DETECTION OF DEFECTS. If the purchaser detects a defect within the warranty periods defined in Section 5.1.1, it shall promptly notify the Dealer representative. Within five (5) working days after receipt of notification, Dealer representative shall either agree that the defect is in fact covered by the “complete vehicle” warranty, or reserve judgment until the subsystem or component is inspected by Dealer's representative and/or is removed and examined at the purchaser’s property or at the Contractor’s facility. At that time, the status of warranty coverage, either subsystem or vehicle, shall be mutually resolved between the purchaser and Dealer. If the defect belongs to a subsystem or component, then work necessary to affect the repairs defined in Section 5.1.2 shall commence within ten (10) working days after receipt of notification by Dealer. Otherwise, Section 5.1.1 applies and repairs will be started immediately.

DETECTION OF DEFECTS. The Consumer is obliged to conduct an acceptance inspection for the faultless quality of the Product. If, in the Consumer's opinion, there is a defect in the Product, the defective Product must not be installed. The Consumer shall immediately or within a maximum period of two (2) months from the date when the Guaranteed Defect was found, notify the Supplier (see Supplier contact details at the end of the Guarantee) of the Guaranteed Defect in writing attaching the following: (a) The original purchase invoice or other proof of purchase (b) A list of the number of pieces and the size of each piece for which the claim is made (c) Pictures showing the issue of damage from all angles and pictures of entire deck overview The Consumer has also the obligation to retain the defective Product, prevent further damage and give the Supplier and/or the Manufacturer an occasion to inspect the Product. It is the Consumer's duty to prove that the Product is defective and the defect is regarded as Guaranteed Defect.

DETECTION OF DEFECTS. (1) If the Authority detects a defect within a warranty period as defined herein, it shall promptly notify the Contractor. (2) The warranty shall not apply to Contractor-furnished consumables, such as filters, seat cushions, or brakes shoes, unless the Defect is due to defective manufacture or workmanship of the consumable; or to items furnished by the Authority, except insofar as such an item is damaged by a Defect in a Unit for which the Contractor is responsible.

DETECTION OF DEFECTS. The Consumer is obliged to conduct an acceptance inspection for the faultless quality of the Product. If, in the Consumer's opinion, there is a defect in the Product, the defective Product must not be installed. The Consumer shall immediately or within a maximum period of two (2) months from the date when the Guaranteed Defect was found, notify the Supplier (see Supplier contact details at the end of the Guarantee) of the Guaranteed Defect in writing attaching the following: (a) The original purchase invoice or other proof of purchase as well as an acceptance report for the installer services (b) A list of the number of pieces and the size of each piece for which the claim is made (c) Pictures showing the issue of damage from all angles and pictures of entire deck overview (d) Batch / pack number and distinct production code from the products‘ groove (if available) The Consumer has also the obligation to retain the defective Product, prevent further damage and give the Supplier and/or the Manufacturer an occasion to inspect the Product. It is the Consumer's duty to prove that the Product is defective and the defect is regarded as Guaranteed Defect.

DETECTION OF DEFECTS. If the SFMTA detects a defect within the warranty periods defined in Section a, it shall notify the Proposer's representative within a reasonable time after discovery of the defect. Within three working days after receipt of notification, the Contractor's representative shall either agree that the defect is in fact covered by warranty, or reserve judgment until the subsystem or component is inspected by the Contractor's representative or is removed and examined at the SFMTA property or at the Contractor 's plant. At that time the status of warranty coverage on the subsystem or component shall be mutually resolved between the SFMTA and the Proposer. Work necessary to commence the inspection or repairs, under the provisions of Section 5, Repair Procedures, shall commence within two working days after receipt of notification by the Contractor, unless such time is extended by the SFMTA, and shall be conducted in accordance with Section 5.a, Repairs by Contractor. Specific detail about a manufacturer repair shall be reported to the SFMTA within 24 hours of said repair. If the SFMTA and Contractor are unable to agree whether a defect is covered by the warranty provisions, the SFMTA may direct the Contractor to commence repairs in accordance with Section 5.a, Repairs by Contractor, pending agreement by the SFMTA and Proposer whether the repairs are covered by the warranty provisions. The Proposer shall promptly comply with such a request by the SFMTA.

