Network Maintenance and Management 38.1 The Parties will work cooperatively to implement this Agreement. The Parties will exchange appropriate information (for example, maintenance contact numbers, network information, information required to comply with law enforcement and other security agencies of the government, escalation processes, etc.) to achieve this desired result.
38.2 Each Party will administer its network to ensure acceptable service levels to all users of its network services. Service levels are generally considered acceptable only when End Users are able to establish connections with little or no delay encountered in the network. Each Party will provide a twenty four (24)-hour contact number for Network Traffic Management issues to the other’s surveillance management center.
38.3 Each Party maintains the right to implement protective network traffic management controls, such as “cancel to”, “call gapping” or seven (7)-digit and ten (10)-digit code gaps, to selectively cancel the completion of traffic over its network, including traffic destined for the other Party’s network, when required to protect the public-switched network from congestion as a result of occurrences such as facility failures, switch congestion or failure or focused overload. Each Party shall immediately notify the other Party of any protective control action planned or executed.
38.4 Where the capability exists, originating or terminating traffic reroutes may be implemented by either Party to temporarily relieve network congestion due to facility failures or abnormal calling patterns. Reroutes shall not be used to circumvent normal trunk servicing. Expansive controls shall be used only when mutually agreed to by the Parties.
38.5 The Parties shall cooperate and share pre-planning information regarding cross-network call-ins expected to generate large or focused temporary increases in call volumes to prevent or mitigate the impact of these events on the public-switched network, including any disruption or loss of service to the other Party’s End Users. Facsimile (FAX) numbers must be exchanged by the Parties to facilitate event notifications for planned mass calling events.
38.6 Neither Party shall use any Interconnection Service provided under this Agreement or any other service related thereto or used in combination therewith in any manner that interferes with or impairs service over any facilities of AT&T-21STATE, its affiliated companies or other connecting telecommunications carriers, prevents any carrier from using its Telecommunications Service, impairs the quality or the privacy of Telecommunications Service to other carriers or to either Party’s End Users, causes hazards to either Party’s personnel or the public, damage to either Party’s or any connecting carrier’s facilities or equipment, including any malfunction of ordering or billing systems or equipment. Upon such occurrence either Party may discontinue or refuse service, but only for so long as the other Party is violating this provision. Upon any such violation, either Party shall provide the other Party notice of the violation at the earliest practicable time.
38.7 AT&T TENNESSEE hereby commits to provide Disaster Recovery to CLEC according to the plan below.
38.7.1 AT&T TENNESSEE Disaster Recovery Plan
38.7.2 In the unlikely event of a disaster occurring that affects AT&T TENNESSEE’s long-term ability to deliver traffic to a CLEC, general procedures have been developed by AT&T TENNESSEE to hasten the recovery process in accordance with the Telecommunications Service Priority (TSP) Program established by the FCC to identify and prioritize telecommunication services that support national security or emergency preparedness (NS/EP) missions. A description of the TSP Program as it may be amended from time to time is available on AT&T TENNESSEE’s Wholesale – Southeast Region Web site. Since each location is different and could be affected by an assortment of potential problems, a detailed recovery plan is impractical. However, in the process of reviewing recovery activities for specific locations, some basic procedures emerge that appear to be common in most cases.
38.7.3 These general procedures should apply to any disaster that affects the delivery of traffic for an extended time period. Each CLEC will be given the same consideration during an outage, and service will be restored as quickly as possible. AT&T TENNESSEE reserves the right to make changes to these procedures as improvements become available or as business conditions dictate.
