Department of Justice Xxxx X. Xxxxxxx Student Loan Repayment Program (JRJSLRP) Service Agreement – Secondary Term of Service NAME: In consideration of the student loan repayment incentive for which I may qualify under 34 U.S.C. §10671, such incentive having been offered above and beyond the incentive(s) from which I have already benefitted from in exchange for a term of service that I have fulfilled, I hereby agree as follows:
Office of Justice Programs The Provider must report suspected fraud, waste and abuse to the OAG’s Office of the Inspector General at 000-000-0000.
ENVIRONMENTAL PROTECTION STANDARDS CONTRACTOR shall be in compliance with the Clean Air Act (Title 42 USC Section 7401 et seq.), the Clean Water Act (Title 33 USC Section 1251 et seq.), Executive Order 11738 and Environmental Protection Agency, hereinafter referred to as “EPA,” regulations (Title 40 CFR), as any may now exist or be hereafter amended. Under these laws and regulations, CONTRACTOR assures that:
Department Liaison In performing the Services provided for in this Agreement, Contractor’s liaison with the [insert name of department] will be [insert name of contact person in department].
ENVIRONMENT, SAFETY AND HEALTH PROTECTION (a) Seller shall perform this Agreement in a manner that ensures adequate protection for workers, the public, and the environment, and shall be accountable for actions of itself and its lower-tier subcontractors, agents and employees. Seller shall exercise a degree of care commensurate with the work and the associated hazards. Seller shall ensure that management of environment, safety and health (ES&H) functions and activities is an integral and visible part of Seller’s work planning and execution process. In the event that Xxxxxx fails to comply with this Agreement, Company may, without prejudice to any other legal or contractual rights, issue an order stopping all or any part of the work; thereafter a start order for resumption of work may be issued at Company’s discretion. Seller shall make no claim for an extension of time or for compensation or damages by reason of or in connection with such work stoppage. In addition, Company may require, in writing, that Seller remove from the work any employee the Company deems unsafe, incompetent, careless, or otherwise objectionable.
Environmental Protection Except as set forth in Schedule 5.13 annexed hereto:
Agreement Administration and Communications A. Under this Agreement, either of the representatives of the Judicial Council identified below will monitor the Work and act as the Judicial Council’s liaisons with the Contractor:
Environmental Justice Executive Order 12898 of February 11, 1994—Federal Actions to Address Environmental Justice in Minority Populations and Low-Income Populations, (59 FR 7629), 3 C.F.R., 1994 Comp. p. 859.
CONTRACTOR California Department of General Services Use Only CONTRACTOR’S NAME (if other than an individual, state whether a corporation, partnership, etc.) BY (Authorized Signature) DATE SIGNED (Do not type) PRINTED NAME AND TITLE OF PERSON SIGNING ADDRESS STATE OF CALIFORNIA AGENCY NAME BY (Authorized Signature) DATE SIGNED (Do not type) PRINTED NAME AND TITLE OF PERSON SIGNING Exempt per: ADDRESS Exhibit A Project Summary & Scope of Work
Legal Protection 7.14.1 The University shall provide legal representation to any Member of the Bargaining Unit who is named a defendant in a civil action based on performance of the Member’s duties within the scope of employment. Legal representation will be at the Member’s request, subject to the approval of the Ohio Attorney General and in accordance with Ohio law. Pursuant to Ohio Revised Code Section 9.87 the University shall seek indemnification from the state for liability or judgment of any Member of the Bargaining Unit resulting from the performance of his or her duties for the University. Nothing in this Section is intended to expand or conflict with current Ohio law.