Assessment Period Change Order Sample Clauses

Assessment Period Change Order. Within ten Days after Contractor delivers the final Facility Assessment Replacement List to Owner and Owner's Engineer, Owner and Owner's Engineer shall meet with Contractor at the Site to discuss Owner's comments to the Facility Assessment Replacement List, and Contractor and Owner shall, not later than ten Days after the commencement of such meeting, agree in writing (in a Change Order to this Agreement) to an increase in the Initial Contract Price and/or a change in the Contract Summary Schedule, Contract Detailed Schedule, Schedule of Values, Guaranteed Substantial Completion Dates, Early Completion Dates (subject to the limitations set forth in Section 10.1.3), or Guaranteed Final Completion Date in respect of the additional equipment and materials to be repaired, replaced or supplied, the portions of the Prior Work to be repaired, replaced or reperformed, and any additional engineering, additional documentation and craft and other labor necessary to complete the Work and the Facility in accordance with the Specification, Laws and the other requirements of this Agreement resulting from the Facility Assessment, together with an adjustment in respect of the Major Equipment Contracts and the Paint Contract pursuant to Section 6.1.1.2. The Initial Contract Price, as increased and adjusted pursuant to this Section 6.1.3, shall be fixed and shall thereafter be the "Contract Price". If Contractor and Owner have not agreed on a fixed Contract Price by the 30th Day after the end of the True-Up Period, then Contractor shall, upon the direction of Owner, nevertheless proceed with the Work in accordance with the Schedule and the other terms of this Agreement, and Contractor shall be compensated based upon the Initial Contract Price plus the undisputed amount representing the updated Facility Assessment Replacement List and paid in accordance with the Schedule of Values until the Contract Price is determined, and the Contract Price shall be determined pursuant to the procedures set forth in Article 21. The Contract Price shall not be subject to adjustment or escalation thereafter except in accordance with the terms of this Agreement.
Sample 1
AutoNDA by SimpleDocs

Related to Assessment Period Change Order

  • CONTRACT YEAR The first Contract Year is the period of time ending on the first contract anniversary. Subsequent Contract Years are the annual periods between contract anniversaries.

  • Change Order A written order which is signed by DESIGN/BUILDER and OWNER which authorizes an addition, deletion or revision in the Work, or an adjustment in the Contract Price or the Contract Times, issued on or after the Effective Date of the Agreement.

  • Project Schedule Contractor shall perform the Work in accordance with the Project Schedule.

  • Change Orders Tenant shall have the right, in accordance herewith, to submit for Landlord's approval change proposals subsequent to the completion of the Approved Tenant Improvement Construction Documents (each, a "Tenant Improvement Work Change Proposal"). Landlord agrees to respond to any such Tenant Improvement Work Change Proposal within such time as is reasonably necessary, but no more than five (5) business days, after the submission thereof by Tenant (unless Landlord has previously advised Tenant that a longer time period is reasonably necessary due to the nature and scope of the Tenant Improvement Work Change Proposal, together with Landlord's good faith estimate as to the amount of additional time that will be necessary, or the fact that the information provided by Tenant in the Tenant Improvement Work Change Proposal is insufficient for the purposes of enabling Landlord to make the determination set forth herein), advising Tenant of any items which Landlord in good faith reasonably believes are inconsistent with the design, cost and construction schedule for the Base Building Work, as well as specifying (subject to the terms of Section 5.2 below) whether any alterations, additions or improvements shown in the Tenant Improvement Work Change Proposal must be removed by Tenant upon the expiration or earlier termination of the Term ("Landlord's Tenant Improvement Work Change Order Response") (it being understood and agreed that Landlord's failure to respond within said five (5) business day period shall be deemed to constitute Landlord's approval of the Tenant Improvement Work Change Proposal and determination that none of the items shown thereon are to be removed by Tenant at the expiration or earlier termination of the Term). Tenant shall have the right to then proceed with or withdraw such Tenant Improvement Work Change Proposal within five (5) business days after receipt of Landlord's Tenant Improvement Work Change Order Response. If Tenant fails to respond to Landlord's Tenant Improvement Work Change Order Response within such five (5) business day period, such Tenant Improvement Work Change Proposal shall be deemed withdrawn. If Tenant proceeds with such Tenant Improvement Work Change Proposal, then such Tenant Improvement Work Change Proposal shall be deemed to be a part of the Approved Tenant Improvement Construction Documents for the purposes of this Article III.

