Alteration of Delivery Date Sample Clauses

Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the award may include any postponement of the Delivery Date which the Arbitration Board may deem appropriate. (End of Article)
AutoNDA by SimpleDocs
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the award may include any postponement of the DELIVERY DATE which the Arbitrator or the Arbitration Board may deem appropriate. To the maximum extent possible and provided the arbitration proceedings or the subject matter of the dispute do not affect the construction of the VESSEL, work under this CONTRACT shall continue during the arbitration of any dispute.
Alteration of Delivery Date. In the event that any dispute or difference is referred either to arbitration or to an expert, the arbitration tribunal or expert, as the case may be, shall, where the dispute requires, include a finding as to whether or not the Delivery Date of the VESSEL should, as a result of such dispute, be in any way altered thereby.
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the SELLER shall not be entitled to extend the Delivery Date as defined in ARTICLE VII hereof and the BUYER shall not be entitled to postpone its acceptance of the VESSEL on the Delivery Date or on such newly planned time of delivery of the VESSEL as declared by the SELLER. However, if the construction of the VESSEL is affected by any arbitration or court proceeding, the SELLER shall then be permitted to extend the Delivery Date as defined in ARTICLE VII and the decision or the award shall include a finding as to what extent the SELLER shall be permitted to extend the Delivery Date. (end of Article)
Alteration of Delivery Date. In the event of arbitration of any dispute arising from any matters occurring prior to delivery of the VESSEL EQUIPMENT, all delays in delivery of the VESSEL EQUIPMENT due to such arbitration shall be deemed to be permissible delays and the delivery date shall be automatically postponed and/or extended for the period of time occupied by such arbitration commencing with the notice to arbitrate and concluding with the publication of the award.
Alteration of Delivery Date. In the event of arbitration of any dispute arising or occurring prior to delivery of the VESSEL, an award of the arbitrators shall include a finding as to whether or not the delivery date of the VESSEL is in any way altered thereby.
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the SELLER shall not be entitled to extend the Delivery Date as defined in Article VII hereof and the BUYER shall not be entitled to postpone its acceptance of the VESSEL on the Delivery Date or on such newly planned time of delivery of the VESSEL as declared by the SELLER. However, if the construction of the VESSEL is affected by any arbitration, the SELLER shall then be permitted to extend the Delivery Date as defined in Article VII and the decision or the award shall include a finding as to what extent the SELLER shall be permitted to extend the Delivery Date. Shipbuilding Contract Hull No.H1596
AutoNDA by SimpleDocs

Related to Alteration of Delivery Date

  • Delivery Date the date (or period) for delivery of the Goods or Services as specified and agreed in the Contract.

  • DATE OF DELIVERY OF PUT NOTICE A Put Notice shall be deemed delivered on (i) the Trading Day it is received by facsimile or otherwise by Investor if such notice is received on or prior to 12:00 noon New York time, or (ii) the immediately succeeding Trading Day if it is received by facsimile or otherwise after 12:00 noon New York time on a Trading Day or at anytime on a day which is not a Trading Day.

  • Delivery Dates If the due date of any notice, certificate or report required to be delivered by the Manager hereunder falls on a day that is not a Business Day, the due date for such notice, certificate or report shall be automatically extended to the next succeeding day that is a Business Day.

  • Date of Delivery of Advance Notice An Advance Notice shall be deemed delivered on (i) the Trading Day it is received by facsimile or otherwise by the Investor if such notice is received prior to 12:00 noon Eastern Time, or (ii) the immediately succeeding Trading Day if it is received by facsimile or otherwise after 12:00 noon Eastern Time on a Trading Day or at any time on a day which is not a Trading Day. No Advance Notice may be deemed delivered on a day that is not a Trading Day.

  • Effectiveness and Events Requiring Notice to the Representative The Company will use its best efforts to cause the Registration Statement to remain effective and will notify the Representative immediately and confirm the notice in writing: (i) of the effectiveness of the Registration Statement and any amendment thereto; (ii) of the issuance by the Commission of any stop order suspending the effectiveness of the Registration Statement or any post-effective amendment thereto or preventing or suspending the use of any Preliminary Prospectus or the Prospectus or of the initiation, or the threatening, of any proceeding for that purpose; (iii) of the issuance by any foreign or state securities commission of any proceedings for the suspension of the qualification of the Public Securities for offering or sale in any jurisdiction or of the initiation, or the threatening, of any proceeding for that purpose; (iv) of the mailing and delivery to the Commission for filing of any amendment or supplement to the Registration Statement or Prospectus; (v) of the receipt of any comments or request for any additional information from the Commission; and (vi) of the happening of any event that, in the reasonable judgment of the Company, makes any statement of a material fact made in the Registration Statement or the Prospectus untrue or that requires the making of any changes in the Registration Statement or the Prospectus in order to make the statements therein, and in light of the circumstances under which they were made, not misleading. If the Commission or any foreign or state securities commission shall enter a stop order or suspend such qualification at any time, the Company will make every reasonable effort to obtain promptly the lifting of such order.

