Project Problem definition

Project Problem is defined in Clause 7.1.
Sample 1Sample 2Sample 3
Project Problem means any of the following: the delay to any milestone in the Implementation Schedule, any material failure of either Party to conform to the requirements of the Contract, or any other problem which could have a material adverse effect on the successful completion of the works under the Contract.
Sample 1Sample 2Sample 3
Project Problem shall have the meaning given to such term in Section 10.6(b)(iii).
Sample 1Sample 2

Examples of Project Problem in a sentence

  • If LLC and DBS have not agreed on new prices by 31 October, either of them can initiate the Project Problem procedures.

  • A Project Problem is (i) an alleged failure of a party to perform its obligations, (ii) a disagreement about whether requested work or material is within the scope of the Project, or (iii) any circumstance, whether or not within the control of the parties, which adversely affects performance under this Agreement within the agreed time and budget.

  • If this does not result in a resolution of the Project Problem within two weeks of such referral, any Program Manager can refer the Project Problem to the Escalation Committee (see, Clause 3.7 above); the Escalation Committee cannot impose a resolution of a Project Problem on a party without the party's consent.

  • Prior to commencing arbitration, the parties must exhaust the Project Problem procedures set forth in Section 7.

  • In the event of an actual delay or a delay in complying with the critical path schedule which DBS should reasonably anticipate, DBS must inform LLC in reasonable detail about such problems and the corrective procedures (including the time needed for correction) without undue delay using the Project Problem report procedure.

  • If any Program Manager notifies the others in writing that the Project Problem is urgent, the two week period for referral to the Steering Committee or the Escalation Committee will not apply; i.e., the Project Problem can be referred immediately.

  • A party which receives notice of the Claim under this Clause 11.2.3 can cancel the effect of the notice of termination by paying to the terminating party the excess amount stated by the terminating party in its notice under the first sentence of this Clause 11.2.3 within one week of receiving the notice of termination; such payment does not prejudice the rights of any of the parties under the Project Problem procedures or in arbitration.

  • Compliance with the Project Problem procedure does not waive any substantive rights or remedies under this Agreement.

  • DBS cannot suspend performance, pending resolution of a Project Problem.

  • If the parties resolve a Project Problem without arbitration, the parties will record the resolution in writing.


More Definitions of Project Problem

Project Problem means any error or any other problem or circumstance encountered by Twin or PBS which in Twin's or PBS's judgment might prevent Twin or PBS from meeting a delivery date for a Deliverable or cause any increase in the estimated cost of an Interactive Game Application.
Sample 1
Project Problem shall have the meaning set forth in Section 10.8(b)(i).
Sample 1

Related to Project Problem

  • Project Work means the work required to complete the Project.

  • Project means the goods or Services described in the Signature Document or a Work Order of this Contract.

  • Project Property means the real property on or for which preconstruction service or construction work is or will be provided.

  • The Project Plan means the document to be developed by the Supplier and approved by the Purchaser, pursuant to GCC Clause 19, based on the requirements of the Contract and the Preliminary Project Plan included in the Supplier’s bid. The “Agreed and Finalized Project Plan” is the version of the Project Plan approved by the Purchaser, in accordance with GCC Clause 19.2. Should the Project Plan conflict with the Contract in any way, the relevant provisions of the Contract, including any amendments, shall prevail.

  • Development Project means a project for the development of land within a project area.

  • Project Leader shall have the meaning set forth in Section 3.01(e)(v).

  • Project Plan means the document to be developed by the Contractor and approved by WTL, based on the requirements of the Contract and the Preliminary Project Plan included in the Contractor’s bid. For the sake of clarity, the Agreed and Finalised Project Plan” refers to the version of the Project Plan submitted by the contractor after receiving the letter of Award and the same approved by WTL. The project plan may be changed/ modified during the course of the project. Should the Project Plan conflict with the provisions of the Contract in any way, the relevant provisions of the Contract, including any amendments, shall prevail.

  • Project Engineer means the surveyor or engineer employed by or private

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Project Improvements means site improvements and facilities that are:

  • Disaster recovery project means a project located on property

  • Redevelopment Project Area means an area designated by the municipality, which is not less in the aggregate than 1 1/2 acres and in respect to which the municipality has made a finding that there exist conditions which cause the area to be classified as an industrial park conservation area or a blighted area or a conservation area, or a combination of both blighted areas and conservation areas.

  • Project IPR means all Intellectual Property Rights that arise or are obtained or developed by either party, or by a contractor on behalf of either party, in respect of the Deliverables in the course of or in connection with the Project;

  • Force Majeure Report means a report to be given by the Affected Party to the other party following the giving of a Force Majeure Notice;

  • Project Architect means the professional architect or engineer employed by the Owner as architect or engineer of record for the Project and its consultants.

  • City’s Project Manager means the City’s employee, or his/her delegate, who is authorized in writing to deal with the Consultant on behalf of the City in connection with the Services, or to make decisions in connection with this Agreement;

  • Economic development project means land and existing or planned improvements suitable for use by an industrial or commercial enterprise, or housing development, or the protection of the environment, including, but not limited to, groundwater or surface water. Economic development project includes necessary buildings, improvements, or structures suitable for and intended for or incidental to use as an industrial or commercial enterprise or housing development; and includes industrial park or industrial site improvements and port improvements or housing development incidental to an industrial or commercial enterprise; and includes the machinery, furnishings, and equipment necessary, suitable, intended for, or incidental to a commercial, industrial, or residential use in connection with the buildings or structures.

  • Project Implementation Unit or “PIU” means the unit referred to in Section I.A.1 of Schedule 2 to this Agreement.

  • Development Site means any parcel or lot on which exists or which is intended for building development other than the following:

  • Construction project means the same as that term is defined in Section 38-1a-102.

  • Project Scope means the description or activity of work to be accomplished on the project.

  • Project Area means land or lands located within the incentive

  • Project Implementing Entity means a legal entity (other than the Recipient or the Guarantor): (a) that is responsible for implementing all or a part of the Project; and (b) which is a party to the Project Agreement. If the Bank enters into a Project Agreement with more than one such entity, “Project Implementing Entity” refers separately to each such entity.

  • Projects means the projects identified in Exhibit A to the Agreement and all other projects, any costs of which are included in a Transitional Capital Plan pursuant to the Act or are Recovery Costs, and financed, by payment or reimbursement, with the proceeds of Bonds or Notes.