CONTRACTOR'S RIGHT TO SUSPEND WORK OR TERMINATE CONTRACT Sample Clauses

CONTRACTOR'S RIGHT TO SUSPEND WORK OR TERMINATE CONTRACT. The contractor may suspend work or terminate contract upon ten days written notice to the owner and Engineer, for any of the following reasons: a) If an order of any court, or public authority caused the work to be stopped or suspended for a period of ninety days through no act or fault of the contractor or their employees. b) If the Engineer should fail to act upon any request for payment within thirty days after it is presented in accordance with the general conditions of the contract. c) If the owner should fail to pay the contractor any sum within thirty days after its award by arbitrators.
Sample 1Sample 2Sample 3See All (12)
AutoNDA by SimpleDocs
CONTRACTOR'S RIGHT TO SUSPEND WORK OR TERMINATE CONTRACT. If the work should be stopped under an order of any court or other public agency through no act or fault of the Contractor or of anyone employed by them or if the Engineer fails to issue a certificate in accordance with Section 29, in circumstances other than those in which the Engineer is entitled to withhold the certificate under this Contract, or if the Owner should fail to pay to the Contractor within ten (10) days of its maturing and presentation, any sum certified by the Engineer or awarded by arbitrators, then the Contractor may upon five (5) days written notice to the Owner and the Engineer stop work or remedy they may have, and recover from the Owner payment for all work executed and any loss sustained upon the plant or material with reasonable profit and damage.
Sample 1
CONTRACTOR'S RIGHT TO SUSPEND WORK OR TERMINATE CONTRACT. 11.1.1 The Contractor may suspend work or terminate the Contract upon fifteen (15) days written notice to the Owner for any of the following reasons: a. If the Owner fails to deliver the Project site to the Contractor within fifteen (15) days from the effectivity of the Contract; b. If the Owner fails to secure the building or construction permit within thirty (30) days from the effectivity of the Contract; c. If an order of any court or other public authority caused the Work to be stopped or suspended for an aggregate period of ninety (90) days or more through no act or fault of the Contractor or its employees; d. If the Owner fails to pay the Request for Payment or any amount due the Contractor within the prescribed period and as herein provided; e. If the Owner suspends the Work without just cause for more than an aggregate period of fifteen (15) days without the Contractor’s consent; f. If the Owner fails to deliver at the construction site the Owner-supplied construction materials and/or equipment for the scope of work along the critical path, beyond fifteen (15) days after the agreed scheduled date of delivery; and g. If the Owner fails to issue its approval of Variation Orders for additional works along the critical path, beyond fifteen (15) days after its submission. 11.1.2 If the suspension is necessary for the proper execution of the Work or by reason of weather or other conditions affecting the safety of the Works and/or the Contractor’s workers, the Contractor may request the Owner to suspend work in accordance with the applicable provisions herein provided. 11.1.3 The Contractor shall be entitled to an equitable adjustment of Completion Time and/or Contract Price for suspension of work due to the above circumstances.
Sample 1

Related to CONTRACTOR'S RIGHT TO SUSPEND WORK OR TERMINATE CONTRACT

  • Termination of the Contract 1. The Contractor may terminate the contract if the Partner has inadequately discharged or failed to discharge any of the contractual obligations, insofar as this is not due to force majeure, after notification of the Partner by registered letter has remained without effect for one month. 2. The Partner shall immediately notify the Contractor, supplying all relevant information, of any event likely to prejudice the performance of this contract.

  • License Termination Customer may terminate the license for an ICA Program at any time on one month's written notice to IBM. For ICA Program licenses that Customer acquired for a one-time charge, replacement licenses may be acquired for an upgrade charge, if available. When Customer obtains licenses for these replacement ICA Programs, Customer agrees to terminate the license of the replaced ICA Programs when charges become due, unless IBM specifies otherwise. IBM may terminate Customer’s license if Customer fails to comply with the license terms. If IBM does so, Customer’s authorization to use the ICA Program is also terminated.

