Development of a Standard Connection Agreement Sample Clauses

Development of a Standard Connection Agreement. The Australian Greenhouse Office has provided funding for development of a standard connection agreement template for small (less than 10 kVA) renewable energy systems throughout Australia. This agreement need not be mandatory but would help simplify the grid-connection process for all concerned by providing greater certainty regarding performance, timing and costs. The project extends work carried out by Coelacanth Consulting (now Greenwatt Pty Limited) and the Australian CRC for Renewable Energy (ACRE) Energy Policy Group (known as AEPG). Coelacanth Consulting produced the report Metering of embedded generators in Australia for the Australian Greenhouse Office in October 2001 (Roche, 2001). The AEPG work involved contacting a range of stakeholders including DNSPs, electricity retailers, system owners and system installers, for background information regarding development of a standard connection agreement (Xxxxxx et al., 2002). The process of developing a standard connection agreement has been divided into two stages, the first of which is summarised in this report. The first stage involved surveying DNSPs and electricity retailers regarding agreements they currently use, and the processes they follow for approving grid connection of small systems. Surveys were sent by email, and late responders were sent at least three follow-up emails, before being 2 Independent Pricing and Regulatory Tribunal (IPART) in NSW; Essential Services Commission (ESCOSA) in South Australia; Essential Services Commission (VESC) in Victoria; Independent Competition and Regulatory Commission (ICRC) in the ACT; Office of the Tasmanian Energy Regulator (OTER); Utilities Commission in the Northern Territory; Queensland Competition Authority (QCA). offered the opportunity to provide input directly by phone. Input was also sought from system owners, the Office of the Renewable Energy Regulator and the Australian Taxation Office. This discussion paper summarises the survey results, highlights and discusses the main issues raised, and recommends how these issues should be addressed. In the second and final stage, the responses from stakeholders to the formal discussion paper will be used to propose a standard connection agreement template. This template will be made publicly available for use by DNSPs, electricity retailers, system installers and system owners. A Final Report will summarise the overall project and its outcomes.
Sample 1
AutoNDA by SimpleDocs

Related to Development of a Standard Connection Agreement

  • Development Agreement As soon as reasonably practicable following the ISO’s selection of a transmission Generator Deactivation Solution, the ISO shall tender to the Developer that proposed the selected transmission Generator Deactivation Solution a draft Development Agreement, with draft appendices completed by the ISO to the extent practicable, for review and completion by the Developer. The draft Development Agreement shall be in the form of the ISO’s Commission-approved Development Agreement for its reliability planning process, which is in Appendix C in Section 31.7 of Attachment Y of the ISO OATT, as amended by the ISO to reflect the Generator Deactivation Process. The ISO and the Developer shall finalize the Development Agreement and appendices as soon as reasonably practicable after the ISO’s tendering of the draft Development Agreement. For purposes of finalizing the Development Agreement, the ISO and Developer shall develop the description and dates for the milestones necessary to develop and construct the selected project by the required in-service date identified in the Generator Deactivation Assessment, including the milestones for obtaining all necessary authorizations. Any milestone that requires action by a Connecting Transmission Owner or Affected System Operator identified pursuant to Attachment P of the ISO OATT to complete must be included as an Advisory Milestone, as that term is defined in the Development Agreement. If the ISO or the Developer determines that negotiations are at an impasse, the ISO may file the Development Agreement in unexecuted form with the Commission on its own, or following the Developer’s request in writing that the agreement be filed unexecuted. If the Development Agreement is executed by both parties, the ISO shall file the agreement with the Commission for its acceptance within ten (10) Business Days after the execution of the Development Agreement by both parties. If the Developer requests that the Development Agreement be filed unexecuted, the ISO shall file the agreement at the Commission within ten (10) Business Days of receipt of the request from the Developer. The ISO will draft, to the extent practicable, the portions of the Development Agreement and appendices that are in dispute and will provide an explanation to the Commission of any matters as to which the parties disagree. The Developer will provide in a separate filing any comments that it has on the unexecuted agreement, including any alternative positions it may have with respect to the disputed provisions. Upon the ISO’s and the Developer’s execution of the Development Agreement or the ISO’s filing of an unexecuted Development Agreement with the Commission, the ISO and the Developer shall perform their respective obligations in accordance with the terms of the Development Agreement that are not in dispute, subject to modification by the Commission. The Connecting Transmission Owner(s) and Affected System Operator(s) that are identified in Attachment P of the ISO OATT in connection with the selected transmission Generator Deactivation Solution shall act in good faith in timely performing their obligations that are required for the Developer to satisfy its obligations under the Development Agreement.

