Appeal Extension Period Sample Clauses

Appeal Extension Period. If prior to the Closing Date, Buyer has been granted the Approvals, but any of the Approvals have been appealed by a third party pursuant to an administrative appeal process or to a court of competent jurisdiction, or if any Approvals are denied and/or contain requirements or conditions that render Buyer’s Project “uneconomic” as that term is defined under 760 CMR 56.02 of the DHCD Regulations or otherwise materially deviates from the plans referenced in Buyer’s response to the RFP, and Buyer elects to contest and/or appeal the same, Buyer shall have the right to (1) elect to extend the Time of Closing until the Appeal Extension Deadline (as such term is defined herein); or (2) terminate this Agreement by providing written notice to Seller and the Deposit shall be promptly refunded to Buyer by Escrow Agent without further recourse to either party hereto except for any obligations set forth herein that specifically survive such termination. During any such extension of the Closing Date as provided in Section (1) above, Buyer shall (i) diligently prosecute any such appeal until the issuance of a final un-appealed decision by a court of competent jurisdiction or other applicable adjudicating body, and (ii) provide a monthly status update to Seller of the appeal, and, upon Seller’s request, provide copies of all court or other filings made by the Buyer or any other party to the appeal (iii) Buyer may utilize up to $50,000.00 of the Deposit for the purpose of prosecuting said appeal, in which event the Purchase Price shall be reduced by that same amount. The Seller agrees that it will cooperate and participate in any appeal of the Comprehensive Permit, if any, hereunder. If the Closing has not occurred by the date that is nineteen (19) months after the Effective Date (or such extended period as the Seller may extend in its sole discretion; the “Appeal Extension Deadline”), irrespective of whether any Approvals are outstanding or remain subject to appeal, then Buyer may terminate this Agreement by written notice to Seller and upon such termination, the remaining Deposit, including Extension Deposits and any Appeal Deposit paid shall be refunded to the Buyer by Escrow Agent without further recourse to either party hereto except for any obligations set forth herein that specifically survive such termination, so long as said Approvals have been pursued in good faith and with diligent efforts in accordance with sections 3.7(b) through (f) above. Failure to obtain fi...
Sample 1
AutoNDA by SimpleDocs

Related to Appeal Extension Period

  • Extension Period Any extension hereof shall be subject to the provisions of Article III hereof.

  • Renewal, Extension The renewal or extension of any Letter of Credit shall, for purposes hereof, be treated in all respects the same as the issuance of a new Letter of Credit hereunder.

  • Extension of Facility Termination Date The Seller may advise any Managing Agent in writing of its desire to extend the Facility Termination Date for an additional period not exceeding 364 days, provided such request is made not more than 90 days prior to, and not less than 60 days prior to, the then current Facility Termination Date. Each Managing Agent so advised by the Seller shall promptly notify each Committed Purchaser in its related Purchaser Group of any such request and each such Committed Purchaser shall notify its related Managing Agent, the Collateral Agent and the Seller of its decision to accept or decline the request for such extension no later than 30 days prior to the then current Facility Termination Date (it being understood that each Committed Purchaser may accept or decline such request in its sole discretion and on such terms as it may elect, and the failure to so notify its Managing Agent, the Collateral Agent and the Seller shall be deemed an election not to extend by such Committed Purchaser). In the event that at least one Committed Purchaser agrees to extend the Facility Termination Date, the Seller Parties, the Collateral Agent, the extending Committed Purchasers and the applicable Managing Agent or Managing Agents shall enter into such documents as such extending Committed Purchasers may deem necessary or appropriate to reflect such extension, and all reasonable costs and expenses incurred by such Committed Purchasers, the Managing Agents and the Collateral Agent (including reasonable attorneys’ fees) shall be paid by the Seller. In the event that any Committed Purchaser (a) declines the request to extend the Facility Termination Date or (b) is in a Purchaser Group with respect to which the Seller did not seek an extension of the Facility Termination Date (each such Committed Purchaser being referred to herein as a “Non-Renewing Committed Purchaser”), and, in the case of a Non-Renewing Committed Purchaser described in clause (a), the Commitment of such Non-Renewing Committed Purchaser is not assigned to another Person in accordance with the terms of this Article XI prior to the then current Facility Termination Date, the Purchase Limit shall be reduced by an amount equal to each such Non-Renewing Committed Purchaser’s Commitment on the then current Facility Termination Date.

