Construction Staking Contractor shall avoid careless or negligent damage to construction stakes, flags, or marks. If such damage occurs, Contractor shall be required to replace stakes necessary to construc- tion. Contractor’s replacement staking shall be approved by Forest Service. Alternatively, upon Contractor’s request, Contracting Officer may agree to perform such work under E.2.1.8. When A.7 shows that construction stakes are to be set by Forest Service after clearing, Contractor shall submit to Forest Service a written schedule for clearing, construction staking, and construction that will provide Forest Service a reasonable period for setting construction stakes. Time for setting construction stakes may be modified by written agreement. If Forest Service performs construction staking for Specified Roads, timing of such staking shall permit Contrac- tor’s clearing and other construction activity to proceed without hindrance or delay, provided Contractor’s construction activity is reasonably consistent with needs identified in Contractor’s Operating Schedule or amendments thereto. Should Forest Service be unable to perform construction staking in such reasonable period, upon written agree- ment, Contractor shall assume the responsibility for construction staking for agreed upon portions of Specified Roads. In such event, Contracting Officer shall revise:
Tenant Improvements Landlord shall cause the Core and Shell Contractor or another Contractor designated by Landlord and approved by Tenant, such consent not to be unreasonably withheld or delayed (“TI Contractor”, and together with Core and Shell Contractor, “Contractor”) to commence and thereafter diligently prosecute the construction of the tenant improvements in the Premises pursuant to the Work Letter (the “Tenant Improvements”); provided, however, that before performing the Tenant Improvements, Landlord shall prepare in good faith an estimated budget for the construction of the Tenant Improvements and deliver such budget to Tenant for Tenant’s written approval prior the start of construction (the “Budget”). Landlord and Tenant shall work together cooperatively and in good faith to achieve a mutually acceptable Budget. Landlord shall update the Budget for Tenant’s review and approval at reasonable intervals and shall notify Tenant in writing if the Budget is likely to be exceeded. If there is an indication that the Budget is likely to be exceeded, Landlord and Tenant shall work together cooperatively, if required by Tenant, to modify the scope of the Tenant Improvements to bring the same in line with a budget reasonably acceptable to Tenant. The Tenant Improvements shall be performed in a workmanlike manner and shall substantially conform with Applicable Laws and the Approved TI Plans (as defined in the Work Letter). Tenant shall pay all TI Costs, except that Landlord shall pay for TI Costs that do not exceed the TI Allowance. The “TI Allowance” shall mean (a) One Hundred Twenty Five Dollars ($125.00) per rentable square foot of the Premises (the “Initial TI Allowance”), together with (b) the Additional Allowance. The “TI Costs” shall mean all Tenant Core and Shell Costs (as defined in the Work Letter) and all costs and expenses of performing the TI Work, including without limitation the hard and soft costs of (i) construction, (ii) the Construction Management Fee (as such term is defined in the Work Letter) and any Project or construction management fees paid by Tenant to an unaffiliated third party (such fees not to exceed three percent (3%) of the TI Allowance), (iii) space planning, design, architect, engineering, data and phone cabling and other related services, (iv) costs and expenses for labor, material, equipment, data and phone cabling and fixtures (including, without limitation, any of the Attached Property (as defined in Section 18.5), (v) building permits and other taxes, fees, charges and levies by governmental and quasi-governmental agencies for permits or for inspections of the Tenant Improvements, and (vi) the Warm Shell Costs. In no event shall the TI Allowance be used for: (w) the purchase of any furniture, personal property or other non-building system equipment, (x) costs resulting from a Tenant Delay, (y) costs resulting from any default by Tenant of its obligations under this Lease, or (z) costs that are recoverable or reasonably recoverable by Tenant from a third party (e.g., insurers, warrantors, or tortfeasors). In the event the estimated total TI Costs (as set forth in the Budget) exceed the TI Allowance, Tenant shall deposit with Landlord such overage (the “TI Allowance Excess”), within five (5) business days of receiving the Budget (the “TI Deposit”). In the event Landlord determines the estimate of the TI Costs set forth in the Budget underestimates the amount of TI Costs so that the TI Deposit will not be sufficient to cover the TI Allowance Excess, then Landlord shall communicate the same to Tenant and, if required by Tenant, the parties shall discuss revisions to the Budget and Tenant may make a TI Tenant Change Order Request to reduce TI Costs, and unless the TI Costs are reduced to be within the Budget and previously paid TI Deposit, Tenant shall promptly pay the additional amount to Landlord, and such additional amount shall be added to the TI Deposit. If the sum of the TI Allowance plus the TI Deposit is not sufficient to cover the TI Costs, Tenant shall reimburse Landlord the difference between (a) the TI Costs and (b) the sum of the TI Allowance and the TI Deposit. However, Landlord shall be solely responsible for any costs related to the Tenant Improvements to the extent the same result from Landlord’s gross negligence, intentional misconduct or breach of Lease. Landlord and Tenant shall work together cooperatively at no cost or risk to Landlord to maximize Tenant’s ability, to the extent reasonably possible, to obtain the benefit of any applicable research and development tax credits with respect to the Tenant Improvements.
Construction Work The regulation at 41 C.F.R. § 60-1.3 defines “construction work” as the construction, rehabilitation, alteration, conversion, extension, demolition or repair of buildings, highways, or other changes or improvements to real property, including facilities providing utility services. The term also includes the supervision, inspection, and other onsite functions incidental to the actual construction.