  • Interconnection Agreement On or before December 31, 2015, Wholesale Market Participant must enter into an Interconnection Agreement with the Transmission Owner in order to effectuate the WMPA. Wholesale Market Participant shall demonstrate the occurrence of each of the foregoing milestones to Transmission Provider’s reasonable satisfaction. Transmission Provider may reasonably extend any such milestone dates, in the event of delays that Wholesale Market Participant (i) did not cause and (ii) could not have remedied through the exercise of due diligence. If (i) the Wholesale Market Participant suspends work pursuant to a suspension provision contained in an interconnection and/or construction agreement with the Transmission Owner or (ii) the Transmission Owner extends the date by which Wholesale Market Participant must enter into an interconnection agreement relative to this WMPA, and (iii) the Wholesale Market Participant has not made a wholesale sale under this WMPA, the Wholesale Market Participant may suspend this WMPA by notifying the Transmission Provider and the Transmission Owner in writing that it wishes to suspend this WMPA, with the condition that, notwithstanding such suspension, the Transmission System shall be left in a safe and reliable condition in accordance with Good Utility Practice and Transmission Provider’s safety and reliability criteria. Wholesale Market Participant’s notice of suspension shall include an estimated duration of the suspension period and other information related to the suspension. Pursuant to this section 3.1, Wholesale Market Participant may request one or more suspensions of work under this WMPA for a cumulative period of up to a maximum of three years. If, however, the suspension will result in a Material Modification as defined in Part I, Section 1.18A.02 of the Tariff, then such suspension period shall be no greater than one (1) year. If the Wholesale Market Participant suspends this WMPA pursuant to this Section 3.1 and has not provided written notice that it will exit such suspension on or before the expiration of the suspension period described herein, this WMPA shall be deemed terminated as of the end of such suspension period. The suspension time shall begin on the date the suspension is requested or on the date of the Wholesale Market Participant’s written notice of suspension to Transmission Provider, if no effective date was specified. All milestone dates stated in this Section 3.1 shall be deemed to be extended coextensively with any suspension period permitted pursuant to this provision.

  • Framework Agreement 4.1.2.1 The Parties shall enter into a Framework Agreement within 28 days after the Contractor receives the Letter of Acceptance, unless the Particular Conditions establish otherwise. The Framework Agreement shall be based upon FORM No. 3 – FRAMEWORK AGREEMENT annexed to the Particular Conditions. The costs of stamp duties and similar charges (if any) imposed by law in connection with entry into the Framework Agreement shall be borne by the Procuring Entity.

  • COMMENCEMENT OF WORK UNDER A SOW AGREEMENT Commencement of work as a result of the SOW-RFP process shall be initiated only upon issuance of a fully executed SOW Agreement and Purchase Order.

  • Cooperation Agreement At the Closing, PCC and Buyer shall, and PCC shall cause PCC Parent to, execute and deliver the Cooperation Agreement pursuant to which Buyer, PCC Parent and PCC shall provide each other certain information and other assistance in connection with the collection, administration and/or satisfaction of certain of the Retained Liabilities.

  • PROCUREMENT OF AGREEMENT CONSULTANT represents and warrants that no person or selling agent has been employed or retained by CONSULTANT to solicit or secure this Agreement upon an agreement or upon an understanding for a commission, percentage, a brokerage fee, contingent fee or any other compensation. CONSULTANT further represents and warrants that no payment, gift or thing of value has been made, given or promised to obtain this or any other agreement between the parties. CONSULTANT makes such representations and warranties to induce the COUNTY to enter into this Agreement and the COUNTY relies upon such representations and warranties in the execution hereof. For a breach or violation of such representations or warranties, the COUNTY shall have the right to annul this Agreement without liability, entitling the COUNTY to recover all monies paid hereunder and CONSULTANT shall not make claim for or be entitled to recover, any sum or sums otherwise due under this Agreement. This remedy, if effected, shall not constitute the sole remedy afforded the COUNTY for such falsity or breach, not shall it constitute a waiver of the COUNTY’s right to claim damages or otherwise refuse payment or to take any other action provided for by law or pursuant to this Agreement.

  • Project Agreement (a) Subsequent to the establishment of a Cooperative Agreement pursuant to § 81.3, the Secretary may further agree with the States to provide xxxxx- cial assistance in the development and implementation of acceptable projects for the conservation of endangered and threatened species. Financial agree- ments will consist of an Application for Federal Assistance and a Project Agreement. Such agreements’ contin- ued existence, and continued financial assistance under such agreements, shall be contingent upon the continued existence of the Cooperative Agree- ment described in § 81.3 of this part.

  • Construction Documents Phase Services 3.4.1 Based on the Owner’s approval of the Design Development Documents, and on the Owner’s authorization of any adjustments in the Project requirements and the budget for the Cost of the Work, the Architect shall prepare Construction Documents for the Owner’s approval. The Construction Documents shall illustrate and describe the further development of the approved Design Development Documents and shall consist of Drawings and Specifications setting forth in detail the quality levels and performance criteria of materials and systems and other requirements for the construction of the Work. The Owner and Architect acknowledge that, in order to perform the Work, the Contractor will provide additional information, including Shop Drawings, Product Data, Samples and other similar submittals, which the Architect shall review in accordance with Section 3.6.4.

  • FRAMEWORK AGREEMENT MANAGEMENT The Parties shall manage this Framework Agreement in accordance with Schedule 14 (Framework Management).

  • Statement of Work The Contractor shall provide the services and staff, and otherwise do all things necessary for or incidental to the performance of work, as set forth below:

Time is Money Join Law Insider Premium to draft better contracts faster.