Force Majeure Delays means delays experienced by DRH in the construction process with respect to the Corrective Work that are not the result of the negligence or willful misconduct of DRH, but only to the extent such delays are legitimately caused by (a) strikes, lockouts or other labor disputes, unusual and unanticipated delays in deliveries, shortages in labor or materials, fire, windstorm, hurricane, tornado, earthquake, natural disaster, flooding or other casualty, acts of God, rioting or other civil disturbance, acts of war or acts of terrorism, adverse weather conditions of atypical severity, duration or frequency, regulatory/code changes from any other governmental authority arising after the date of this Agreement, or (b) other events that are both not reasonably expected and beyond the reasonable control of DRH. Notwithstanding the foregoing to the contrary, the characterization of a circumstance as a Permitted Force Majeure Delay is subject to the following requirements and conditions:
Sample 1

Examples of Permitted Force Majeure Delays in a sentence

  • As used herein, the term “Outside Date” shall mean the later of November 1, 2017, or the date 90 (ninety) days following the execution of this Agreement by all parties; provided, however, the Outside Date shall be extended by reason of Permitted Force Majeure Delays (as defined below).

Related to Permitted Force Majeure Delays

  • Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.

  • Tenant Delays means delays caused by: (i) requirements of the Plans and Specifications requested by Tenant that do not conform to Landlord’s building standards for office and lab build-out, or which contain long lead-time or non-standard items requested by Tenant; provided that Landlord has notified Tenant of such deviations upon execution of this Lease (ii) any material change in the Plans and Specifications requested by Tenant and agreed to by Landlord; (iii) any request by Tenant for a delay in the commencement or completion of the Initial Tenant Improvements for any reason; (iv) Tenant delay in finalizing and approving the design of the vivarium and value engineering of same or (v) any other act or omission of Tenant or its employees, agents or contractors which reasonably inhibits the Landlord from timely completing the Initial Tenant Improvements including, without limitation any delays caused by Tenant’s presence in the Premises prior to the Term Commencement Date. The Premises shall not be deemed to be incomplete if only minor or insubstantial details of construction, decoration or mechanical adjustments remain to be done which do not unreasonably interfere with Tenant’s occupancy of the Premises. If as a result of Tenant Delays the Premises are deemed ready for Tenant’s occupancy, pursuant to the foregoing (and the term shall have commenced by reason thereof), but the Premises are not in fact actually ready for Tenant’s occupancy, Tenant shall not (except with Landlord’s consent not to be unreasonably withheld, conditioned or delayed) be entitled to take possession of the Premises for the permitted use until the Premises are in fact actually ready for such occupancy.

  • Force Majeure Period has the meaning specified in Section 13.1.

  • Force Majeure means an event beyond the control of the supplier and not involving the supplier’s fault or negligence and not foreseeable. Such events may include, but is not restricted to, acts of the purchaser in its sovereign capacity, wars or revolutions, fires, floods, epidemics, quarantine restrictions and freight embargoes.

  • Excusable Delays means delays due to acts of terrorism, acts of war or civil insurrection, strikes, riots, floods, earthquakes, fires, tornadoes, casualties, acts of God, labor disputes, governmental restrictions or priorities, embargoes, national or regional material shortages, failure to obtain regulatory approval from any Federal or State regulatory body, unforeseen site conditions, extraordinary rainfall or snowfall, or any other condition or circumstances beyond the reasonable or foreseeable control of the applicable Party using reasonable diligence to overcome which prevents such Party from performing its specific duties or obligation hereunder in a timely manner; provided, however, Excusable Delay does not include lack of financing, unanticipated or unexpected increases in the costs of construction, or errors in business judgment by a Party; and provided further that Excusable Delay shall only extend the time of performance for the period of such Excusable Delay, which shall begin on the date which the event of Excusable Delay first occurs and extend until the date which the event which has caused the Excusable Delay has been corrected or performed, or reasonably should have been corrected or performed.

  • Force Majeure Events means acts of war, domestic and/or international terrorism, civil riots or rebellions, quarantines, embargoes and other similar unusual governmental actions, extraordinary elements of nature or acts of God.

  • Force Majeure Failure has the meaning set forth in Section 8.1(d).

  • Tenant Delay as used in the Lease or this Agreement shall mean any delay that Landlord may encounter in the performance of Landlord’s obligations under the Lease or this Agreement because of any act or omission of any nature by Tenant or its agents or contractors, including any: (1) delay attributable to changes in or additions to the Approved Plans or to the Landlord’s Work requested by Tenant; (2) delay attributable to the postponement of any Landlord’s Work at the request of Tenant; (3) delay caused by a Change Order requested by Tenant; (4) delay attributable to the failure of Tenant to pay, when due, any amounts required to be paid by Tenant pursuant to the Lease; or (5) delay attributable to a failure of Tenant to employ union labor for Tenant’s work at the Premises during the time the Landlord’s Work is being constructed. Tenant shall pay all actual costs and expenses incurred by Landlord which result from any Tenant Delay and the Commencement Date of the Lease shall be accelerated one (1) day for each day the Premises is not Ready for Occupancy as a result of a Tenant Delay. No Tenant Delay shall be deemed to have occurred unless Landlord gives Tenant prior written notice or written notice within five (5) days of the occurrence, as reasonable under the circumstances, specifying the claimed reasons for such Tenant Delay, and Tenant shall fail to promptly correct or cure such Tenant Delay. There shall be excluded from the number of days of any Tenant Delay, or any of the following events of force majeure: labor disputes, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, delays in obtaining permits or governmental approvals or any other causes beyond Landlord’s or its contractor’s reasonable control (and other than for financial reasons) (collectively, “Force Majeure Delays”).

