Substantial Completion Guaranteed Date definition

Substantial Completion Guaranteed Date means January 1, 2014 as the same may be extended pursuant to Articles XVI, and Sections 8.04, 22.02 and 23.07, provided a Full Notice to Proceed is issued by Owner no later than April 1, 2012.
Sample 1
Substantial Completion Guaranteed Date means the date that is no later than twenty (20) months after the Starting Date of Construction as extended (if applicable) for so long as necessary (i) for the Gas Purchaser to connect the Plant to the grid; (ii) to account for extreme weather conditions during construction and/or due to other Events of Force Majeure; or (iii) to account for or delays due to Principal including Principal’s delay in providing the Plant with Sufficient Substrates. This date coincides with the start of the liquidated damages if the Contractor is late meeting this guaranteed date.
Sample 1
Substantial Completion Guaranteed Date means, with respect to the first Unit, the date of ***, and, with respect to the second Unit, the date of ***, as such dates may be modified in accordance with the terms hereof.
Sample 1

Examples of Substantial Completion Guaranteed Date in a sentence

  • The CPM Schedule shall represent Contractor's best judgment as to how it shall complete the Work in compliance with the Schedule Milestones including the Phase Substantial Completion Guaranteed Dates, the PV Power Plant Substantial Completion Guaranteed Date, and the Final Completion Guaranteed Date.

  • If the Project fails to achieve the Substantial Completion Date on or prior to close of business on the Substantial Completion Guaranteed Date, then Developer shall pay to PacifiCorp liquidated damages for each day until the Project achieves the Substantial Completion Date, in an amount equal to [ ($ )] per day for the first thirty-one (31) days following the Substantial Completion Guaranteed Date and [ (collectively, the “Delay Liquidated Damages”).

  • Contractor shall cause Substantial Completion to occur on or before the Substantial Completion Guaranteed Date (as such dates may be extended pursuant to this Contract, including Articles XXIII, XVII, XXII, Section 25.01, Section 36.01 or any other provision hereof).

  • Subject to Contractor’s obligation to pay Delay Liquidated Damages to the extent set forth herein, Contractor shall have the period (the “Performance Testing Period”) through and including the ninetieth (90th) day following the Substantial Completion Guaranteed Date during which Contractor shall run, and, if necessary, re-run each of the Performance Tests necessary to demonstrate compliance with Performance Guarantees.

  • A student and faculty centered information processing and dissemination can enhance speedy decision making, provide easy access and ensure transparency and accountability of various actions taken.

  • Contractor shall cause Substantial Completion of each Unit to occur on or before the applicable Substantial Completion Guaranteed Date.

  • If Retainage is not released upon Substantial Completion of a Unit due to Contractor being in default under the terms of this Agreement, Owner shall release such fifty percent (50%) Retainage related to the first Unit within ten (10) days after Contractor reasonably demonstrates that such default has been cured; provided that Contractor is on schedule to achieve Substantial Completion by the Substantial Completion Guaranteed Date for the remaining Unit.

  • The frequency of such meetings shall be established and modified, from time to time, by mutual agreement of the Parties; provided, however, such meetings shall occur no less frequently than monthly; provided, further, if the Milestone Summary Schedule indicates that Substantial Completion is scheduled to occur thirty (30) days or more after the Substantial Completion Guaranteed Date, Owner shall be entitled to require that meetings occur as frequently as weekly.

  • Without limiting the foregoing, Contractor shall, subject to the terms and conditions of this Agreement, including Section 15.1, perform the Work so as to achieve Substantial Completion of each Unit by such Unit’s Substantial Completion Guaranteed Date.

  • If an event described in Section 16.1(g) occurs, the Project Schedule (and the Substantial Completion Guaranteed Date referenced therein for Unix 0 xx Unit 2, as applicable) shall be equitably extended as necessary for the repair of such welds and as set forth in a Change In Work Form accepted by Owner; provided that Contractor uses all reasonable efforts to mitigate the duration of any delay in achieving the Substantial Completion Guaranteed Date.


More Definitions of Substantial Completion Guaranteed Date

Substantial Completion Guaranteed Date means the date that is no later than thirteen (13) months after the Starting Date of Construction as extended (if applicable) for so long as necessary (i) for the Power Purchaser to connect the Plant to the grid, so long as delay is not caused by Contractor’s default of its obligations under this Agreement; (ii) to account for extreme weather conditions during construction and/or due to Events of Force Majeure; (iii) to account for or delays due to any actions or omissions of Principal in breach of this Agreement, including Principal’s delay in providing the Plant with Sufficient Substrates; or (iv) as required due to changes to the Workflow Plan agreed to by Principal;
Sample 1
Substantial Completion Guaranteed Date means the Phase 1 Substantial Completion Guaranteed Date, the Phase 2 Substantial Completion Guaranteed Date, the Phase 3 Substantial Completion Guaranteed Date, the Phase 4 Substantial Completion Guaranteed Date, or the PV Power Plant Substantial Completion Guaranteed Date, as applicable.
Sample 1
Substantial Completion Guaranteed Date means the date of August 31, 2009, as such date may be modified in accordance with the terms hereof.
Sample 1
Substantial Completion Guaranteed Date means [___________].
Sample 1

Related to Substantial Completion Guaranteed Date

  • Guaranteed Substantial Completion Date or “Guaranteed Substantial Completion Dates” has the meaning set forth in Section 5.3B.

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Completion Guaranty means the Guaranty of Completion and Payment of even date herewith from Indemnitor for the benefit of Lender, as amended from time to time.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Construction Completion Date means the Completion Date of the Construction as specified in the Statutory Declaration of Completion for the Project;

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Guaranteed Construction Start Date means the Expected Construction Start Date, as such date may be extended by the Development Cure Period.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Substantial Completion Certificate means the certificate issued and approved by the Authority indicating the date upon which the Trade Contractor Work (or a designated portion thereof) is Substantially Complete.

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Final Completion Date means the date on which Final Completion occurs.

  • Landlord’s Work means the work of constructing the Tenant Improvements.

  • CONSTRUCTION GUARANTEE means a guarantee at call obtained by the contractor from an institution approved by the employer in terms of the employer's construction guarantee form as selected in the schedule

  • Subproject means a specific project to be carried out by an existing BE utilizing the proceeds of a Sub-loan or Investment, as hereinafter defined, fulfilling the conditions set forth in Part A of Schedule 4 to this Agreement;

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Guaranteed Commercial Operation Date has the meaning set forth in Section 3.9(c)(i).

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Substantial compliance means a level of compliance with these rules where any deficiencies pose no greater risk to resident health or safety than the potential for causing minor harm.

  • Construction Completion Certificate means a certificate of the I-Bank to the effect that the construction of the Project is complete.

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Phase 1 means the phase of the ATP comprised of: (1) improvements to the State Street Substation; (2) construction of the Proposed Line; (3) the rebuilding of NYSEG’s existing Lines 971 and 000 xxxxx xx Xxxxxxxx Xxxx xx the NYSEG ROW to allow for construction of the Proposed Line as intended; (4) improvements to the Elbridge Substation to accept the Proposed Line; and (5) National Grid’s conveyance to NYSEG of the NYSEG Acquired ROW and such other land interests as contemplated by the Purchase and Sale Agreement.

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Project Commencement Date means the commencement date notified to the Minister pursuant to clause 4(1);