DETECTION OF DEFECTS. If the SFMTA detects a Defect within the warranty period, it shall within 20 working days, notify the Contractor's representative. Within 10 working days after receipt of notification, the Contractor's representative shall either agree that the Defect is in fact covered by warranty, or reserve judgment until the subsystem or component is inspected by the Contractor's representative or is removed and examined at the SFMTA's property or at the Contractor's plant. At that time, the status of warranty coverage on the subsystem or component shall be mutually resolved between the SFMTA and the Contractor.

Related to DETECTION OF DEFECTS

Correction of Defects 35.1 The Engineer shall give notice to the Contractor of any Defects before the end of the Defects Liability Period, which begins at Completion and is defined in the Contract Data. The Defects Liability Period shall be extended for as long as Defects remain to be corrected. 35.2 Every time notice of a Defect is given, the Contractor shall correct the notified Defect within the length of time specified by the Engineer’s notice.
REMEDY OF DEFECTS (a) The BUILDER shall remedy, at its expense, any defects, against which the VESSEL is guaranteed under this Article, by making all necessary repairs or replacements at the SHIPYARD or elsewhere as provided for in (b) hereinbelow. In such case, the VESSEL shall be taken at the BUYER's cost and responsibility to the place selected, ready in all respects for such repairs or replacements and in any event, the BUILDER shall not be responsible for towage, dockage, wharfage, port charges and anything else incurred for the BUYER's getting and keeping the VESSEL ready for such repairing or replacing. (b) However, if it is impractical (which shall include, but not be limited to, an emergency) to bring the VESSEL to the SHIPYARD, the BUYER may cause the necessary repairs or replacements to be made elsewhere which is deemed by the BUYER with the consent of the BUILDER which shall not be unreasonably withheld, to be suitable for the purpose, provided that, in such event, the BUILDER may forward or supply replacement parts or materials under the terms described in (c) hereinbelow, unless forwarding or supplying thereof under the terms described in (c) hereinbelow would impair or delay the operation or working schedule of the VESSEL. In the event that the BUYER proposes to cause the necessary repairs or replacements to be made to the VESSEL at any shipyard or works other than the SHIPYARD, the BUYER shall first (but in all events as soon as reasonably possible) give the BUILDER notice by email or facsimile of the time and place such repairs will be made, and if the VESSEL is not thereby delayed, or her operation or working schedule is not thereby impaired, the BUILDER shall have the right to verify by its own representative(s) the nature and extent of the defects complained of. The BUILDER shall, in such case, promptly advise the BUYER by email or facsimile, after such examination has been completed, of its acceptance or rejection of the defects as ones that are covered by the guarantee herein provided. Upon the BUILDER's acceptance of the defects as justifying remedy under this Article, or upon award of the arbitration so determining, the BUILDER shall compensate the BUYER an amount equal to the reasonable cost of making the same repairs or replacements at the SHIPYARD. (c) In the event that it is necessary for the BUILDER to forward a replacement for a defective part under this guarantee, replacement parts shall be shipped to the BUYER under the C.I.F terms to the BUYER's nominated port. The BUILDER reserves the option to retrieve, at the BUILDER's cost, any of the replaced equipment/parts in case defects are remedied in accordance with the provisions in this Article. (d) Any dispute under this Article shall be referred to arbitration in accordance with the provisions of Article XIII hereof.
Latent Defects Notwithstanding anything to the contrary set forth herein, no acceptance, or deemed acceptance, by City pursuant to this Section shall be applicable with respect to any Latent Defects. An acceptance, or deemed acceptance, by City pursuant to this Section shall not mean that City has accepted, or the other party has been relieved of, responsibility for: (i) compliance with the Laws; (ii) the proper application of construction means or methods; or (iii) correcting any portion of the Project if it later is determined that any portion of the Project is inconsistent with the Final Documents and Drawings.
Notice of Defects If, based on Consulting Engineer/Architect's involvement during the construction phase, Consulting Engineer/Architect observes or otherwise becomes aware of any defect in the work, he shall give prompt written notice to City of such defects and their approximate location on the Project. However, Consulting Engineer/Architect shall not have control over or charge of and shall not be responsible for construction means, methods, techniques, sequences or procedures, or for safety precautions, inspections and programs in connection with the work, since these are solely the contractor's responsibility under the contract for construction. Consulting Engineer/Architect shall not be responsible for the contractor's schedules or failure to carry out the work in accordance with the Contract Documents. Consulting Engineer/Architect shall not have control over or charge of acts or omissions of the contractor, contractor's subcontractors, or their agents or employees.