  • Unavoidable Delays means delays due to any of the following, and only the following, (provided that such delay is beyond Construction Manager’s reasonable control): war, insurrection, civil commotion, strikes, slowdowns, lock outs, riots, flood, earthquakes, fires, casualties, acts of God, acts of a public enemy, acts of terrorism, epidemics, quarantine restrictions, freight embargoes, lack of transportation, governmental moratoriums, unusually severe or abnormal weather conditions, failure of utilities, or a court order which causes a delay (unless resulting from a wrongful act of Construction Manager). In no event shall the application to Construction Manager of any applicable law, regulation, rule or other governmental requirement constitute an Unavoidable Delay. Contractor shall use reasonable good faith efforts to notify Owner not later than five (5) days after Construction Manager knows of the occurrence of an Unavoidable Delay. An extension of time for an Unavoidable Delay shall only be for the period of the Unavoidable Delay, which period shall commence to run from the time of the commencement of the cause of the Unavoidable Delay.

  • Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.

  • Force Majeure Event means an event, or a series of related events, that is outside the reasonable control of the party affected (including failures of the internet or any public telecommunications network, hacker attacks, denial of service attacks, virus or other malicious software attacks or infections, power failures, industrial disputes affecting any third party, changes to the law, disasters, explosions, fires, floods, riots, terrorist attacks and wars);

  • Relevant Force Majeure Event means a Force Majeure Event in relation to which an Affected Party is claiming relief under this Clause 17; and

  • Unavoidable Delay means an event which delays Closing which is a strike, fire, explosion, flood, act of God, civil insurrection, act of war, act of terrorism or pandemic, plus any period of delay directly caused by the event, which are beyond the reasonable control of the Vendor and are not caused or contributed to by the fault of the Vendor. “Unavoidable Delay Period” means the number of days between the Purchaser’s receipt of written notice of the commencement of the Unavoidable Delay, as required by paragraph 5(b), and the date on which the Unavoidable Delay concludes.

  • Landlord Delay shall occur if either: (i) Landlord fails to complete the Base Building and/or other improvements on the Project that are required by the DDA, the Parking REA and/or the CC&Rs, and as a direct result of such failure Tenant is unable to obtain a temporary or permanent certificate of occupancy for the Premises upon substantial completion of the Tenant Improvements; or (ii) substantial completion of the Warm Shell Improvements or Tenant Improvements is delayed directly and solely as a result of any of the following and such delay could not have been mitigated by Tenant using commercially reasonable measures, which delay occurs after the Delivery Date and before the Commencement Date and does not result from Tenant's interference or delay in connection with completion of the Tenant Improvements or after a Tenant Default or Work Letter Draw Event: (a) subject to Paragraph 8 above, unreasonable interference by Landlord or Landlord's Contractor with the construction of the Warm Shell Improvements or the Tenant Improvements; (b) Landlord's failure to comply with any deadlines for response to, or submissions from, Tenant as required by this Work Letter; (c) any material Discretionary Changes to Landlord's Plans or the Warm Shell Plans after their final approval by applicable governmental entities (other than Tenant Modifications) that directly affect Tenant's Plans or the Tenant Improvements; and/or (d) Landlord failure to complete portions of the Base Building and/or other improvements on the Project that are Landlord's obligation to complete hereunder, and as a direct result of such failure Tenant and Tenant's contractors do not have access to the Premises to the extent required to complete the Warm Shell Improvements and/or Tenant Improvements. Tenant shall give Landlord at least five (5) days prior notice if Tenant becomes aware that Landlord is in danger of causing a Landlord Delay, and if Landlord takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Commencement Date shall be made on account of such Landlord; provided, however, that if such delay was not reasonably foreseeable by Tenant, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Tenant becomes aware of such delay or potential delay.

  • Event of Force Majeure means one of the following events:

  • Force Majeure Exception means any failure or delay in the performance of the Issuer's reporting obligation pursuant to Section 2.4 arising out of or caused, directly or indirectly, by circumstances beyond its reasonable control, including, without limitation, acts of God; earthquakes; flood; terrorism; wars and other military disturbances; sabotage; epidemics; riots; loss or malfunctions of utilities, computer (hardware or software) or communication services; accidents; acts of civil or military authority and governmental action. The Issuer shall use commercially reasonable efforts to commence performance of its obligations during any of the foregoing circumstances.

  • Base Building Work means the base building work for the Building as described in this Manual.

  • Force Majeure Report means a report to be given by the Affected Party to the other party following the giving of a Force Majeure Notice;

  • Force Majeure Notice means a notice to be given by the Affected Party to the other party stating that a Force Majeure Event has occurred;

  • Building Work has the meaning given to it in section 6 of the Building and Construction Industry (Improving Productivity) Act 2016 (Cth);

  • Excused Downtime means the number of minutes in the Charging Period, rounded to the nearest minute that the link state of Customer’s Port is ‘down’ due to:

  • Tenant Party means any of the following persons: Tenant; any assignees claiming by, through, or under Tenant; any subtenants claiming by, through, or under Tenant; and any of their respective agents, contractors, employees, licensees, guests and invitees.

  • Excused Outage means any disruption to or unavailability of Services caused by or due to (i) Scheduled Maintenance,

  • Tenant’s Work means all improvements, alterations, fixture, equipment, and signage installation, and furniture placement necessary or appropriate for the conduct of the Permitted Use, including all work described as Tenant’s Work on Exhibit D, attached (the “Work Letter”).

  • Tenant Improvements Defined in Exhibit B, if any.