Extensions of Time for Performance Sample Clauses

Extensions of Time for Performance. (a) Upon satisfaction of the provisions of paragraph (b) of this Section, neither the City nor the Developer nor any successor in interest shall be considered in breach or default of their respective obligations under this Agreement, and times for performance of obligations hereunder shall be extended in the event of any delay caused by force majeure, including, without limitation, damage or destruction by fire or casualty; strike; lockout; civil disorder; acts of terrorism; significant escalation of hostilities involving U.S. armed forces; lack of issuance of any permits and/or legal authorization by the governmental entity necessary for the applicable Developer to proceed with construction of the applicable portion of the Work, including rezoning and approval of the Concept Site Plan for the D3 Components (but only if the Developer files all necessary documentation relating thereto in a timely manner considering the dates set forth in Section 3.3 of this Agreement); shortage or delay in shipment of material or fuel; acts of God; unusually adverse weather or wet soil conditions; or other causes beyond the reasonable control of the party required to perform, including, but not limited to, any litigation, court order or judgment resulting from any litigation affecting the validity of the Redevelopment Plan, the Redevelopment Project, the TIF Obligations, this Agreement or any other litigation that adversely affects the development of the Redevelopment Project. Notwithstanding the foregoing, the parties agree that economic conditions, market conditions, financial conditions, lender restrictions, lack of tenant interest, and similar conditions or events do not constitute events of force majeure hereunder. The parties further agree that, to the best of their knowledge, no event of force majeure exists at the time of execution of this Agreement.
Sample 1
AutoNDA by SimpleDocs
Extensions of Time for Performance. (a) Upon satisfaction of the provisions of paragraph (b) of this Section, neither the City nor the Developer nor any successor in interest shall be considered in breach or default of their respective obligations under this Agreement, and times for performance of obligations hereunder shall be extended in the event of any delay caused by force majeure, including, without limitation, damage or destruction by fire or casualty; strike; lockout; civil disorder; war; restrictive government regulations; lack of issuance of any permits and/or legal authorization by the governmental entity necessary for the Developer to proceed with construction of the Work or any portion thereof, including rezoning and approval of the Concept Site Plan (but only if the Developer files all necessary documentation relating thereto in a timely manner in accordance with the time specified in Section 3.5 of this Agreement); shortage or delay in shipment of material or fuel; acts of God; unusually adverse weather or wet soil conditions; or other causes beyond the parties’ reasonable control, including but not limited to, any litigation, court order or judgment resulting from any litigation affecting the validity of the Redevelopment Plan, the Redevelopment Project or the TIF Obligations, this Agreement, or eminent domain actions.
Sample 1
Extensions of Time for Performance. Notwithstanding anything to the contrary herein, the Contractor may request (in writing) reasonable extensions of time for completion of the Site Survey, Initial Design, Permits and Interconnection Filing and Approvals, Final Design, Installation and Commissioning, and Final PV System Acceptance testing, Commissioning and Timely Completion phases (as described above in Sections 4(b) and (c) above) of the Initial Period, which the Host in its reasonable sole discretion can approve or disapprove. Host shall exercise its reasonable discretion to approve or disapprove without undue delay following Contractor’s request but in any event within five (5) Business Days. Any extension granted by Host hereunder must be in writing and shall extend the Initial Period by the same amount of time as agreed-upon by Host and Contractor.
Sample 1
Extensions of Time for Performance. Notwithstanding anything to the contrary contained in this Agreement, neither party shall be deemed to be in default where delays and performance or failure to perform are due to war, insurrection, strike or other labor disturbances, walkouts, riots, floods, earthquakes, fires, casualties, acts of God, extended appeals by third parties or similar basis for excused performance which are not within the reasonable control of the party to be excused. Upon the request of either party, an extension of time for such cause shall be granted in writing for the period of the forced delay, or longer, as may be mutually agreed upon.
Sample 1

Related to Extensions of Time for Performance

  • Extensions of Time 34.1 If at any time during performance of the Contract, the Supplier or its subcontractors should encounter conditions impeding timely delivery of the Goods or completion of Related Services pursuant to GCC Clause 13, the Supplier shall promptly notify the Procuring Entity in writing of the delay, its likely duration, and its cause. As soon as practicable after receipt of the Supplier's notice, the Procuring Entity shall evaluate the situation and may at its discretion extend the Supplier's time for performance, in which case the extension shall be ratified by the parties by amendment of the Contract.

  • DELAYS AND EXTENSIONS OF TIME 8.3.1 If the Contractor is delayed at any time in the progress of the Work by any act or failure to act by the State or the Architect, or by any employee of either, or by any separate contractor employed by the State, or by changes ordered in the Work, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, or any causes beyond the Contractor's control, or by delay authorized by the State pending alternative dispute resolution proceedings, or by any other cause which may justify the delay, then the Contract Time shall be extended by Change Order for such reasonable time as recommended by the Architect and approved by the State.

  • Extensions and Renewals All extensions or renewals of leaves shall be applied for and granted in writing.

  • Extension of Time Limits The time limits referred to in this Article may be extended by mutual agreement of the parties in writing.

  • Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely:

  • Calculation of Time Periods Unless otherwise specified, in computing any period of time described in this Agreement, the day of the act or event after which the designated period of time begins to run is not to be included and the last day of the period so computed is to be included, unless such last day is a Saturday, Sunday or legal holiday under the laws of the State in which the Property is located, in which event the period shall run until the end of the next day which is neither a Saturday, Sunday or legal holiday. The final day of any such period shall be deemed to end at 5 p.m., local time.

  • No Extension of Time If the Owner’s determination proves valid that good cause existed to believe a violation had occurred, the Contractor is not entitled to an extension of time for any delay arising directly or indirectly from the arbitration procedures set forth herein.

  • Extension of Time If the Executive shall be in violation of any provision of this Article 6, then each time limitation set forth in this Article 6 shall be extended for a period of time equal to the period of time during which such violation or violations occur. If the Company seeks injunctive relief from such violation in any court, then the covenants set forth in this Article 6 shall be extended for a period of time equal to the pendency of such proceeding including all appeals by the Executive.

  • OBLIGATIONS OF THE CONTRACTOR AND SURETY The Contractor and the Surety, in consideration of the award of this Contract to the Contractor, jointly and severally for themselves, their heirs, executors, administrators, and successors or assigns, hereby guarantee, covenant and agree to and with the Owner that:

  • Computation of Time Periods In this Agreement in the computation of periods of time from a specified date to a later specified date, the word “from” means “from and including” and the words “to” and “until” each mean “to but excluding”.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!