Updated Project Schedule definition

Updated Project Schedule has the meaning set out in Schedule 2 [Design and Construction Protocols];
Sample 1Sample 2Sample 3
Updated Project Schedule means an updated detailed project schedule setting forth the expected schedule for the engineering, procurement and construction of the Renewable Diesel Conversion, showing the projected date for achievement of Conversion Completion for the construction of the Renewable Diesel Conversion, delivered to the Lenders pursuant to Section 4.02(b).
Sample 1
Updated Project Schedule means the most recent instance of the Project Schedule.
Sample 1

Examples of Updated Project Schedule in a sentence

  • Each Updated Project Schedule shall be sequentially numbered and dated for identification, and Contractor shall separately maintain and archive electronically throughout the term of the Contract (e.g., no Updated Project Schedule shall “over-write” the prior version or versions of the Project Schedule or Updated Project Schedule).

  • Updated Project Schedule(s) shall be subject to Princeton University’s written approval, shall not change the previously established Scheduled Completion Date or the Schedule Milestones, and shall not be binding upon Princeton University until Princeton University has approved such Updated Project Schedule.

  • In addition to the Updated Project Schedule, and any other reports required under Clause E1, Contractor shall provide monthly progress reports (in narrative form) that analyze and comment on issues in the Updated Project Schedule.

  • After approval of the proposed Project Schedule, the Contractor shall prepare on a monthly basis, or as Princeton University may require, an Updated Project Schedule that shall document the current schedule status of the Project and incorporate changes based on actual progress and new or more reliable information.

  • Contractor shall post all Primavera files and data associated with the Project Schedule and any revisions thereto to the Princeton University PCS site.CLAUSE E3 PROGRESS AND COMPLETION(a) Time is of the essence for all provisions of the Contract.(b) Contractor shall achieve Schedule Milestone dates and the Substantial Completion Date in accordance with the (Updated) Project Schedule.

  • Updated Project Schedule(s) shall be subject to Princeton University’s written approval, shall not change the previously established Required Substantial Completion Date or any of the Schedule Milestones, and shall not be binding upon Princeton University in any manner unless or until Princeton University has approved such Updated Project Schedule, subject to any qualifications in such approval and all other terms of this Contract.

  • Contractor will submit an electronic Project Schedule file to be posted by Princeton to the cloud-based scheduling environment as Contractor’s Updated Project Schedule for Princeton University review.

  • In addition to the Updated Project Schedule(s), and any other reports required under Clause E1, Contractor shall provide monthly progress reports (in narrative form) that analyze and comment on issues in the Updated Project Schedule.

  • After approval of the proposed Project Schedule, the Contractor shall prepare on a monthly basis, or as Princeton University may require, an Updated Project Schedule that shall document the current schedule status of the Project and incorporate changes based on new or more reliable information.

  • In addition to the Updated Project Schedule, and any other reports required under Section 42, Contractor shall provide monthly progress reports (in narrative form) that analyze and comment on issues in the Updated Project Schedule.

Related to Updated Project Schedule

  • Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.

  • Approved Project Budget means the most recent statement, approved by the FTA, of the costs of the Project, the maximum amount of Federal assistance for which the TJPA is currently eligible, the specific tasks (including specified contingencies) covered, and the estimated cost of each task.

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Approved Project means the Scheme application of the Applicant approved by the CIC.

  • Project Budget means the budget and project description included in the grant application. The Project Budget must succinctly describe all major elements of project work, the estimated cost of each and clearly allocate requested grant funding and match contributions to each.

  • Estimated Project Cost means Benchmark cost of MNRE which is Rs 8.00 Crore/MWp as per MNRE letter no. 03/20/2014-15/GCRT/11.12.14 at the time of Bid Due date.

  • Development Schedule shall have the meaning set forth in Section 1.1.

  • Construction Budget means the cost of acquisition, installation, testing, constructing and developing any Property as determined by the Construction Agent in its reasonable, good faith judgment.

  • Project area budget means a multiyear projection of annual or cumulative

  • BASE budget means the minimum general fund budget of a district, which includes 80% of the basic

  • The Project Plan means the document to be developed by the Supplier and approved by the Purchaser, pursuant to GCC Clause 19, based on the requirements of the Contract and the Preliminary Project Plan included in the Supplier’s bid. The “Agreed and Finalized Project Plan” is the version of the Project Plan approved by the Purchaser, in accordance with GCC Clause 19.2. Should the Project Plan conflict with the Contract in any way, the relevant provisions of the Contract, including any amendments, shall prevail.

