Term Termination and Survival 9.1 This Agreement shall commence as of the Effective Date and shall continue thereafter until the completion of the Services under all Statements of Work unless sooner terminated pursuant to Section 9.2 or Section 9.3.
9.2 Either Party may terminate this Agreement, effective upon written notice to the other Party (the “Defaulting Party”) if the Defaulting Party:
(a) Materially breaches this Agreement, and such breach is incapable of cure, or with respect to a material breach capable of cure, the Defaulting Party does not cure such breach within 30 days after receipt of written notice of such breach.
(b) Becomes insolvent or admits its inability to pay its debts generally as they become due.
(c) Becomes subject, voluntarily or involuntarily, to any proceeding under any domestic or foreign bankruptcy or insolvency law, which is not fully stayed within seven business days or is not dismissed or vacated within 45 business days after filing.
(d) Is dissolved or liquidated or takes any corporate action for such purpose.
(e) Makes a general assignment for the benefit of creditors.
(f) Has a receiver, trustee, custodian, or similar agent appointed by order of any court of competent jurisdiction to take charge of or sell any material portion of its property or business.
9.3 Notwithstanding anything to the contrary in Section 9.2(a), TAI may terminate this Agreement upon written notice to XXX upon the occurrence of any of the following events (each of the following, a “Specified Event of Default”):
(a) XXX fails to pay any undisputed amount when due hereunder and such failure continues for 30 days after XXX’s receipt of written notice of nonpayment;
(b) XXX fails to timely achieve, complete, or pass any of the XXX Caravan STC Milestone Requirements by the applicable XXX Completion Date (subject to the applicable cure period) as set forth in Exhibit A as determined in the good faith discretion of TAI; provided that, the applicable XXX Completion Dates shall be equitably adjusted to the extent XXX is not able to achieve, complete or pass any XXX Caravan STC Milestone Requirement or such XXX Caravan STC Milestone Requirement is not otherwise met, in each case as a result of (a) the material breach of TAI of its obligations hereunder or (b) the occurrence of a Force Majeure Event, with an extension to the corresponding XXX Completion Date commensurate with the delay caused by such TAI breach or Force Majeure Event, provided, however, that no extension related to a Force Majeure Event shall be longer than 45 days;
(c) the occurrence of a “Change of Control”, which means (i) the acquisition by any Person of ownership or power to vote more than 49% of the voting stock of XXX by means of any transaction or series of related transactions (including any reorganization, merger or consolidation, but excluding any business combination with a SPAC by XXX or its Affiliate completed prior to the one (1) year anniversary of the date hereof), (ii) the acquisition of ownership or power to vote more than 10% of the voting stock of XXX by a TAI competitor, (iii) a sale of all or substantially all of the assets of XXX, (iv) a material change of XXX’s senior leadership occurring prior to the five (5) year anniversary of the date hereof, in each case of the foregoing clauses (i) – (iv), directly or indirectly, including as to any successor of XXX;
Term, Termination and Suspension 18.1 This Agreement shall be effective from the Effective Date for the Term. The Service shall commence on the Commencement Date and continue until the Completion Date, whereupon this Agreement shall expire unless terminated earlier in accordance with its terms.
18.2 You shall not commence any additional service in the event of notification of termination of this Agreement, however, in the event that service is provided to us beyond the Completion Date, the terms and conditions of this Agreement shall continue on a day-to-day basis terminable without cause upon twenty-four (24) hours prior written notice by either party to the other.
18.3 Either party may terminate a Service or this Agreement, in part or in whole, during the Term upon prior written notice without cause in accordance with the termination notice period as set out in Schedule 1.
18.4 We may terminate this Agreement at any time based upon your default of your obligations under this Agreement. We, in our sole discretion, may provide you with a notice to cure (“Cure Notice”) the breach that would otherwise amount to a basis to terminate this Agreement as a result of your failure to fulfill your obligations hereunder. You shall respond to any such Cure Notice within a reasonable time or within such time as provided therein, and you shall either cure the specified breach or provide assurances to cure the same which we, in our sole discretion, deem adequate.