  • Extension Term The options to extend the Term of this Lease as described above shall not be deemed exercised by Tenant unless at least twenty-four (24) months prior to the Lease Expiration Date for the Primary Term or at least twenty-four (24) months prior to the expiration of the Extension Term for the first (1st) Extension Term, Tenant shall have delivered written notice to Landlord of Tenant's irrevocable election to so extend this Lease at the end of the Primary Term or the first (1st) Extension Term, as applicable. Tenant's failure to deliver one (1) such timely notice to Landlord shall terminate all future Extension Terms, if any, following the Extension Term to which such notice specifically relates. Subject to the provisions of paragraph 5 of this Lease, the terms and conditions of this Lease shall apply to each Extension Term with the same force and effect as if such Extension Term had originally been included in the Primary Term of the Lease. The right of Tenant to exercise its rights with respect to the Extension Terms shall be conditioned upon this Lease being in full force and effect and no Event of Default then existing as of the Lease Expiration Date (for the first (1st) Extension Term), or expiration of the first (1st) Extension Term (for the second (2nd) Extension Term). The Primary Term, together with any Extension Term with respect to which Tenant properly exercises its option, and for which the conditions related thereto are satisfied, shall constitute the "TERM" of this Lease.

  • Territorial Extension At the time of signature of this Agreement, or at any time thereafter, the provisions of this Agreement may be extended to such territories for whose international relations the Government of the United Kingdom are responsible as may be agreed between the Contracting Parties in an Exchange of Notes.

  • Listing Period Extension The Commission shall be due if the Property is sold, conveyed, exchanged, optioned, or otherwise transferred within _ _ days (“Extension Period”) after the expiration of the Listing Period to anyone with whom the Broker or Agency has negotiated unless the Property is listed, in good faith, with another real estate agency. The term “negotiation” shall include providing information about the Property, showing the Property, or presenting an offer on the Property. All rights under this Section shall terminate upon the expiration of the Extension Period.

  • Time Extension CONTRACTOR shall provide a time extension request on completion of Task Order for delays caused by others (Permitting Agencies, COUNTY or Contract Cities, or unforeseen conditions such as inclement weather, etc.) and at no fault by CONTRACTOR, subject to approval by COUNTY. COUNTY will review the request and determine in its sole discretion whether the situation warrant a time extension at no-cost or with costs. If CONTRACTOR completes the Task Order beyond the stipulated completion date without COUNTY’s specific written approval for time extension, CONTRACTOR will be subject to liquidated damages and may be construed as non-responsive, which may affect CONTRACTOR for considerations for future Task Orders or projects.

  • COMMENCEMENT/EXPIRATION DATE This agreement is executed as of the date of the last signature and is effective through at which time it will expire. The expiration date is the final date for completion of all work activities under this agreement.

  • Extended Term Tenant shall have the option to extend the Term for two (2) consecutive five (5) year periods (the "FIRST EXTENDED TERM" and "SECOND EXTENDED TERM", respectively) on all the terms and conditions contained in this Lease including, without limitation, continuation of the adjustment of the Base Rent on an annual basis as provided in Section 3.3 below (provided only that upon commencement of the First Extended Term the only remaining option to extend the Term shall be the Second Extended Term and upon exercise of the option with respect to the Second Extended Term, no further right to extend the Term shall exist). Tenant shall deliver, if at all, written notice of its exercise of the option ("OPTION NOTICE") to Landlord at least six (6) months but not more than one (1) year before the expiration of the Term or First Extended Term, as the case may be. In the event Tenant fails to deliver the applicable Option Notice within the time allowed, Landlord shall deliver written notice to Tenant of Tenant's failure to deliver the Option Notice, and Tenant shall then have thirty (30) days from receipt of such notice within which to deliver the Option Notice, if at all, to Landlord. In the event (and only in the event) that, Tenant fails to deliver an Option Notice to Landlord within such thirty (30) days, Tenant shall be considered to have elected not to extend the Term of this Lease and thereafter, Tenant shall have no further right to extend the Term of this Lease. References in this Lease to the "Term" shall include the initial Term of fifteen (15) years and shall, in addition, include the First Extended Term and the Second Extended Term, if applicable.

  • Due Date Extension If any payment of principal or Yield with respect to any Advance falls due on a day which is not a Business Day, then such due date shall be extended to the next following Business Day, and additional Yield shall accrue and be payable for the period of such extension at the rate applicable to such Advance.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!