  • License of Data; Warranty; Termination of Rights A. The valuation information and evaluations being provided to the Trust by USBFS pursuant hereto (collectively, the “Data”) are being licensed, not sold, to the Trust. The Trust has a limited license to use the Data only for purposes necessary to valuing the Trust’s assets and reporting to regulatory bodies (the “License”). The Trust does not have any license nor right to use the Data for purposes beyond the intentions of this Agreement including, but not limited to, resale to other users or use to create any type of historical database. The License is non-transferable and not sub-licensable. The Trust’s right to use the Data cannot be passed to or shared with any other entity. The Trust acknowledges the proprietary rights that USBFS and its suppliers have in the Data. B. THE TRUST HEREBY ACCEPTS THE DATA AS IS, WHERE IS, WITH NO WARRANTIES, EXPRESS OR IMPLIED, AS TO MERCHANTABILITY OR FITNESS FOR ANY PURPOSE OR ANY OTHER MATTER. C. USBFS may stop supplying some or all Data to the Trust if USBFS’s suppliers terminate any agreement to provide Data to USBFS. Also, USBFS may stop supplying some or all Data to the Trust if USBFS reasonably believes that the Trust is using the Data in violation of the License, or breaching its duties of confidentiality provided for hereunder, or if any of USBFS’s suppliers demand that the Data be withheld from the Trust. USBFS will provide notice to the Trust of any termination of provision of Data as soon as reasonably possible.

  • Suspension of Work and Termination 15.01 Owner May Suspend Work A. At any time and without cause, Owner may suspend the Work or any portion thereof for a period of not more than 60 consecutive days by written notice to Contractor and Engineer. Such notice will fix the date on which Work will be resumed. Contractor shall resume the Work on the date so fixed. Contractor shall be entitled to an adjustment in the Contract Price or an extension of the Contract Times, or both, directly attributable to any such suspension.

  • Licensee’s Right to Terminate Licensee may, at its option, without prejudice to any other remedies it may have, terminate this agreement by giving written notice of such termination to Licensor as follows: (a) immediately, in the event that Licensor abandons the Licensed Marks or otherwise ceases to support the Licensed Marks in Licensor's business; or (b) immediately in the event of the occurrence of a Bankruptcy with respect to Licensor; or (c) immediately in the event of an occurrence of termination pursuant to Section 13.2(d).

  • Term and Termination of Engagement; Exclusivity The term of Xxxxxxxxxx’x exclusive engagement will begin on the date hereof and end six (6) months thereafter (the “Term”). Notwithstanding anything to the contrary contained herein, the Company agrees that the provisions relating to the payment of fees, reimbursement of expenses, right of first refusal, tail, indemnification and contribution, confidentiality, conflicts, independent contractor and waiver of the right to trial by jury will survive any termination or expiration of this Agreement. Notwithstanding anything to the contrary contained herein, the Company has the right to terminate the Agreement for cause in compliance with FINRA Rule 5110(g)(5)(B)(i). The exercise of such right of termination for cause eliminates the Company’s obligations with respect to the provisions relating to the tail fees and right of first refusal. Notwithstanding anything to the contrary contained in this Agreement, in the event that an Offering pursuant to this Agreement shall not be carried out for any reason whatsoever during the Term, the Company shall be obligated to pay to Xxxxxxxxxx its actual and accountable out-of-pocket expenses related to an Offering (including the fees and disbursements of Xxxxxxxxxx’x legal counsel) and, if applicable, for electronic road show service used in connection with an Offering. During Xxxxxxxxxx’x engagement hereunder: (i) the Company will not, and will not permit its representatives to, other than in coordination with Xxxxxxxxxx, contact or solicit institutions, corporations or other entities or individuals as potential purchasers of the Securities and (ii) the Company will not pursue any financing transaction which would be in lieu of an Offering. Furthermore, the Company agrees that during Xxxxxxxxxx’x engagement hereunder, all inquiries from prospective investors will be referred to Xxxxxxxxxx. Additionally, except as set forth hereunder, the Company represents, warrants and covenants that no brokerage or finder’s fees or commissions are or will be payable by the Company or any subsidiary of the Company to any broker, financial advisor or consultant, finder, placement agent, investment banker, bank or other third-party with respect to any Offering.