18.5 Either party may terminate this Agreement immediately, if the other party:
(a) commits an irremediable breach; or
(b) is subject to a change of control or chooses to discontinue its business; or
(c) if the other party has a lack of funding or becomes or is deemed insolvent; or
(d) if the other party’s performance is affected by a force majeure event which lasts seven (7) days or more.
18.6 In the event of termination of this Agreement, all Fees then due and payable shall be paid to you.
18.7 Upon expiry or termination of this Agreement, you shall return all Government property or information or you shall irretrievably delete, as commercially practicable as possible, all Confidential Information, stored in any way using any device or application and all matter derived from such sources which is in your possession, custody or power and provide a signed statement that you have fully complied with your obligations under this section, save for any back-up required by law or as required in accordance with your record retention policy.
18.8 Upon expiry or termination of this Agreement, you shall provide us with all such assistance as may be reasonably necessary in order to end the relationship in a manner which causes the least inconvenience to us including assisting with the transfer of Data.
18.9 We may temporarily suspend a Service hereunder and shall confirm such instruction in writing to you.
18.10 Upon any such suspension, we shall pay all Fees and Expenses up until the time of such suspension of a Service. If, following suspension of a Service, there is no resumption within six (6) months, this Agreement may be terminated by you, and us shall make a payment of all outstanding Fees and Expenses in accordance with this Agreement if such amounts are due.
18.11 We may issue a written order to resume the provision of the Service within six (6) months of suspension in accordance with the terms and conditions of this Agreement.
18.12 The rights arising under this termination section represent your sole remedy and excludes common law rights to terminate and claim damages for any Loss you may suffer under this Agreement.
Termination and Substitution of Servicing Agreements Upon the occurrence of any event for which a Servicer may be terminated pursuant to its Servicing Agreement, the Master Servicer shall promptly deliver to the Seller and the Trustee an Officer's Certificate certifying that an event has occurred which may justify termination of such Servicing Agreement, describing the circumstances surrounding such event and recommending what action should be taken by the Trustee with respect to such Servicer. If the Master Servicer recommends that such Servicing Agreement be terminated, the Master Servicer's certification must state that the breach is material and not merely technical in nature. Upon written direction of the Master Servicer, based upon such certification, the Trustee shall promptly terminate such Servicing Agreement. Notwithstanding the foregoing, in the event that (i) WFHM fails to make any advance, as a consequence of which the Trustee is obligated to make an advance pursuant to Section 3.03 and (ii) the Trustee provides WFHM written notice of the failure to make such advance and such failure shall continue unremedied for a period of 15 days after receipt of such notice, the Trustee shall terminate the WFHM Servicing Agreement without the recommendation of the Master Servicer. The Master Servicer shall indemnify the Trustee and hold it harmless from and against any and all claims, liabilities, costs and expenses (including, without limitation, reasonable attorneys' fees) arising out of, or assessed against the Trustee in connection with termination of such Servicing Agreement at the direction of the Master Servicer. If the Trustee terminates such Servicing Agreement, the Trustee may enter into a substitute Servicing Agreement with the Master Servicer or, at the Master Servicer's nomination, with another mortgage loan service company acceptable to the Trustee, the Master Servicer and each Rating Agency under which the Master Servicer or such substitute servicer, as the case may be, shall assume, satisfy, perform and carry out all liabilities, duties, responsibilities and obligations that are to be, or otherwise were to have been, satisfied, performed and carried out by such Servicer under such terminated Servicing Agreement. Until such time as the Trustee enters into a substitute servicing agreement with respect to the Mortgage Loans previously serviced by such Servicer, the Master Servicer shall assume, satisfy, perform and carry out all obligations which otherwise were to have been satisfied, performed and carried out by such Servicer under its terminated Servicing Agreement. However, in no event shall the Master Servicer be deemed to have assumed the obligations of a Servicer to advance payments of principal and interest on a delinquent Mortgage Loan in excess of the Master Servicer's independent Periodic Advance obligation under Section 3.03 of this Agreement. As compensation for the Master Servicer of any servicing obligations fulfilled or assumed by the Master Servicer, the Master Servicer shall be entitled to any servicing compensation to which a Servicer would have been entitled if the Servicing Agreement with such Servicer had not been terminated.