38.7.4 This plan will cover the basic recovery procedures that would apply to every CLEC.
Project Management Project Management Institute (PMI) certified project manager executing any or all of the following: • Development of Project Charter • Development of project plan and schedule • Coordination and scheduling of project activities across customer and functional areas • Consultation on operational and infrastructure requirements, standards and configurations • Facilitate project status meetings • Timely project status reporting • Address project issues with functional areas and management • Escalation of significant issues to customers and executive management • Manage project scope and deliverable requirements • Document changes to project scope and schedule • Facilitate and document project closeout
Program Management 1.1.01 Implement and operate an Immunization Program as a Responsible Entity
1.1.02 Identify at least one individual to act as the program contact in the following areas:
1. Immunization Program Manager;
Workload Management 11.1 The parties to this Agreement acknowledge that employees and management have a responsibility to maintain a balanced workload and recognise the adverse affects that excessive workloads may have on employee/s and the quality of resident/client care.
11.2 To ensure that employee concerns involving excessive workloads are effectively dealt with by Management the following procedures should be applied:
(a) Step 1: In the first instance, employee/s should discuss the issue with their immediate supervisor and, where appropriate, explore solutions.
(b) Step 2: If a solution cannot be identified and implemented, the matter should be referred to an appropriate senior manager for further discussion.
(c) Step 3: If a solution still cannot be identified and implemented, the matter should be referred to the Facility Manager for further discussion.
(d) Step 4: The outcome of the discussions at each level and any proposed solutions should be recorded in writing and fed back to the effected employees.
11.3 Workload management must be an agenda item at staff meetings on at least a quarterly basis. Items in relation to workloads must be recorded in the minutes of the staff meeting, as well as actions to be taken to resolve the workloads issue/s. Resolution of workload issues should be based on the following criteria including but not limited to:
(a) Clinical assessment of residents’ needs;
(b) The demand of the environment such as facility layout;
(c) Statutory obligation, (including, but not limited to, work health and safety legislation);
(d) The requirements of nurse regulatory legislation;
(e) Reasonable workloads (such as roster arrangements);
(f) Accreditation standards; and
(g) Budgetary considerations.
11.4 If the issue is still unresolved, the employee/s may advance the matter through Clause 9 Dispute Resolution Procedure. Arbitration of workload management issues may only occur by agreement of the employer and the employee representative, which may include the union/s.
Change Management BellSouth provides a collaborative process for change management of the electronic interfaces through the Change Control Process (CCP). Guidelines for this process are set forth in the CCP document as amended from time to time during this Agreement. The CCP document may be accessed via the Internet at xxxx://xxx.xxxxxxxxxxxxxxx.xxxxxxxxx.xxx.
Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
Contract Management To ensure full performance of the Contract and compliance with applicable law, the System Agency may take actions including:
a. Suspending all or part of the Contract;
b. Requiring the Grantee to take specific corrective actions in order to remain in compliance with term of the Contract;
c. Recouping payments made to the Grantee found to be in error;
d. Suspending, limiting, or placing conditions on the continued performance of the Project;
e. Imposing any other remedies authorized under this Contract; and
f. Imposing any other remedies, sanctions or penalties permitted by federal or state statute, law, regulation, or rule.
Corporate Governance Matters (a) Holdco and Sorin shall take all actions within their power as may be necessary to cause (i) for a period beginning as of the Cyberonics Merger Effective Time and ending on the date of the first annual meeting of the members of Holdco following the completion of the second full fiscal year of Holdco (such period, the “Initial Period”) the number of directors constituting the Holdco board of directors as of the Effective Times to be nine (9) and (ii) the Holdco board of directors during the Initial Period to be composed as follows: (A) four (4) individuals designated by Cyberonics prior to the Closing Date (each, a “Cyberonics Designee”), (B) four individuals designated by Sorin prior to the Closing Date (each, a “Sorin Designee”) and (C) one (1) director mutually agreed to by Sorin and Cyberonics, who shall meet the independence standards of the NASDAQ applicable to non-controlled domestic U.S. issuers.
