CONSTRUCTION SCHEDULE & SCHEDULE OF VALUES Sample Clauses

CONSTRUCTION SCHEDULE & SCHEDULE OF VALUES. 3.5.1 Except as set out in GC 6.1 – CHANGES, 6.2 – CHANGE ORDER and 6.5 - DELAYS, the Construction Schedule can only be altered with an express written approval from the Owner in consultation with the Project Monitor. The Contractor agrees that the Construction Schedule shall give priority to the completion of all site servicing for the Project. 3.5.2 The Contractor shall: .1 Prepare a detailed Construction Schedule and deliver it to the Owner, for the Owner’s approval, within 60 days from the satisfaction or waiver by the parties of the Conditions Precedent. .2 monitor the progress of the Work relative to the Construction Schedule and update the Construction Schedule on a monthly basis or as stipulated by the Contract Documents; and .3 advise the Owner, the Project Monitor and the Consultant of any revisions required to the Construction Schedule as the result of extensions of the Contract Time as provided in Part 6 of the General Conditions - CHANGES IN THE WORK. 3.5.3 Any adjustment to the Schedule of Values that results in an increase in the Contract Price must be requested by Contractor pursuant to a Change Order Request and approved and implemented pursuant to a Change Order in accordance with GC 6.2 – CHANGE ORDER. Any adjustment to the Schedule of Values that does not result in an increase in the Contract Price may be requested by Contractor in writing and approved by the Project Monitor in its sole discretion and such adjustment implemented by revision to then existing Schedule of Values.
Sample 1
AutoNDA by SimpleDocs

Related to CONSTRUCTION SCHEDULE & SCHEDULE OF VALUES

  • Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.

  • Schedule of Values 9.2.1 Before the first Application for Payment, the Contractor shall submit to the Architect a schedule of values allocated to the various portions of the Work, prepared in such form and supported by such data to substantiate its accuracy as the Architect may require. This schedule, unless objected to by the Architect, shall be used only as a basis for the Contractor's Applications for Payment.

  • Completion Schedule 6.1 The proposed schedule for the completion of the Project is presented in “Attachment D” and is made a part hereof. 6.2 ENGINEER shall adhere to all time limits stated in this Agreement or included in any accepted time schedule. All such time limits shall be of the essence to this Agreement. 6.3 In all events the various stages and phases of ENGINEER’S services are to be completed in such sequence and at such times, and with approved or agreed upon time limits, as may be required to assure the timely, continuous, efficient and diligent prosecution of the work and services provided for by this Agreement. 6.4 OWNER may at any time, by written order, make changes within the general scope of the Agreement in the services of work to be performed. If ENGINEER believes that such a change justifies an increase in ENGINEER’S contract time or contract price required to perform the series under this Agreement it must assert such claim in writing within thirty (30) days of receipt of OWNER’S written order giving rise to the claim. No claim for adjustment in the contract time or contract price will be valid if not submitted in accordance with this paragraph. No services for which ENGINEER will charge additional compensation shall be furnished without the written authorization of OWNER. 6.5 ENGINEER shall carry on all work required under this Agreement and maintain the schedule for services during all disputes or disagreements with OWNER. No work shall be delayed or postponed pending resolution of any disputes or disagreements except as permitted in Article 8, or as ENGINEER and OWNER may otherwise agree in writing. 6.6 If the commencement, prosecution or completion of the services under this Agreement, or of the construction of the Project is delayed by any act, omission, delay, neglect or default of ENGINEER, or anyone employed by ENGINEER, or by any damage or acts caused by the negligent acts or omission by ENGINEER, then ENGINEER shall be liable to OWNER for any and all costs, assessments, expense, liabilities or damages caused thereby, in accordance with Section 4.8. 6.7 ENGINEER shall not be responsible for any time delays in the Project, or in the performance of services under this Agreement, to the extent such delays are caused solely by any act, omission, neglect or default of OWNER or anyone employed by OWNER, or by the unreasonable delay of any review agency or utility, or for any delay or damage caused by fire or the combined action of workers and which are in no way chargeable, in whole or in part, to ENGINEER, or by any other conditions or circumstances beyond the control of ENGINEER, its employee, agent, or other persons for whose acts or omissions ENGINEER is responsible. In the event of such delay, ENGINEER shall be entitled to an adjustment in the schedules or agreed time limitations for the performance of services, and this Agreement shall be modified in writing accordingly. Any claim of ENGINEER for adjustment under this cause must be asserted in writing within thirty (30) days from the date of the occurrence of the event giving rise to the claim, unless OWNER grants a further period of time before the date of final payment to ENGINEER. The adjustment of time for the performance of services, as provided in this paragraph, shall be ENGINEER’s sole exclusive right, entitlement and remedy in the event of such delays, and ENGINEER shall have no claim against OWNER for adjustment for increase in costs of performance, or other damages occurred in connection therewith.

