Damage to Work. Contractor, at its sole cost, shall be responsible for and obligated to replace, repair, or reconstruct the Work and any material, equipment, or supplies furnished for the Work which is lost, damaged or destroyed prior to transfer of care, custody and control thereof to Company however such loss shall occur. Contractor shall be responsible for repair and replacement of any of Company's other property, other than the Work covered by this Contract, which is lost, damaged, or destroyed by the act or omission of Contractor.
Damage to Work. If Construction Manager causes damage to the property of Separate Contractors or to other work or property on the Project Site, Construction Manager shall promptly remedy such damage as provided in this Agreement. If any Separate Contractor causes damage to the Work, and Construction Manager is required to remedy such damage, Owner will issue a Change Order for the cost thereof, and will further grant a Time Extension or, alternatively, Owner may direct and compensate Construction Manager for Acceleration, if the delayed activity is on the Critical Path of the Project Schedule.
Damage to Work. The sole responsibility for damage to any part the breakwater, bulkheads, docks, submerged or buried pipelines, or other structures shall be repaired at the Contractor’s expense. Except as herein provided; damage to all utilities, materials, equipment and plant shall be repaired to the satisfaction of the Contracting Officer at the Contractor's expense, regardless of the cause of such damage.
Damage to Work. .1 The Contractor shall bear all loss or damage whatsoever which may arise or occur to the Work or any portion thereof until the same are fully and finally completed and delivered to and accepted by the Owner.
Damage to Work. All loss or damage to Subcontractor’s work resulting from any cause whatsoever shall be borne by Subcontractor and shall be Subcontractor’s sole risk until final acceptance. Subcontractor shall at all times and at its expense protect all labor, materials, supplies, tools, equipment and completed work at the site against any damage, injury, destruction, theft or loss. Subcontractor shall at its expense promptly repair or replace damage to work of others, or to the Project resulting from its activities or the activities of its employees, agents or independent contractors.
Damage to Work. If a Change In Work is required pursuant to Section 16.1(f), then Contractor shall, as soon as practicable, prepare and submit to Owner a proposed Change In Work, which shall include the change in the cost of the performance of the Work and any projected modification of the Contract Price, occasioned by such Change In Work. Unless Owner does not require Contractor to repair such damaged Work, Contractor shall be entitled to a Change In Work (which, for purposes of clarity, will not be deemed an increase to the Contract Price, or a payment on account of the Contract Price (including for purposes of Section 20.2.2)) equal to the amount of insurance proceeds distributed by the applicable insurers as verified by Contractor in the applicable “proof of loss” or other form that must be executed in order to receive such proceeds; there shall be no additional monetary compensation due from Owner, and the Project Schedule shall be adjusted only if Contractor is entitled to an adjustment under Section 16.4.2. Except as set forth in the next sentence, all deductibles under the Builder’s All Risk Insurance shall be borne by the Contractor, regardless of cause. If Owner caused the loss or damage to the Insured Property, or if such loss or damage is caused by a Force Majeure Event, then Owner shall be responsible for the applicable deductible under the Builder’s All Risk Policy. If the damage to the Insured Property was caused by a Force Majeure Event which is also not a covered peril by the Builder’s All Risk Insurance, then Owner shall be responsible to pay the costs to repair such damage pursuant to the provisions of Section 16.4.2 (without markup for profit by Contractor or any of its Subcontractors (of any tier)). With the sole exception of the foregoing two sentences, Contractor acknowledges and agrees that its sole compensation for loss or damage to the Insured Property, and all increases in Contractor’s costs necessary to repair the Work resulting from such Damage and to recover from all effects to the Work resulting from such damage, shall be those proceeds obtained from the applicable insurers, and Contractor bears the risk that its coverage is reduced or denied due to the failure to abide by the terms and conditions of the policy (such as a failure to abide by the “sue and labor” requirements), or a determination is made that the loss or destruction of the Insured Property was caused by an excluded peril which would not constitute a Force Majeure Event (such a...
Damage to Work. In the event work already performed is damaged by any cause beyond Builder's control and Buyer elects to cancel the work or the work is ordered terminated by public authority, Builder shall be paid for such work, the amount agreed to in writing for such work, or if not so agreed, the cost price for such labor and materials plus 20% of such price cost. If the work is not cancelled or terminated, all work necessary to replace work already performed shall be considered additional work to be paid for by the Buyer in accordance with the preceding sentence.
Damage to Work. 15.1 All loss or damage to Subcontractor's work resulting from any cause whatsoever, unless Subcontractor provides proof that damage was caused by other jobsite Subcontractor or Contractor, shall be borne and sustained by Subcontractor and shall be solely at its risk until final acceptance by Contractor, Owner or Owner's Representative. Subcontractor shall at all times and at is sole expense fully secure and protect against any damage, injury, destruction, theft or loss, all work and all labor, materials, supplies, tools and equipment furnished by Subcontractor or its sub-subcontractors, laborers and material men. Subcontractor shall at its sole expense promptly repair or replace damage to the work of others, or to any part of the project, resulting from its activities. Subcontractor shall not travel outside the TCE's or will incur the cost for additional soil stabilization, planting, or seeding.
Damage to Work. In the event work already performed is damaged by any cause beyond RP control and Customer elects to cancel work, or the work is ordered terminated by public authority, RP shall be paid for such work the amount agreed to in writing for such work, or if not so agreed, the cost price for such labor and material plus 20% of such cost necessary to replace work already performed shall be considered additional work to be paid for by the Customer in accordance with the preceding sentence. RP is not responsible for rain damage during construction.
Damage to Work. Damage to work will not be tolerated. Any person found damaging any work, existing or new, or any materials or equipment shall be promptly removed from the Project. The subcontractor employing such person will incur the cost of repair or replacement.
