Audit of Contractor Sample Clauses

Audit of Contractor. The TI Construction Contract shall provide that Landlord and Tenant shall have a right, within a reasonable period of time following Substantial Completion of the Premises, to conduct an audit of the books and records of the TI Contractor to confirm the costs actually incurred with respect to the construction of the TI Work, the allocation of costs between the Landlord’s Work and the TI Work and similar matters under the TI Construction Contract. The results of the audit shall be made available to both Landlord and Tenant. The TI Construction Contract shall provide for binding arbitration of all disputes arising over change orders or from the audit. Tenant shall be responsible for the costs of such audit and any arbitration relating thereto, subject to reimbursement from the TI Contractor as may be provided in the TI Construction Contract. Tenant shall be responsible for and entitled to any adjustments to the cost of the TI Work that may be made by reason of such audit.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Audit of Contractor. The Company may at any time undertake, or engage a third party to undertake, an audit of the Contractor to ensure that: (a) the Contractor is compliant with the SHE Requirements; and (b) that the Contractor has ensured, and has proof, that all Contractor's Personnel are also compliant with the SHE Requirements.
Sample 1
Audit of Contractor. Company shall have the right to audit Contractor's books and records relating to services performed hereunder. To facilitate such audit, Contractor shall retain its books and records made in any calendar year during the term of Agreement, for a period of two (2) years from the end of such calendar year. This obligation survives termination of this Agreement. For the purpose of audit, Company and its authorized representatives or agents shall have the right to examine during business hours at Contractor's office and for a reasonable length of time all books, records, accounts, correspondence, instructions, specification, maps, receipts and memoranda insofar as they are pertinent to this Agreement.
Sample 1
Audit of Contractor. The TI Construction Contract shall provide that Landlord and Tenant shall have a right, within a reasonable period of time following Substantial Completion of Floor 32, to conduct an audit of the books and records of the TI Contractor to confirm the costs actually incurred with respect to the construction of the Floor 32 TI Work. The results of the audit shall be made available to both Landlord and Tenant. The TI Construction Contract shall provide for binding arbitration of all disputes arising over change orders or from the audit. Tenant shall be responsible for the costs of such audit and any arbitration relating thereto, subject to reimbursement from the TI Contractor as may be provided in the TI Construction Contract. Tenant shall be responsible for and entitled to any adjustments to the cost of the Floor 32 TI Work that may be made by reason of such audit.
Sample 1
Audit of Contractor. At any time during the life of this Contract, OGS Procurement Services reserves the right to suspend this Contract for failure of the Contractor to provide accurate and timely documentation as required by this Contract. This will include, but is not limited to submission of all reports, proof of insurance and Consultant Disclosure documents. OGS will activate this right for the failure of the Contractor to make timely and accurate payment of the quarterly Administrative Fee. This suspension will impact the Annual Contractor Evaluation. At any time during the life of this Contract, OGS Procurement Services reserves the right to audit the accuracy and timeliness of the Administrative Fee. Audits shall be conducted during regular business hours, upon not less than fifteen (15) business days prior written notice. Administrative Fees will be due immediately for any errors or omissions disclosed by any such audit. If, as a result of any such audit, Administrative Fees are determined to have been underpaid by more than five (5) percent (5%) for the period audited, Contractor shall pay the costs of such audit or three (3) times the discrepancy, whichever is higher. Failure to make such payments or repeated errors on subsequent audits may result in the scheduling of a responsibility meeting and may lead to termination of this Agreement. At any time during the life of this Contract, OGS Procurement Services reserves the right to audit the accuracy and timeliness of all payments and supporting documentation between Contractor, Subcontractors and Selected Candidates. Audits shall be conducted during regular business hours, upon not less than fifteen (15) business days prior written notice. Failure to comply or repeated errors on subsequent audits may result in the scheduling of a responsibility meeting and may lead to termination of this Agreement.
Sample 1
Audit of Contractor. The TI Construction Contract shall provide that Landlord and Tenant shall have a right, within a reasonable period of time following Substantial Completion of the Premises, to conduct an audit of the books and records of the Ti Contractor to confirm the costs actually incurred with respect to the construction of the TI Work, the allocation of costs between the Landlord’s Work and the TI Work and similar matters under the TI Construction Contract. The results of the audit shall be made available to both Landlord and Tenant. The TI Construction Contract shall provide for binding arbitration of all disputes arising over change orders or from the audit. Tenant shall be responsible for the costs of such audit and any arbitration relating thereto, subject to reimbursement from the TI Contractor as may be provided in the TI Construction Contract. Tenant shall be responsible for and entitled to any adjustments to the cost of the TI Work that may be made by reason of such audit. Landlord agrees that it will, at its sole cost and expense, apply for the permit and upon its receipt commence to remove the stairway between Floor 19 and Floor 20 and pursue the completion (with the exception of delays or conditions beyond the Landlord’s control) in accordance with Landlord’s or Landlord’s architect’s designs and plans
Sample 1

Related to Audit of Contractor

  • Engagement of Contractor Subject to the terms and conditions of this Agreement, CDS engages Contractor to provide services specified in Section 1.2. Contractor hereby accepts this engagement by CDS with respect to such matters and for such compensation and terms as provided herein.

