Practical Completion Date means the date on which Practical Completion occurs as stated in the Practical Completion Certificate;

Practical Completion Date means the date of the certificate of practical completion of the Development issued under the terms of any building contract.

Practical Completion Date means the date on which the Principal Agent issues a certificate certifying that the Works have been substantially completed in accordance with the Unit Floor Plan and the Specifications and Schedule of Finishes, the Property can effectively be used for its intended purpose and a municipal occupancy certificate has been issued in respect thereof;

Examples of Practical Completion Date in a sentence

Available on:http://www.weinstitute.com/paper/p2014-1.pdf Accesed on: June 18th 2017.
Other than with the prior written consent of the LTA, any amount of the Loan which remains undrawn on the earlier of: the date falling three months after the Practical Completion Date; or the Longstop Date, shall immediately be cancelled in full.
The Developer must at its own cost make good to the satisfaction of the Council any loss of or damage to the Works or to the Site resulting from any cause whatsoever until the Practical Completion Date.
The Contractor will maintain the PI Insurance and pay all premiums due under the Insurance for a minimum of 5 years after the Practical Completion Date.
The Applicant shall, no later than six months after the Practical Completion Date, ensure that it has implemented the use of the membership management and the court booking modules of ClubSpark (or such other or replacement membership and booking platform as may be required by LTA in writing (which includes e-mail)), so as to have open, bookable courts and the LTA Rally functionality enabled.

More Definitions of Practical Completion Date

Practical Completion Date means the date upon which Practical Completion occurs and a Certificate of Practical Completion is issued and the council have issued an occupation certificate for the development or respective Purchasers’ Section.

Practical Completion Date means the date on which the Council advises the Developer in writing that the Works have been completed to Councils satisfaction.

Practical Completion Date has the meaning given in clause 24.

Practical Completion Date means the date upon which the principal agent issues the Practical

Practical Completion Date means such date upon which the practical completion certificate has been issued by the Developer confirming that the state of completion where, completion of the Works has been substantially reached and the Dwelling House can be effectively used for residential purposes;

Practical Completion Date means the date on which a portion of the Development is certified as being practically completed by the project manager;

Practical Completion Date means the date certified as such by the architect;