Adjustment of Contract Time Sample Clauses

Adjustment of Contract Time. 6.6.1. Excusable, Non compensable Delays
Sample 1Sample 2
AutoNDA by SimpleDocs
Adjustment of Contract Time. If Substantial Completion is delayed, adjustment, if any, to the Contract Time on account of such delay shall be in accordance with this Article
Sample 1
Adjustment of Contract Time. The Commission, at its own discretion, will have the authority to revise the Contract Time, the Required Completion Date, and the Milestone Completion Dates. Such change may be for additional work or extra work. The Contractor will be notified in writing and the resulting schedule adjustment will be effected via Change Order, when approved. Notify the Commission in writing within 2 working days if delayed, hindered, disrupted, or otherwise interfered with in the performance of the work for reasons demonstrably beyond the Contractor's own control. Such a delay, disruption, hindrance, or other interferences will be referred to in this section as an Event. For all such events, including those of a continuing or extended duration, continue with all required maintenance and updating of the project schedule, in full accordance with this Contract. If an Event affects neither the Required Completion Date, the Milestone Completion Dates, nor the work of other Contractors, then incorporate schedule revisions acceptable to the Commission into the next schedule update and proceed in accordance with the revised and updated schedule. If, however, the Event affects the Contract Time, the Required Completion Date, the Milestone Completion Dates, or the work of the other Contractors, as determined by the Commission, then an extension of time may be due. In order to allow the Commission, in its sole discretion, to determine whether or not a time extension is appropriate, demonstrate in a written request for extension, submitted no later than 30 days after the written notification of delay, but prior to the expiration of Contract Time as currently in effect, each of the following:
Sample 1
Adjustment of Contract Time. .1 The Milestone Completion Date(s) and Contract Completion date will not be changed because of Force Account Work unless Design-Builder demonstrates that such Work actually affected the Contract Time(s).
Sample 1
Adjustment of Contract Time. § 8.3.1 The Contract Time shall be subject to adjustment only in strict conformity with applicable provisions of the Contract Documents. Failure of Design-Builder to request adjustment(s) of the Contract Time in strict conformity with applicable provisions of the Contract Documents shall be deemed Design-Builder’s waiver of the same.
Sample 1
Adjustment of Contract Time. 7.4.4.1 Procedure for Adjustment of Contract Time.
Sample 1

Related to Adjustment of Contract Time

  • Adjustment of Contract Notwithstanding any other provisions of this contract, STATE may, pursuant to Oregon law, make adjustments in the contract when major catastrophes or significant changes in state or federal law after the date of this contract materially affect the volume and value of timber, or project work to be done, as specified in the section titled, "Project Work," under the contract. Major catastrophes or events beyond the reasonable control of the parties are defined as windstorms, floods, fire, or other acts of God, or significant changes in state or federal law, which are beyond the control of PURCHASER and in no way connected with negligent acts or omissions of PURCHASER, its officers, employees, agents, or subcontractors. Market conditions shall not be considered a reason for contract adjustments. Such adjustments may be made to place the parties in their original status under the contract insofar as possible; provided, however, that any loss or cost to PURCHASER is in no way recoverable from third parties by PURCHASER and that PURCHASER make written application to STATE within 30 days after discovery of the damage done by the catastrophe. If, prior to acceptance of project work, a catastrophe (as defined above) caused by a single event results in additional project work for PURCHASER involving an additional estimated cost of more than: (1) $500 for sales less than one-half million board feet; (2) $1,000 for sales of one-half million to three million board feet; or

  • Contract Time The period of time established for completion of the Project by the Contract Documents. Contract Time commences upon the date specified in the Proceed Order and ends upon the Material Completion and Occupancy Date, as it may be amended.

  • Adjustment Plan (A) If the Employer introduces or intends to introduce a measure, policy, practice or change that affects the terms, conditions or security of employment of a significant number of employees by classification to whom the Collective Agreement applies;

  • Adjustment of Grievance The School District and the teacher shall attempt to adjust all grievances which may arise during the course of employment of any teacher within the School District in the following manner:

  • Adjustment of the Contract Sum shall include profit. No adjustment shall be made to the extent:

  • Recovery of Schedule Delays During Last Sixty Days of Contract Time At any time during the last sixty days of the Contract Time that the Design Professional finds that the Contractor is behind schedule per the Contract Time, as amended, the Design Professional shall notify the Contractor in writing. Within seven days of the date of the Design Professional's notice, the Contractor shall prepare and deliver to the Design Professional and Owner a written plan explaining how the Contractor intends to bring the Project back on schedule. The Contractor's plan must provide sufficient detail to allow the Design Professional and Owner to determine the proposal's feasibility.

  • Contract Term Adjustment “Contract Term Adjustment” means adjustment only as provided for in the three circumstances described in this Subsection. Under these circumstances, the contract term shall be adjusted in writing to include additional calendar days in one or more Normal Operating Seasons equal to the actual time lost, except as limited by paragraph (b) in this Subsection. To qualify for such adjustment, Purchaser shall give written notice of the lost time not later than 30 days after end of Normal Operating Season in which time was lost and at least 10 days before Termination Date. Contracting Officer shall make prompt written acknowledgment of such notice, indicating concurrence with the number of days in the notice or the number of days Forest Service considers as qualifying for the adjustment. Lost portions of days shall be disregarded in computing time lost. The three circumstances qualifying for a Contract Term Adjustment are:

  • Price Adjustments for OGS Centralized Contracts Periodic price adjustments will occur no more than twice per year on a schedule to be established solely by OGS. Pricing offered shall be fixed for the first twelve (12) months of the Contract term. Such price increases will only apply to the OGS Centralized Contracts and shall not be applied retroactively to Authorized User Agreements or any Mini-bids already submitted to an Authorized User. Price Decreases Price decreases may be made at any time. Additionally, some price decreases shall be calculated in accordance with Appendix B, section 17, Pricing.

  • Workforce Adjustment (a) The Parties recognize that workforce adjustment may be necessary due to the elimination of positions resulting from a reduction in the amount of work required to be done by the Commission, reorganization or program termination.

  • Wage Adjustment Notwithstanding any provision in this Agreement on the contrary, the wages of employees shall be reduced by the amount of employee contributions made by the employer pursuant to the provisions hereof.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!