Termination and Suspension Customer is entitled to suspend the performance of its obligations in whole or in part or terminate the Agreement with immediate effect, without prejudice to its right to claim damages and without any compensation to or indemnification of Supplier (i) in case Supplier has been declared bankrupt, is in a state of liquidation, has ceased or suspended whole or a substantial part of its business, is subject of a court order or preventative legal scheme of settlement, (ii) in case of non- compliance with the Compliance Requirements or the provisions of safety, health, environment and security or (iii) in case of not approved changes pursuant to article 10. After such termination Customer may return received Goods and/or Services in whole or partly against repayment and retransfer of ownership therein to Supplier.
Termination and Survival (a) This Agreement shall become effective as of the date of this Agreement.
(b) This Agreement may be terminated, without the payment of any penalty, by the Fund or the Adviser at any time, with or without notice.
(c) This Agreement shall automatically terminate in the event of (i) the termination by the Fund of the Investment Advisory Agreement; (ii) the board of trustees of the Fund makes a determination to dissolve or liquidate the Fund; or (iii) upon a quotation or listing of the Fund’s securities on a national securities exchange (including through an initial public offering) or a sale of all or substantially all of the Fund’s assets to, or a merger or other liquidity transaction with, an entity in which the Fund’s shareholders receive shares of a publicly-traded company which continues to be managed by the Adviser or an affiliate thereof.
(d) Sections 3 and 4 of this Agreement shall survive any termination of this Agreement. Notwithstanding anything to the contrary, Section 2 of this Agreement shall survive any termination of this Agreement with respect to any Expense Payments that have not been reimbursed by the Fund to the Adviser.
Effective Date; Termination; Cancellation and Suspension Section 4.01. This Agreement shall come into force and effect on the date upon which the Development Credit Agreement becomes effective.
Section 4.02. (a) This Agreement and all obligations of the Association and of Republika Srpska thereunder shall terminate on the earlier of the following two dates:
(i) the date on which the Development Credit Agreement shall terminate; or
(ii) a date twenty (20) years after the date of this Agreement.
Termination and Abandonment This Agreement may be terminated and the Merger and the other Transactions may be abandoned at any time prior to the Effective Time, notwithstanding any requisite approval and adoption of this Agreement and the transactions contemplated hereby by the stockholders of the Company:
(a) By mutual written consent duly authorized by the Boards of Directors of Parent, Merger Sub and the Company prior to Merger Sub's Election Date; or
(b) By Parent or the Company if (i) the Minimum Condition has not been satisfied during a ten (10) business day extension of the Offer following the Initial Expiration Date, but all other conditions have been satisfied or (ii) any court of competent jurisdiction in the United States or other governmental authority shall have issued an order, decree, ruling or taken any other action restraining, enjoining or otherwise prohibiting the acceptance for payment of, or payment for, shares of Company Common Stock pursuant to the Offer or the Merger and such order, decree, ruling or other action shall have become final and nonappealable; or
(c) By Parent, if due to an occurrence or circumstance that results in a failure to satisfy any condition set forth in Annex A, Merger Sub shall have (A) failed to commence the Offer within 10 days following the date of this Agreement or (B) terminated the Offer without having accepted any Shares for payment thereunder, unless any such failure listed above shall have been caused by or resulted from the failure of Parent or Merger Sub to perform in any material respect any material covenant or agreement of either of them contained in this Agreement or the material breach by Parent or Merger Sub of any material representation or warranty of either of them contained in this Agreement; or
(d) By the Company, upon approval of the Board, if (i) Merger Sub shall have (A) failed to commence the Offer within 10 days following the date of this Agreement or (B) terminated the Offer without having accepted any Shares for payment thereunder, unless such failure to pay for Shares shall have been caused by or resulted from the failure of the Company to satisfy the conditions set forth in paragraphs (f) or (g) of Annex A, (ii) prior to the purchase of Shares pursuant to the Offer, the Board shall have withdrawn or modified in a manner adverse to Merger Sub or Parent its approval or recommendation of the Offer, this Agreement or the Merger in order to approve a Superior Proposal; provided, however, that such termination under this clause (ii) shall not be effective until the Company has made payment to Parent of the Termination Fee (as hereinafter defined) required to be paid pursuant to Section 8.2(a) and has deposited with a mutually acceptable escrow agent $2 million for reimbursement to Parent and Merger Sub of Expenses (as hereinafter defined) or (iii) Parent or Merger Sub shall have breached in any material respect any of their respective representations, warranties, covenants or other agreements contained in this Agreement, which failure to perform is incapable of being cured or has not been cured within 20 days after the giving of written notice to Parent or Merger Sub, as applicable, except, in any case, such failures which are not reasonably likely to affect adversely Parent's or Merger Sub's ability to complete the Offer or the Merger. The party desiring to terminate this Agreement pursuant to this Section 8.1 (other than pursuant to Section 8.1(a)) shall give notice of such termination to the other party.