Correction of Errors Contractor shall perform, at its own cost and expense and without reimbursement from the District, any work necessary to correct errors or omissions which are caused by the Contractor’s failure to comply with the standard of care required herein.
Defects a. The Customer shall inspect the Goods upon delivery and will, within 48 hours, notify the Company of any defects, short deliveries or any failure to fulfill any quotation or order. b. The Customer will, within a reasonable time following delivery, grant the Company access to the Goods in order to inspect for any alleged defects. c. Should the Customer fail to notify the Company within the specified period then the Goods shall be deemed to be in compliance with the order and free from any defect whatsoever.
Inspection and Rejection of Nonconforming Goods The Buyer has the right to inspect the Goods on or after the Delivery Date. Buyer, at its sole option, may inspect all or a sample of the Goods, and may reject all or any portion of the Goods if it determines the Goods are nonconforming or defective. If Buyer rejects any portion of the Goods, Buyer has the right, effective upon written notice to Seller, to: (a) rescind the Order in its entirety; (b) accept the Goods at a reasonably reduced price; or (c) reject the Goods and require replacement of the rejected Goods. If Buyer requires replacement of the Goods, Seller shall, at its expense, promptly replace the nonconforming Goods and pay for all related expenses, including, but not limited to, transportation charges for the return of the defective goods and the delivery of replacement Goods. If Seller fails to timely deliver replacement Goods, Buyer may replace them with goods from a third party and charge Seller the cost thereof and terminate this Order for cause pursuant to Section 19. Any inspection or other action by Buyer under this Section shall not reduce or otherwise affect Seller's obligations under the Order, and Buyer shall have the right to conduct further inspections after Seller has carried out its remedial actions.
Destruction of Data Provider shall destroy or delete all Personally Identifiable Data contained in Student Data and obtained under the DPA when it is no longer needed for the purpose for which it was obtained or transfer said data to LEA or LEA’s designee, according to a schedule and procedure as the parties may reasonable agree. Nothing in the DPA authorizes Provider to maintain personally identifiable data beyond the time period reasonably needed to complete the disposition.
Destruction or Damage (a) If the Building or the Premises are totally destroyed by storm, fire, earthquake, or other casualty, or damaged to the extent that, in Landlord's reasonable opinion the damage cannot be restored within one hundred eighty (180) days of the date Landlord provides Tenant written notice of Landlord's reasonable estimate of the time necessary to restore the damage, or if the damage is not covered by standard "all risks" property insurance and as a result Landlord elects not to restore such damage, Landlord or Tenant shall have the right to terminate this Lease effective as of the date of such destruction or damage by written notice to the other on or before thirty (30) days following Landlord's notice described in the next sentence and Rent shall be accounted for as between Landlord and Tenant as of that date. Landlord shall provide Tenant with notice within forty-five (45) days following the date of the damage of the estimated time needed to restore, and whether the loss is covered by Landlord's insurance coverage (and if not, whether Landlord nevertheless elects to restore). (b) If the Premises are damaged by any such casualty or casualties but neither party is entitled to or neither party elects to terminate this Lease as provided in subparagraph (a) above, this Lease shall remain in full force and effect, Landlord shall notify Tenant in writing within forty-five (45) days of the date of the damage that the damage will be restored (and will include Landlord's good faith estimate of the date the restoration will be complete), in which case Rent shall xxxxx as to any portion of the Premises which is not usable, and Landlord shall restore the Premises to substantially the same condition as before the damage occurred as soon as practicable, whereupon full Rent shall recommence.
Failure to Respond If you fail to respond by the date given above, your application will be refused under Section 3A(4)(a) of the Registered Designs Act 1949.

DETECTION OF DEFECTS Sample Clauses

Filter & Search

Related Clauses

Parent Clauses

Related to DETECTION OF DEFECTS