  • Milestone Schedule means Seller’s milestone schedule, the form of which is attached to this Agreement as Exhibit Q.

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Baseline Schedule means the initial time schedule prepared by Contractor for Owner’s information and acceptance that conveys Contractor’s and Subcontractors’ activities (including coordination and review activities required in the Contract Documents to be performed by A/E and ODR), durations, and sequence of work related to the entire Project to the extent required by the Contract Documents. The schedule clearly demonstrates the critical path of activities, durations and necessary predecessor conditions that drive the end date of the schedule. The Baseline Schedule shall not exceed the time limit current under the Contract Documents.

  • Construction Schedule means a construction schedule indicating the planned start and completion dates of the major activities of the Work as set out in Appendix [ ], a future Appendix;

  • Project Plan means the document to be developed by the Contractor and approved by WTL, based on the requirements of the Contract and the Preliminary Project Plan included in the Contractor’s bid. For the sake of clarity, the Agreed and Finalized Project Plan” refers to the version of the Project Plan submitted by the contractor after receiving the letter of Award and the same approved by WTL. The project plan may be changed/ modified during the course of the project. Should the Project Plan conflict with the provisions of the Contract in any way, the relevant provisions of the Contract, including any amendments, shall prevail.

  • Work Schedule means the approved order and timeline for how the requirements of this contract, including Work on individual Units or groups of Units, will be fulfilled by the Contractor.

  • Project Scope means the description or activity of work to be accomplished on the Project.

  • Completion Schedule means the fulfilment of the Related Services by the Supplier in accordance with the terms and conditions set forth in the Contract;

  • Product Schedule means a product schedule documenting the specific terms and conditions applying to a Product as may be amended, updated or replaced from time to time (and includes any Electronic Platform Schedules);

  • Project Plans mean the plans for the Project that are attached to this Agreement as Exhibit “B.”

  • Development Budget means the cost categories listed on Pages 8 - 11 in Form 3 that are directly related to the proposed Project as submitted in the Application. Indirect or off-site costs not directly related to the development of the project are not valid or eligible costs.

  • The Contract Price/Project Cost means the price payable to the Vendor under the Contract for the full and proper performance of its contractual obligations.

  • The Contract Price/ Project Cost means the price payable to the Vendor under the Contract for the full and proper performance of its contractual obligations.

  • Qualified Project Costs means Project Costs that meet each of the following requirements: (i) the costs are properly chargeable to capital account (or would be so chargeable with a proper election by the Borrower or but for a proper election by the Borrower to deduct such costs) in accordance with general Federal income tax principles and in accordance with United States Treasury Regulations §1.103-8(a)(1), provided, however, that only such portion of interest accrued during rehabilitation of the Projects shall be eligible to be a Qualified Project Cost as is so capitalizable and as bears the same ratio to all such interest as the Qualified Project Costs bear to all Project Costs; and provided further that interest accruing after the date of completion of the rehabilitation of the Projects shall not be a Qualified Project Cost; and provided still further that if any portion of any of the Projects is being rehabilitated by an Affiliated Party (whether as a general contractor or a subcontractor), Qualified Project Costs shall include only (A) the actual out-of-pocket costs incurred by such Affiliated Party in rehabilitating the Projects (or any portion thereof), (B) any reasonable fees for supervisory services actually rendered by the Affiliated Party, and (C) any overhead expenses incurred by the Affiliated Party which are directly attributable to the work performed on the Projects, and shall not include, for example, intercompany profits resulting from members of an affiliated group (within the meaning of Section 1504 of the Code) participating in the rehabilitation of the Projects or payments received by such Affiliated Party due to early completion of the rehabilitation of the Projects; (ii) the costs are paid with respect to a qualified residential rental project or projects within the meaning of Section 142(d) of the Code, (iii) the costs are paid after the earlier of 60 days prior to the Inducement Date or the Closing Date, and (iv) if the Project Costs were previously paid and are to be reimbursed with proceeds of the Loan or the Bonds, such costs were (A) costs of issuance of the Issuer Note, (B) preliminary capital expenditures (within the meaning of United States Treasury Regulations §1.139-2(f)(2)) with respect to the Projects (such as architectural, engineering and soil testing services) incurred before commencement of the rehabilitation of the Projects that do not exceed twenty percent (20%) of the issue price of the Bonds (as defined in United States Treasury Regulations §1.148-1), or (C) were capital expenditures with respect to the Projects that are reimbursed no later than eighteen

  • Original Project Cost means the capital expenditure incurred by the Generating Company or the Transmission Licensee, as the case may be, within the original scope of the project up to the cut-off date as admitted by the Commission;