  • INTEREST OF CONTRACTOR The Contractor covenants that he presently has no interest and shall not acquire any interest direct or indirect, which would conflict in any manner or degree with the performance of services required to be performed under this Agreement. The Contractor further covenants that in the performance of this Agreement no person having any such interest shall be employed.

  • Subcontract Costs Payments made by the Construction Manager to Subcontractors in accordance with the requirements of the subcontracts and this Agreement.

  • Supervision of Contractor Personnel The Contractor must supply all necessary and sufficient supervision over the work that is being performed and will be held solely responsible for the conduct and performance of his employees or agents involved in work under the Agreement.

  • CONTRACTOR SUPERVISION Contractor shall provide competent supervision of personnel employed on the job Site, use of equipment, and quality of workmanship.

  • Contractor Certification regarding Boycotting Israel Pursuant to Chapter 2270, Texas Government Code, Contractor certifies Contractor (1) does not currently boycott Israel; and (2) will not boycott Israel during the Term of this Agreement. Contractor acknowledges this Agreement may be terminated and payment withheld if this certification is inaccurate.

  • CERTIFICATION REGARDING USE OF CONTRACT FUNDS FOR LOBBYING This provision is applicable to all Federal-aid construction contracts and to all related subcontracts which exceed $100,000 (49 CFR 20). 1. The prospective participant certifies, by signing and submitting this bid or proposal, to the best of his or her knowledge and belief, that: a. No Federal appropriated funds have been paid or will be paid, by or on behalf of the undersigned, to any person for influencing or attempting to influence an officer or employee of any Federal agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with the awarding of any Federal contract, the making of any Federal grant, the making of any Federal loan, the entering into of any cooperative agreement, and the extension, continuation, renewal, amendment, or modification of any Federal contract, grant, loan, or cooperative agreement. b. If any funds other than Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any Federal agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with this Federal contract, grant, loan, or cooperative agreement, the undersigned shall complete and submit Standard Form-LLL, "Disclosure Form to Report Lobbying," in accordance with its instructions. 2. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Submission of this certification is a prerequisite for making or entering into this transaction imposed by 31 U.S.C. 1352. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. 3. The prospective participant also agrees by submitting its bid or proposal that the participant shall require that the language of this certification be included in all lower tier subcontracts, which exceed $100,000 and that all such recipients shall certify and disclose accordingly. This provision is applicable to all Federal-aid projects funded under the Appalachian Regional Development Act of 1965. 1. During the performance of this contract, the contractor undertaking to do work which is, or reasonably may be, done as on-site work, shall give preference to qualified persons who regularly reside in the labor area as designated by the DOL wherein the contract work is situated, or the subregion, or the Appalachian counties of the State wherein the contract work is situated, except: a. To the extent that qualified persons regularly residing in the area are not available. b. For the reasonable needs of the contractor to employ supervisory or specially experienced personnel necessary to assure an efficient execution of the contract work. c. For the obligation of the contractor to offer employment to present or former employees as the result of a lawful collective bargaining contract, provided that the number of nonresident persons employed under this subparagraph (1c) shall not exceed 20 percent of the total number of employees employed by the contractor on the contract work, except as provided in subparagraph (4) below. 2. The contractor shall place a job order with the State Employment Service indicating (a) the classifications of the laborers, mechanics and other employees required to perform the contract work, (b) the number of employees required in each classification, (c) the date on which the participant estimates such employees will be required, and (d) any other pertinent information required by the State Employment Service to complete the job order form. The job order may be placed with the State Employment Service in writing or by telephone. If during the course of the contract work, the information submitted by the contractor in the original job order is substantially modified, the participant shall promptly notify the State Employment Service. 3. The contractor shall give full consideration to all qualified job applicants referred to him by the State Employment Service. The contractor is not required to grant employment to any job applicants who, in his opinion, are not qualified to perform the classification of work required. 4. If, within one week following the placing of a job order by the contractor with the State Employment Service, the State Employment Service is unable to refer any qualified job applicants to the contractor, or less than the number requested, the State Employment Service will forward a certificate to the contractor indicating the unavailability of applicants. Such certificate shall be made a part of the contractor's permanent project records. Upon receipt of this certificate, the contractor may employ persons who do not normally reside in the labor area to fill positions covered by the certificate, notwithstanding the provisions of subparagraph (1c) above. 5. The provisions of 23 CFR 633.207(e) allow the contracting agency to provide a contractual preference for the use of mineral resource materials native to the Appalachian region. 6. The contractor shall include the provisions of Sections 1 through 4 of this Attachment A in every subcontract for work which is, or reasonably may be, done as on-site work.

  • Independent Contractor; Authority Notwithstanding the Services provided by the Administrator pursuant to this Agreement, the Administrator shall be deemed to be an independent contractor with respect to the Services. The management, policies and operations of the Parties (including the ultimate approval of the making or disposition of the Painting by the Issuer or Masterworks Cayman, and the terms and conditions thereof) shall be the responsibility of the Parties other than the Administrator.

  • Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shall submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the general conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over-Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (i), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease.

  • Authority of Contractor The Contractor shall have no right or authority, express or implied, to commit or otherwise obligate the Company in any manner whatsoever except to the extent specifically provided herein or specifically authorized in writing by the Company.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!