  • Annual Budget (a) The Company and its Subsidiaries shall be operated in accordance with an annual budget, as it may be annually updated from time to time pursuant to this Section 3 (the “Annual Budget”). The initial Annual Budget for the period beginning on the Effective Date and ending on December 31, 2018, including the related variances, is attached hereto as Schedule B-1 (the “Initial Annual Budget”). For each Fiscal Year thereafter, the Asset Manager shall be responsible for preparing and submitting to the Company Board for approval as a Major Decision in accordance with the terms of the Company LLC Agreement a proposed updated Annual Budget, including the related variances. The Annual Budget shall be prepared by the Asset Manager in accordance with the protocols (including the preparation of the back-up materials on the timetable set forth therein) set forth on Schedule B-2 hereto (the “Budget Development Protocols”). The Annual Budget for each Fiscal Year shall be prepared with the same detail and line items as set forth in the Initial Annual Budget and such other detail as the members of the Company Board appointed by the Preferred Partners in accordance with Section 4.3(c) of the Parent LP Agreement (the “Preferred Board Members”) may reasonably request. In connection with the review of a proposed Annual Budget, the Preferred Board Members may reasonably request additional information regarding the materials supporting the proposed Annual Budget or such other information as is necessary or desirable to enable review of such proposed Annual Budget, and the Asset Manager shall provide such requested information. The Preferred Board Members shall consent to or reject the proposed Annual Budget, or request additional information (as provided for above), within ten (10) Business Days following (i) receipt of such proposed Annual Budget or (ii) receipt of all additional information that is, in the determination of the Preferred Board Members, necessary or desirable to enable review of such proposed Annual Budget. The Asset Manager shall comply with the Budget Development Protocols regarding the Preliminary Budget for each Fiscal Year. The Annual Budget shall be prepared and submitted annually by the Asset Manager no later than December 10, 2018 for the next Fiscal Year and thereafter by December 10 of each year with respect to the following Fiscal Year. The Annual Budget for each Fiscal Year shall include use of the pre-funded reserve amounts as shown on Schedule B-3 hereto for the four Fiscal Quarters comprising such Fiscal Year. In connection with the submission of the Annual Budget, the Asset Manager shall also prepare and submit to the Company Board an annual business plan for Parent and its Subsidiaries, including a responsible five-year operations forecast, including the operating metrics set forth on Schedule B-4 hereto (the “Annual Plan”). The Preferred Board Members, or their designated representatives, shall be provided reasonable access to all information, data, reports, models and analyses relied on in developing the Annual Plan (including, for the avoidance of doubt, all financial and silvicultural assumptions, constraints, supporting stand level data, merchantable timber volumes, pre-merchantable acres by species and age class, and acres by land classification).

  • Development Plan As defined in Section 3.2(a).

  • Commencement Date Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):