  • Auction Schedule The Auction Agent shall conduct Auctions in accordance with the schedule set forth below. Such schedule may be changed by the Auction Agent with the consent of the Company, which consent shall not be withheld unreasonably. The Auction Agent shall give notice of any such change to each Broker-Dealer. Such notice shall be received prior to the first Auction Date on which any such change shall be effective. Time Event ---- ----- By 9:30 A.M. Auction Agent advises the Company and the Broker-Dealers of the Reference Rate and the Maximum Applicable Rate as set forth in Section 2.2(e)(i) hereof.

  • PROGRESS SCHEDULE The Contractor, within ten (10) working days of receiving notice of the award of the contract, shall prepare and submit for the State's and Architect's information an estimated progress schedule for the Work. The progress schedule shall be related to the entire Project to the extent required by the Contract Documents, and shall provide for expeditious and practicable execution of the Work.

  • Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.

  • Vacation Schedules (a) Completed vacation schedules will be posted by April 30th of each year. The schedule will be circulated commencing February 1st of the same year. (b) An employee who does not exercise her seniority rights within two (2) weeks of receiving the vacation schedule, shall not be entitled to exercise those rights in respect to any vacation time previously selected by an employee with less seniority. (c) An employee who relocates to another work location where the vacation schedule has already been completed will not be entitled to exercise her seniority rights for that year only. However, every effort shall be made to grant vacation at the time of the employee's choice.

  • Vacation Schedule 1. Vacation periods shall be fixed by the Employer to suit the requirements of his business, but as far as possible and practicable, vacations will be given during the summer months, and for employees with school-age children, during the school vacations. Vacation periods shall be unbroken unless by mutual consent between Employer and employee, or where it is impractical. Grievances relating to this Section shall be subject to the Adjustment and Arbitration Procedure in this Agreement. 2. Time off, based upon service in the Industry Vacation Plan, may be granted to an employee by mutual agreement between the Employer and the employee. The Employer shall not be required to give time off based upon service under the Industry Vacation Plan. However, if such additional industry vacation time off is granted to an employee, such time off shall be counted as time worked for the purpose of computing the employee's earned vacation benefits on his next anniversary date of employment.

  • CONVERSION SCHEDULE The Original Issue Discount Senior Convertible Debentures due on March 1, 2018 in the aggregate principal amount of $385,000 are issued by Legend Oil and Gas, Ltd., a Colorado corporation. This Conversion Schedule reflects conversions made under Section 4 of the above referenced Debenture.

  • Contract Exhibit J Quarterly Sales Report If a conflict exists among any of the Contract documents, the documents shall have priority in the order listed below: a) The Contract b) Statement of Work, Contract Exhibit A c) Additional Special Contract Conditions, Contract Exhibit D d) Special Contract Conditions, Contract Exhibit C e) Resume Acknowledgement Form, Contract Exhibit G f) Contractor Selection Justification Form, Contract Exhibit H

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!