Weather Conditions In the event of temporary suspension of work or during inclement weather or whenever the OWNER shall direct, the CONSTRUCTION MANAGER will, and will cause its Subcontractors to protect carefully its and their work and material against damage or injury from the weather. If, in the opinion of the OWNER, any Work or material shall have been damaged or injured by reason of failure on the part of the CONSTRUCTION MANAGER or any of its Subcontractors so to protect his work, said materials shall be removed and replaced at the expense of the CONSTRUCTION MANAGER.
Adverse Weather Conditions Except in emergency situations, the Employer shall not require an employee:
INCLEMENT CONDITIONS Section 1.
Inclement Weather 24.1 This Inclement Weather clause sets out the full rights, obligations and entitlements of the parties and establishes the conditions under which payment for periods of inclement weather shall be made.
Inclement Weather Days Employees shall not report to work when schools are closed for inclement weather. In an emergency situation (e.g. Board packet day) when an inclement weather closing occurs, an employee(s) may be called in to work if there is a supervisor present in the work location. Said employee(s) shall receive compensatory time off for the time worked.
Subsurface Conditions Unless the Contract Documents stipulate specific quantities and units of rock or unsuitable soils, the Contractor shall assume material below the surface of the Earth to be earth and other material that can be removed by power shovel or similar equipment. Should conditions encountered below the surface of the ground be at variance to the number of unit requirements as indicated by drawings or specifications, and absent an agreed-upon unit price established prior to the bid by Addendum, or after contract execution by Change Order, the Contract Sum and/or time shall be adjusted as provided in the Contract Documents for changes in the work.
Weather 6.1 No extension of time shall be granted for delays resulting from normal weather conditions prevailing in the area as defined by the average of the last ten years of weather data as recorded by the U.S. Department of Commerce, National Oceanic and Atmospheric Administration at the Fort Lauderdale Weather Station.
Emergency Conditions “Emergency Condition” shall mean a condition or situation: (1) that in the judgment of the Party making the claim is imminently likely to endanger life or property; or (2) that, in the case of the Transmission Provider, is imminently likely (as determined in a non-discriminatory manner) to cause a material adverse effect on the security of, or damage to the Transmission System, the Transmission Owner’s Interconnection Facilities or the Transmission Systems of others to which the Transmission System is directly connected; or (3) that, in the case of the Interconnection Customer, is imminently likely (as determined in a non-discriminatory manner) to cause a material adverse effect on the security of, or damage to, the Small Generating Facility or the Interconnection Customer’s Interconnection Facilities. Under Emergency Conditions, the Transmission Owner may immediately suspend interconnection service and temporarily disconnect the Small Generating Facility. The Transmission Provider shall notify the Interconnection Customer promptly when it becomes aware of an Emergency Condition that may reasonably be expected to affect the Interconnection Customer’s operation of the Small Generating Facility. The Interconnection Customer shall notify the Transmission Provider promptly when it becomes aware of an Emergency Condition that may reasonably be expected to affect the Transmission Owner’s Transmission System or other Affected Systems. To the extent information is known, the notification shall describe the Emergency Condition, the extent of the damage or deficiency, the expected effect on the operation of both Parties’ facilities and operations, its anticipated duration, and the necessary corrective action.
Emergency/Declared Disaster Requirements In the event of an emergency or if Orange County is declared a disaster area by the County, state or federal government, this Contract may be subjected to unusual usage. The Contractor shall service the County during such an emergency or declared disaster under the same terms and conditions that apply during non-emergency/disaster conditions. The pricing quoted by the Contractor shall apply to serving the County’s needs regardless of the circumstances. If the Contractor is unable to supply the goods/services under the terms of the Contract, then the Contractor shall provide proof of such disruption and a copy of the invoice for the goods/services from the Contractor’s supplier(s). Additional profit margin as a result of supplying goods/services during an emergency or a declared disaster shall not be permitted. In the event of an emergency or declared disaster, emergency purchase order numbers will be assigned. All applicable invoices from the Contractor shall show both the emergency purchase order number and the Contract number.
Unsafe Conditions In accordance with 29 CFR § 1977, occasions might arise when an employee is confronted with a choice between not performing assigned tasks or subjecting himself/herself to serious injury or death arising from a hazardous condition at the workplace. If the employee, with no reasonable alternative, refuses in good faith to expose himself/herself to the dangerous condition, he/she would be protected against subsequent discrimination. The condition causing the employee's apprehension of death or injury must be of such a nature that a reasonable person, under the circumstances then confronting the employee, would conclude that there is a real danger of death or serious injury and that there is insufficient time, due to the urgency of the situation, to eliminate the danger by resorting to regular statutory enforcement channels. In addition, in such circumstances, the employee, where possible, must also have sought from his Employer, and been unable to obtain, a correction of the dangerous condition.