  • Effectiveness and Events Requiring Notice to the Representatives The Company will use its best efforts to cause the Registration Statement to remain effective and will notify the Representatives immediately and confirm the notice in writing: (i) of the effectiveness of the Registration Statement and any amendment thereto; (ii) of the issuance by the Commission of any stop order suspending the effectiveness of the Registration Statement or any post-effective amendment thereto or preventing or suspending the use of any Preliminary Prospectus or the Prospectus or of the initiation, or the threatening, of any proceeding for that purpose; (iii) of the issuance by any foreign or state securities commission of any proceedings for the suspension of the qualification of the Public Securities for offering or sale in any jurisdiction or of the initiation, or the threatening, of any proceeding for that purpose; (iv) of the mailing and delivery to the Commission for filing of any amendment or supplement to the Registration Statement or Prospectus; (v) of the receipt of any comments or request for any additional information from the Commission; and (vi) of the happening of any event that, in the reasonable judgment of the Company, makes any statement of a material fact made in the Registration Statement or the Prospectus untrue or that requires the making of any changes in the Registration Statement or the Prospectus in order to make the statements therein, and in light of the circumstances under which they were made, not misleading. If the Commission or any foreign or state securities commission shall enter a stop order or suspend such qualification at any time, the Company will make every reasonable effort to obtain promptly the lifting of such order.

  • Date of Delivery Any notice so addressed shall be deemed to be given or received (i) if delivered by hand, on the date of such delivery, (ii) if mailed by courier or by overnight mail, on the first business day following the date of such mailing, and (iii) if mailed by registered or certified mail, on the third business day after the date of such mailing.

  • Terms of Delivery The Terms of Delivery are contained in the General Conditions of Contract (GCC) and Special Conditions of Contract.

  • Description of Deliverables The Contractor shall Perform as set forth in Exhibit A.

  • Delivery of Documents; Delivery Dates (a) The Trustee is hereby directed (i) to execute and deliver the Intercreditor Agreement, the Escrow Agreement and the NPA on or prior to the Issuance Date, each in the form delivered to the Trustee by the Company, and (ii) subject to the respective terms thereof, to perform its obligations thereunder. Upon request of the Company and the satisfaction or waiver of the closing conditions specified in the Underwriting Agreement, the Trustee shall execute, deliver, authenticate, issue and sell Applicable Certificates in authorized denominations equaling in the aggregate the amount set forth, with respect to the Applicable Trust, in Schedule I to the Underwriting Agreement evidencing the entire ownership interest in the Applicable Trust, which amount equals the maximum aggregate principal amount of Equipment Notes which may be purchased by the Trustee pursuant to the NPA. Except as provided in Sections 3.03, 3.04, 3.05 and 3.06 of the Basic Agreement, the Trustee shall not execute, authenticate or deliver Applicable Certificates in excess of the aggregate amount specified in this paragraph. The provisions of this Section 5.01(a) supersede and replace the first sentence of Section 3.02(a) of the Basic Agreement, with respect to the Applicable Trust. (b) After the Issuance Date, the Company may deliver from time to time to the Trustee a Closing Notice relating to one or more Equipment Notes. After receipt of a Closing Notice and in any case no later than one Business Day prior to a Scheduled Closing Date as to which such Closing Notice relates (the “Applicable Closing Date”), the Trustee shall (as and when specified in the Closing Notice) instruct the Escrow Agent to provide a Notice of Purchase Withdrawal to the Depositary requesting (A) the withdrawal of one or more Deposits on the Applicable Closing Date in accordance with and to the extent permitted by the terms of the Escrow Agreement and the Deposit Agreement and (B) the payment of all, or a portion, of such Deposit or Deposits in an amount equal in the aggregate to the purchase price of such Equipment Notes to or on behalf of the Company, all as shall be described in the Closing Notice. The Trustee shall (as and when specified in such Closing Notice), subject to the conditions set forth in Section 2 of the NPA, enter into and perform its obligations under the Participation Agreement specified in such Closing Notice (the “Applicable Participation Agreement”) and cause such certificates, documents and legal opinions relating to the Trustee to be duly delivered as required by the Applicable Participation Agreement. If at any time prior to the Applicable Closing Date, the Trustee receives a notice of postponement pursuant to Section 1(e) or 1(f) of the NPA, then the Trustee shall give the Depositary (with a copy to the Escrow Agent) a notice of cancellation of such Notice of Purchase Withdrawal relating to such Deposit or Deposits on such Applicable Closing Date. Upon satisfaction of the conditions specified in the NPA and the Applicable Participation Agreement, the Trustee shall purchase the applicable Equipment Notes with the proceeds of the withdrawals of one or more Deposits made on the Applicable Closing Date in accordance with the terms of the Deposit Agreement and the Escrow Agreement. The purchase price of such Equipment Notes shall equal the principal amount of such Equipment Notes. Amounts withdrawn from such Deposit or Deposits in excess of the purchase price of the Equipment Notes or to the extent not applied on the Applicable Closing Date to the purchase price of the Equipment Notes, shall be re-deposited by the Trustee with the Depositary on the Applicable Closing Date in accordance with the terms of the Deposit Agreement. The provisions of this Section 5.01(b) supersede and replace the provisions of Section 2.02 of the Basic Agreement with respect to the Applicable Trust, and all provisions of the Basic Agreement relating to Postponed Notes and Section 2.02 of the Basic Agreement shall not apply to the Applicable Trust. (c) The Trustee acknowledges its acceptance of all right, title and interest in and to the Trust Property to be acquired pursuant to Section 5.01(b) of this Trust Supplement, the NPA and each Applicable Participation Agreement, and declares that it holds and will hold such right, title and interest for the benefit of all present and future Applicable Certificateholders, upon the trusts set forth in the Agreement. By its acceptance of an Applicable Certificate, each initial Applicable Certificateholder, as a grantor of the Applicable Trust, joins with the Trustee in the creation of the Applicable Trust. The provisions of this Section 5.01(c) supersede and replace the provisions of Section 2.03 of the Basic Agreement, with respect to the Applicable Trust.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!