Termination Resignation and Successions 7.1 Final Termination. Unless terminated at an earlier date by mutual agreement of the parties hereto, this Agreement shall terminate upon the first to occur of the following: (a) the last Serviced Appointment is terminated, matured or expired under the terms of the applicable Serviced Corporate Trust Contract and all Trust Assets in respect thereof have been fully distributed, (b) the last Serviced Appointment is Transferred to the applicable Purchaser,
Dissolution and Termination of the Company 20 Section 12.1. Dissolution.................................................20 Section 12.2. Liquidation.................................................20 Section 12.3. Time for Liquidation, etc...................................21 Section 12.4. Claims of the Members.......................................21
CONDITIONS OF SETTLEMENT, EFFECT OF DISAPPROVAL, CANCELLATION OR TERMINATION 9.1. The Effective Date of this Settlement Agreement shall not occur unless and until each and every one of the following events occurs:
(a) This Agreement has been signed by the Parties and Class Counsel, and the individual settlement agreements with Xxxxxxxxx Xxxxx, the heirs of Xxxxx Xxxxx, Xxxxxx Xxxxxxxxx, and Xxxxxx Xxxxxxxx-Xxx have been fully executed;
(b) The Court has entered an order granting Preliminary Approval of the Agreement;
(c) The Court has entered a Final Approval Order finally approving the Agreement, or a judgment substantially consistent with this Settlement Agreement that has become final and unappealable, following Notice and a Final Approval Hearing, as provided in the Federal Rules of Civil Procedure; and
(d) In the event that the Court enters an approval order and final judgment in a form other than that provided above (“Alternative Approval Order”) to which the Parties have consented, that Alternative Approval Order has become final and unappealable.
9.2. If some or all of the conditions specified in Paragraph 9.1 are not met, or in the event that this Settlement Agreement is not approved by the Court, or the settlement set forth in this Agreement is terminated or fails to become effective in accordance with its terms, then this Settlement Agreement shall be canceled and terminated subject to Paragraph 9.3, unless Class Counsel and Defendant’s Counsel mutually agree in writing to proceed with this Agreement. If any Party is in material breach of the terms hereof, any other Party, provided that it is in substantial compliance with the terms of this Agreement, may terminate this Agreement on notice to all other Parties. Notwithstanding anything herein, the Parties agree that the Court’s decision as to the amount of the Illinois Fee Award and Ohio Fee Award to Class Counsel set forth above or the incentive award to the Class Representatives, regardless of the amounts awarded, shall not prevent the Agreement from becoming effective, nor shall it be grounds for termination of the Agreement.
9.3. If this Agreement is terminated or fails to become effective for the reasons set forth in Paragraphs 6.1, 6.2, 9.1, or 9.2 above, the Parties shall be restored to their respective positions in the Action as of the date of the signing of this Agreement. In such event, any Final Approval Order or other order entered by the Court in accordance with the terms of this Agreement shall be treated as vacated, nunc pro tunc, and the Parties shall be returned to the status quo ante with respect to the Actions as if this Agreement had never been entered into, including Defendant’s right to seek to compel arbitration as to the Plaintiffs named in the Second Amended Complaint.
9.4. In the event the Settlement is terminated or fails to become effective for any reason, the Illinois Settlement Fund and Ohio Settlement Fund, together with any earnings thereon at the same rate as earned, less any taxes paid or due, less Settlement Administrative Expenses actually incurred and paid or payable from the Settlement Fund, shall be returned to Defendant or its Insurer within thirty (30) calendar days after written notification of such event in accordance with instructions provided by Defendant’s Counsel to the Settlement Administrator.