  • Landlord’s Right to Terminate Landlord shall have the right to terminate this Lease in the event any of the following occurs, which right may be exercised by delivery to Tenant of a written notice of election to terminate within forty-five (45) days after the date of such damage: A. The Project is damaged by an Insured Peril to such an extent that the estimated cost to restore exceeds ten percent (10%) of the then actual replacement cost thereof, or the Building in which the Premises is located is damaged to such an extent that the estimated cost to restore exceeds twenty-five percent (25%) of the then actual replacement cost thereof; B. Either the Project or the Building is damaged by an Uninsured Peril to such an extent that the estimated cost to restore exceeds two percent (2%) of the then actual replacement cost of the Building; C. The Premises are damaged by any peril within twelve (12) months of the last day of the Lease Term to such an extent that the estimated cost to restore equals or exceeds an amount equal to six (6) times the Base Monthly Rent then due; or D. Either the Project or the Building is damaged by any peril and, because of the Laws then in force, (i) cannot be restored at reasonable cost to substantially the same condition in which it was prior to such damage, or (ii) cannot be used for the same use being made thereof before such damage if restored as required by this Article. E. As used herein, the following terms shall have the following meanings: (i) the term “Insured Peril” shall mean a peril actually insured against for which the insurance proceeds actually received by Landlord (and which are not required to be paid to any Lender) are sufficient (except for any “deductible” amount specified by such insurance) to restore the Project under then existing Laws to the condition existing immediately prior to the damage; and (ii) the term “Uninsured Peril” shall mean any peril which is not an Insured Peril. Notwithstanding the foregoing, if the “deductible” for earthquake or flood insurance exceeds two percent (2%) of the replacement cost of the improvements insured, such peril shall, at Landlord’s election, be deemed an “Uninsured Peril” for purposes of this Lease.

  • License Term and Termination Unless otherwise specified, any license granted is perpetual, provided however that if Customer fails to comply with the terms of this Agreement, HP may terminate the license upon written notice. Immediately upon termination, or in the case of a limited-term license, upon expiration, Customer will either destroy all copies of the software or return them to HP, except that Customer may retain one copy for archival purposes only.

  • TERM AND TERMINATION OF THIS AGREEMENT; NO ASSIGNMENT (a) This Agreement shall go into effect as to the Fund on the date set forth above and shall, unless terminated as hereinafter provided, continue in effect for a period of two years from the date of approval by shareholders of the Fund at a meeting called for the purpose of such approval. This Agreement shall continue in effect thereafter for additional periods not exceeding one (l) year so long as such continuation is approved for the Fund at least annually by (i) the Board of Trustees of the Trust or by the vote of a majority of the outstanding voting securities of the Fund and (ii) the vote of a majority of the Trustees of the Trust who are not parties to this Agreement nor interested persons thereof, cast in person at a meeting called for the purpose of voting on such approval. The terms “majority of the outstanding voting securities” and “interested persons” shall have the meanings as set forth in the 1940 Act; (b) This Agreement may be terminated by the Trust on behalf of the Fund at any time without payment of any penalty, by the Board of Trustees of the Trust, by the Manager, or by vote of a majority of the outstanding voting securities of a Fund without the payment of any penalties, upon sixty (60) days’ written notice to the Sub-Adviser, and by the Sub-Adviser upon sixty (60) days’ written notice to the Fund and the Manager. In the event of a termination, the Sub-Adviser shall cooperate in the orderly transfer of the Fund’s affairs and, at the request of the Board of Trustees or the Manager, transfer any and all books and records of the Fund maintained by the Sub-Adviser on behalf of the Fund; and (c) This Agreement shall terminate automatically in the event of any transfer or assignment thereof, as defined in the 1940 Act. This Agreement will also terminate in the event that the Management Agreement is terminated.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!