Required Substantial Completion Date definition

Required Substantial Completion Date means the required date for Substantial Completion of the Project. The Required Substantial Completion Date can be adjusted only by written Change Order.
Sample 1Sample 2Sample 3
Required Substantial Completion Date means the date that is * calendar days from the date of the Full Notice to Proceed, as such date may be adjusted by mutual agreement of the Parties in accordance with this Agreement.
Sample 1Sample 2
Required Substantial Completion Date means the date set forth in the Project Schedule, as such date may be adjusted by mutual agreement of the Parties in accordance with this Agreement.
Sample 1Sample 2Sample 3

Examples of Required Substantial Completion Date in a sentence

  • An equitable adjustment by Agreed Change shall be made for increases in the Contract Sum, Required Substantial Completion Date and Required Final Completion Date on account of any such suspension, delay or interruption.

  • Notwithstanding the preceding or any approvals by Princeton University of any Updated Project Schedules or anything in this Contract to the contrary, any change to the Required Substantial Completion Date or any of the Schedule Milestones shall only be pursuant to a Change Order signed by Princeton University.

  • Updated Project Schedule(s) shall be subject to Princeton University’s written approval, shall not change the previously established Required Substantial Completion Date or any of the Schedule Milestones, and shall not be binding upon Princeton University in any manner unless or until Princeton University has approved such Updated Project Schedule, subject to any qualifications in such approval and all other terms of this Contract.

  • Accordingly, notwithstanding anything in this Clause E5, even if conditions exist which would otherwise be an excusable delay hereunder to Contractor’s performance of the Work, Contractor may only be entitled to seek an extension of the Contract Time (for any Schedule Milestones or the Required Substantial Completion Date) only to the extent that such excusable delay is proven to the satisfaction of Princeton University in its discretion to demonstrably impact the critical path of the Project Schedule.

  • Contractor acknowledges that a delay in any one portion of the Project or in any Work sequence or any other aspect of the Work does not necessarily entitle Contractor to a delay in, or a delay of equal duration in, completion of the entire Project, or a delay that materially and adversely affects the Required Substantial Completion Date.

  • Such agreement shall be effective immediately and shall be an “Agreed Change,” which term, as used herein, shall mean any change in the Work as to which Contractor and Owner have agreed as any changes in the Contract Sum, the Required Substantial Completion Date and the Required Final Completion Date.

  • If no such agreement is reached, Contractor shall give notice to Architect and Owner of its objection to the change, if any, in the Contract Sum, Required Substantial Completion Date and/or Required Final Completion Date proposed in the Change Directive within five (5) business days after receipt of the Change Directive.

  • Required Substantial Completion Date must be set as a “Complete on or Before” constraint in accordance with the dates set forth in the Contract.

  • Notwithstanding anything in the Contract to the contrary, in no event shall the Contractor be entitled to an extension of the dates for any Schedule Milestones or the Required Substantial Completion Date or additional compensation for any delays with respect to non-critical-path activities.

  • Contractor shall be deemed to have achieved the Required Substantial Completion Date only if the criteria set forth in Clause E10 have been met on or before the Required Substantial Completion Date.(c) Throughout the duration of the Project, the Contractor must identify the existence of and/or reasonable opportunities for increasing the float in the Project Schedule.


More Definitions of Required Substantial Completion Date

Required Substantial Completion Date means the date by which Lessor has agreed to cause Substantial Completion of the Lessor Work to occur, which shall be August 1, 2017.
Sample 1Sample 2
Required Substantial Completion Date has the meaning set forth in Section 5.2B.
Sample 1Sample 2
Required Substantial Completion Date means July 15, 2016.
Sample 1
Required Substantial Completion Date means the date required for Substantial Completion of the Project as required under the Construction Contract and shall initially be May 12, 2005.
Sample 1
Required Substantial Completion Date with respect to an Approved Project, shall mean the earliest of (a) the date set forth in the EPC Contract as the “Guaranteed Substantial Completion Date”, if applicable, (b) the date that is ninety (90) days prior to the date on which such Approved Project is required to achieve Substantial Completion pursuant to the applicable Revenue Contract unless, in the reasonable discretion of Lender, Borrower has demonstrated that significant progress has been made on Project construction such that it is reasonably likely that such Approved Project will achieve Substantial Completion by the date required in such Revenue Contract; and (c) the date that is one hundred eighty (180) days after the date set forth for Substantial Completion in the Construction Budget and Schedule for such Approved Project.
Sample 1
Required Substantial Completion Date means the date on which the General Contractor is required to obtain Substantial Completion of the Work as provided in Section 14.1 of the Design/Build Contract.”
Sample 1

Related to Required Substantial Completion Date

  • Substantial Completion Date means the required date for Substantial Completion of the Project. The Substantial Completion Date can be adjusted only by written Change Order.

  • Guaranteed Substantial Completion Date or “Guaranteed Substantial Completion Dates” has the meaning set forth in Section 5.3B.

  • Final Completion Date means the date on which Final Completion occurs.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Construction Completion Date means date of the completion of the Construction Period, which shall be at the expiry of a period of 24 (Twenty Four) months from the Compliance Date or such other date (with the consent of the Authority) by which the overall development of the Project is completed in accordance with the provisions of this Concession Agreement and when the Construction Completion Certificate is issued by Authority as per Article 14.1.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Substantial compliance means a level of compliance with these rules where any deficiencies pose no greater risk to resident health or safety than the potential for causing minor harm.

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Substantial Completion Certificate means the certificate issued and approved by the Authority indicating the date upon which the Trade Contractor Work (or a designated portion thereof) is Substantially Complete.

  • Certificate of Substantial Completion means the certificate executed by the A/E, ODR and Contractor that documents to the best of A/E’s and ODR’s knowledge and understanding, Contractor’s sufficient completion of the work in accordance with the Contract, so as to be operational and fit for the use intended.

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Final Completion Certificate has the meaning set forth in Section 11.6.

  • Outside Completion Date shall have the meaning assigned to such term in Section 6.3(d).

  • Virtual Completion means the premise is in the opinion of the Employer fit for occupation.

  • Improvement completion assurance means a surety bond, letter of credit,

  • Construction Completion Certificate means the certificate issued under ARTICLE 14.

  • Occupancy Date means the date on which occupancy of all Units in a Project is permitted;

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.