(b) Sorin and Holdco shall take all corporate actions as may be necessary to cause, effective as of the Sorin Merger Effective Time and Cyberonics Merger Effective Time, as the case may be: (i) the Chief Executive Officer of Sorin as of immediately prior to the Sorin Merger Effective Time to serve as the Chief Executive Officer of the Sorin Merger Surviving Company immediately following the Sorin Merger Effective Time until the end of the Initial Period, (ii) the Chief Executive Officer of Cyberonics as of immediately prior to the Cyberonics Merger Effective Time to serve as the Chairman of the Holdco board of directors for the Initial Period, (iii) a Cyberonics Designee to serve as the Chairman of the audit and compensation committees of the Holdco board of directors for the Initial Period, (iv) each committee of the Holdco board of directors to have at least three (3) members and (v) a Sorin Designee to serve as a member of each committee of the Holdco board of directors during the Initial Period.
(c) For as long as the Holdco Shares are listed on the NASDAQ, Holdco shall comply with all NASDAQ corporate governance standards set forth in Rule 5600 of the NASDAQ Stock Market Rules applicable to non-controlled domestic U.S. issuers, regardless of whether Holdco is a foreign private issuer. For as long as the Holdco Shares are listed on the LSE, Holdco shall comply with all Listing Rules and any other Laws applicable to it.
(d) Prior to the Closing Date, Sorin and Holdco shall procure the passing of resolutions of the shareholders of Holdco providing for the reregistration of Holdco as a public limited company.
(e) Subject to applicable Law, Sorin and Cyberonics shall take all requisite action to cause the organizational documents of those entities that will be Subsidiaries of Holdco to be substantially in such form as agreed by Cyberonics and Sorin, effective as of the Cyberonics Merger Effective Time.
(f) As promptly as practicable after the Effective Times, the Sorin Merger Surviving Company shall take all requisite action to cause the composition of the board of directors or other governing body of each of the Subsidiaries of the Sorin Merger Surviving Company to reflect representation by directors designated by Cyberonics immediately prior to the Effective Times, on the one hand, and directors designated by Sorin immediately prior to the Effective Times, on the other hand, that is proportionate to the relative representation of directors designated by such party on the Holdco board of directors as of the Effective Times as provided in Section 5.18(a), unless otherwise mutually agreed by Sorin and Cyberonics.
(g) The Cyberonics Designees, the Sorin Designees and each of their respective successors on the Holdco board of directors during the first three (3) years following the Effective Times are express third-party beneficiaries of Sections 5.18(a) and 5.18(b).
Quality Management Grantee will:
1. comply with quality management requirements as directed by the System Agency.
2. develop and implement a Quality Management Plan (QMP) that conforms with 25 TAC § 448.504 and make the QMP available to System Agency upon request. The QMP must be developed no later than the end of the first quarter of the Contract term.
3. update and revise the QMP each biennium or sooner, if necessary. Xxxxxxx’s governing body will review and approve the initial QMP, within the first quarter of the Contract term, and each updated and revised QMP thereafter. The QMP must describe Xxxxxxx’s methods to measure, assess, and improve -
i. Implementation of evidence-based practices, programs and research-based approaches to service delivery;
ii. Client/participant satisfaction with the services provided by Xxxxxxx;
iii. Service capacity and access to services;
iv. Client/participant continuum of care; and
v. Accuracy of data reported to the state.
4. participate in continuous quality improvement (CQI) activities as defined and scheduled by the state including, but not limited to data verification, performing self-reviews; submitting self-review results and supporting documentation for the state’s desk reviews; and participating in the state’s onsite or desk reviews.
5. submit plan of improvement or corrective action plan and supporting documentation as requested by System Agency.
6. participate in and actively pursue CQI activities that support performance and outcomes improvement.
7. respond to consultation recommendations by System Agency, which may include, but are not limited to the following:
i. Staff training;
ii. Self-monitoring activities guided by System Agency, including use of quality management tools to self-identify compliance issues; and
iii. Monitoring of performance reports in the System Agency electronic clinical management system.
Classroom Management The certificated classroom teacher demonstrates in his/her performance a competent level of knowledge and skill in organizing the physical and human elements in the educational setting.