  • Budget Borrower shall submit to Lender for Lender’s written approval (provided that such approval shall only be required in the event that Borrower or any Affiliate of Borrower has the right to approve any such budget pursuant to the terms of the Management Agreement) not to be unreasonably withheld, an annual budget (the “Annual Budget”) within ten (10) Business Days after receipt thereof from Manager, in form satisfactory to Lender setting forth in reasonable detail budgeted monthly operating income and monthly operating capital and other expenses for the Premises. In the event Lender shall have the right to approve such Annual Budget and Lender objects to the proposed Annual Budget submitted by Borrower, Lender shall advise Borrower of such objections within fifteen (15) days after receipt thereof (and deliver to Borrower a reasonably detailed description of such objections) and Borrower shall, within three (3) days after receipt of notice of any such objections, revise such Annual Budget and resubmit the same to Lender. Lender shall advise Borrower of any objections to such revised Annual Budget within ten (10) days after receipt thereof (and deliver to Borrower a reasonably detailed description of such objections) and Borrower shall revise the same in accordance with the process described herein until Lender approves an Annual Budget, provided, however, that if Lender shall not advise Borrower of its objections to any proposed Annual Budget within the applicable time period set forth in this Section, then such proposed Annual Budget shall be deemed approved by Lender. If Lender has the right to approve the Annual Budget pursuant to the terms of the Management Agreement, until such time that Lender approves a proposed Annual Budget, the most recently Approved Annual Budget shall, except as otherwise provided in the Management Agreement, apply; provided that, such Approved Annual Budget shall be adjusted to reflect actual increases in Basic Carrying Costs and utilities expenses. In the event that Owner must incur an Extraordinary Expense, then Borrower shall promptly deliver to Lender a reasonably detailed explanation of such proposed Extraordinary Expense which, if Borrower has the right to approve such expenditures pursuant to the terms of the Management Agreement, shall be subject to Lender’s approval, which approval may be granted or denied in Lender’s reasonable discretion.

  • Feasibility Study Buyer is granted the right to conduct engineering and/or market and economic feasibility studies of the Property and a physical inspection of the Property, including studies or inspections to determine the existence of any environmental hazards or conditions (collectively, the “Feasibility Study”) during the period (the “Feasibility Period”) commencing on the Effective Date and ending at 5:00 p.m., Central Time, on the June 3, 2010. With Seller’s permission, after Seller has received advance notice sufficient to permit it to schedule in an orderly manner Buyer’s examination of the Property and to provide at least 24-hours’ advance written notice to any affected tenants, Buyer or its designated agents may enter upon the Property during normal business hours for purposes of analysis or other tests and inspections which may be deemed necessary by Buyer for the Feasibility Study. Buyer or its designated representative must be accompanied by a designated representative of Seller or have received Seller’s written permission prior to entering upon the Property in connection with Buyer’s Feasibility Study; provided, however, Buyer may not enter into any space leased by any tenant without being accompanied by a designated representative of Seller. Seller agrees to make its representative reasonably available during normal business hours. Buyer will not alter the physical condition of the Property or conduct invasive testing without notifying Seller of its requested tests, and obtaining the written consent of Seller to any physical alteration of the Property or invasive testing. Buyer will utilize commercially reasonable diligence to conduct or cause to be conducted all inspections and tests in a manner and at times which will not unreasonably interfere with any tenant’s use and occupancy of the Property. If Buyer determines, in its sole judgment, that the Property is not suitable for any reason for Buyer’s intended use or purpose, or is not in satisfactory condition, then Buyer may terminate this Contract by written notice to Seller prior to expiration of the Feasibility Period, in which case the Xxxxxxx Money (other than the Option Money) will be returned to Buyer, and neither party shall have any further right or obligation hereunder other than as set forth herein with respect to rights or obligations which survive termination. If this Contract is not terminated pursuant to this Section 5(a), then after expiration of the Feasibility Period, after Seller has received advance notice sufficient to permit it to schedule in an orderly manner Buyer’s examination of the Property and to provide at least 24-hours’ advance written notice to any affected tenants, Buyer or its designated agents may enter upon the Property during normal business hours. Buyer or its designated representative must be accompanied by a designated representative of Seller or have received Seller’s written permission prior to entering upon the Property; provided, however, Buyer may not enter into any space leased by any tenant without being accompanied by a designated representative of Seller. If this Contract is not timely terminated pursuant to this Section 5(a), Buyer’s right to terminate this Contract pursuant to this Section 5(a) and any and all objections with respect to the Feasibility Study will be deemed to have been waived by Buyer for all purposes.

  • Project Plan Based on the Project Specifications, Omnicare CR has provided a description of services to be performed for Sponsor’s “A multi-center, randomized, double-blind, double-dummy, vehicle-controlled sequential cohort study to determine the safety of PEP005 0.025% and 0.05% topical gel in patients with actinic keratoses” (hereinafter “the Project”) and associated costs. Changes made in the Project scope, at any time during the Project, will result in a corresponding adjustment to the Project costs.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!