Initial Notice to Proceed Sample Clauses

Initial Notice to Proceed. After the Agreement has been fully executed by the Contractor and the City, the City shall issue the “Notice to Proceed to Fulfill Preconstruction Requirements.” The date specified in the Notice to Proceed to Fulfill Preconstruction Requirements constitutes the date of commencement of the Contract Time of Sixty (60) Working Days. The Contract Time includes the time necessary to fulfill preconstruction requirements and to complete construction of the Project (except as adjusted by subsequent Change Orders). The Notice to Proceed to Fulfill Preconstruction Requirements shall further specify that Contractor must complete the preconstruction requirements within Ten (10) Working Days after the date of commencement of the Contract Time; this duration is part of the Contract Time. Preconstruction requirements include, but are not limited to, the following: • Submitting and obtaining approval of Traffic Control Plans • Submitting and obtaining approval of the Stormwater Pollution Prevention Plan (SWPPP)/Water Pollution Control Plan (WPCP) • Submitting and obtaining approval of critical required submittals • Installation of the approved Project Identification Signs • Obtaining an approved no fee Encroachment Permit • Obtaining a Temporary Use Permit for a construction yard • Notifying all agencies, utilities, residents, etc., as outlined in the Contract Documents If the City’s issuance of a Notice to Proceed to Fulfill Preconstruction Requirements is delayed due to Contractor’s failure to return the fully executed Agreement and insurance and bond documents within ten (10) Working Days after Contract award, then Contractor agrees to the deduction of one (1) Working Day from the number of days to complete the Project for every Working Day of delay in the City’s receipt of said documents. This right is in addition to and does not affect the City’s right to demand forfeiture of Contractor’s Bid Security if Contractor persistently delays in providing the required documentation.
Sample 1Sample 2See All (8)
AutoNDA by SimpleDocs
Initial Notice to Proceed. Execution of this Agreement by Owner constitutes Notice to Proceed with design and Construction Document preparation.
Sample 1Sample 2Sample 3See All (6)
Initial Notice to Proceed. After the Agreement has been fully executed by the Contractor and the City, the City shall issue the “Notice to Proceed to Fulfill Preconstruction Requirements and Notice to Proceed with Order of Materials.” The date specified in the Notice to Proceed to Fulfill Preconstruction Requirements and Notice to Proceed with Order of Materials constitutes the date of commencement of the Contract Time of Ninety (90)
Sample 1
Initial Notice to Proceed. After the Agreement has been fully executed by the Contractor and the City, the City shall issue the “Notice to Proceed to Fulfill Preconstruction Requirements and Notice to Proceed with Order of Materials.” The date specified in the Notice to Proceed to Fulfill Preconstruction Requirements and Notice to Proceed with Order of Materials constitutes the date of commencement of the Contract Time of One Hundred Twenty (120) Working Days. The Contract Time includes the time necessary to fulfill preconstruction requirements, place the order of materials, and to complete construction of the Project (except as adjusted by subsequent Change Orders).
Sample 1
Initial Notice to Proceed. After the Agreement has been fully executed by the Contractor and the City, the City shall issue the “Notice to Proceed to Fulfill Preconstruction Requirements and Notice to Proceed with Order of Materials.” The date specified in the Notice to Proceed to Fulfill Preconstruction Requirements and Notice to Proceed with Order of Materials constitutes the date of commencement of the Contract Time of One Hundred Fifteen (115) Working Days for the Base Bid only, and up to One Hundred Fifty-Five (155) Working Days for Base Bid plus Alternate Bids (1, 4, 5 and 7). The Contract Time includes the time necessary to fulfill preconstruction requirements, place the order of materials, and to complete construction of the Project (except as adjusted by subsequent Change Orders).
Sample 1
Initial Notice to Proceed. By execution of this Sub-Agreement, the VPA provides Notice to Proceed for the Work identified in §§ 3.1.2 and 5.1, and Articles 7 and 8.
Sample 1
Initial Notice to Proceed. Execution of this Agreement by Owner constitutes Notice to Proceed with design and Construction Document preparation. No construction Work may be performed by or through Contractor except pursuant to a Notice to Proceed with construction issued by the Owner’s Representative. The Contractor shall: Commence Work under this Agreement within ten (10) days after the date it receives the Notice to Proceed from the Owner’s Representative, Prosecute the Work diligently, and Substantial Completion of the Building complete the construction Work not later than (May 31, 2026). Some Work (preliminary site work, demolition, Shop Drawings, fabrication, general conditions work, etc.) may have to be performed prior to the full commencement of construction. The time stated for completion includes cleanup of the site. Contractor shall achieve Final Completion as soon as possible but not later than ninety (90) calendar days after Substantial Completion of the Project. At the time of receipt of the building permit and monthly thereafter, Contractor shall consult with the Owner’s Representative with regard to the likely Substantial Completion of the Building Date and earlier occupancy dates so as to allow the Owner to plan its move.
Sample 1
AutoNDA by SimpleDocs

Related to Initial Notice to Proceed

  • Notice to Proceed Work shall not commence on this Project until the Director has issued a written Notice to Proceed to the Recipient. Such Notice will not be issued until the Director is assured that the Recipient has complied with the Recipient's responsibilities concerning OEPA plan approval, when applicable. A Notice to Proceed shall be required for all project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.

  • Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.

  • STOP WORK NOTICE The City may issue an immediate Stop Work Notice in the event the Contractor is observed performing in a manner that is in violation of Federal, State, or local guidelines, or in a manner that is determined by the City to be unsafe to either life or property. Upon notification, the Contractor will cease all work until notified by the City that the violation or unsafe condition has been corrected. The Contractor shall be liable for all costs incurred by the City as a result of the issuance of such Stop Work Notice.

  • Notice to Proceed - Land Acquisition The acquisition of the Land shall not occur until the Director has issued a written Notice to Proceed for land acquisition to the Recipient (the "Notice to Proceed"). Such Notice to Proceed will not be issued until the Director has received a Request to Proceed acceptable to the Director and is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and any requirements for land acquisition set forth in this Agreement, including without limitation the OPWC's approval of the proposed Deed Restrictions and Title Agent. The Notice to Proceed also shall specify the time frame for the Closing.

  • Effectiveness and Events Requiring Notice to the Representative The Company will use its best efforts to cause the Registration Statement to remain effective and will notify the Representative immediately and confirm the notice in writing: (i) of the effectiveness of the Registration Statement and any amendment thereto; (ii) of the issuance by the Commission of any stop order suspending the effectiveness of the Registration Statement or any post-effective amendment thereto or preventing or suspending the use of any Preliminary Prospectus or the Prospectus or of the initiation, or the threatening, of any proceeding for that purpose; (iii) of the issuance by any foreign or state securities commission of any proceedings for the suspension of the qualification of the Public Securities for offering or sale in any jurisdiction or of the initiation, or the threatening, of any proceeding for that purpose; (iv) of the mailing and delivery to the Commission for filing of any amendment or supplement to the Registration Statement or Prospectus; (v) of the receipt of any comments or request for any additional information from the Commission; and (vi) of the happening of any event that, in the reasonable judgment of the Company, makes any statement of a material fact made in the Registration Statement or the Prospectus untrue or that requires the making of any changes in the Registration Statement or the Prospectus in order to make the statements therein, and in light of the circumstances under which they were made, not misleading. If the Commission or any foreign or state securities commission shall enter a stop order or suspend such qualification at any time, the Company will make every reasonable effort to obtain promptly the lifting of such order.

  • Initial Contract Term The Initial Contract Term shall be for two years. The Initial Contract Term shall begin on October 1, 2021, or on the last date the Contract is signed by all Parties, whichever is later. The Contract shall expire on October 1, 2023, unless terminated earlier in accordance with the Special Contract Conditions or Additional Special Contract Conditions.

  • Effectiveness and Events Requiring Notice to the Underwriters The Company will use its best efforts to cause the Registration Statement to remain effective with a current prospectus until the later of nine (9) months from the Execution Date and the date on which the Warrants are no longer outstanding, and will notify the Underwriters and holders of the Warrants immediately and confirm the notice in writing: (i) of the effectiveness of the Registration Statement and any amendment thereto; (ii) of the issuance by the Commission of any stop order or of the initiation, or the threatening, of any proceeding for that purpose; (iii) of the issuance by any state securities commission of any proceedings for the suspension of the qualification of the Securities for offering or sale in any jurisdiction or of the initiation, or the threatening, of any proceeding for that purpose; (iv) of the mailing and delivery to the Commission for filing of any amendment or supplement to the Registration Statement or Prospectus; (v) of the receipt of any comments or request for any additional information from the Commission; and (vi) of the happening of any event during the period described in this Section 4.4 that, in the judgment of the Company, makes any statement of a material fact made in the Registration Statement or the Prospectus untrue or that requires the making of any changes in the Registration Statement or the Prospectus in order to make the statements therein, in light of the circumstances under which they were made, not misleading. If the Commission or any state securities commission shall enter a stop order or suspend such qualification at any time, the Company will make every reasonable effort to obtain promptly the lifting of such order.

  • Notice to FINRA For a period of ninety (90) days after the date of the Prospectus, in the event any person or entity (regardless of any FINRA affiliation or association) is engaged, in writing, to assist the Company in its search for a Target Business or to provide any other services in connection therewith, the Company will provide the following to FINRA and the Representative prior to the consummation of the Business Combination: (i) complete details of all services and copies of agreements governing such services; and (ii) justification as to why the person or entity providing the merger and acquisition services should not be considered an “underwriter and related person” with respect to the Offering, as such term is defined in Rule 5110 of the FINRA Manual. The Company also agrees that, if required by law, proper disclosure of such arrangement or potential arrangement will be made in the tender offer documents or proxy statement which the Company will file with the Commission in connection with the Business Combination.

  • Project Closeout a. Participate in final inspection to prepare punch lists for project contractor to correct and/or to complete listed items. Verify that items on punch lists have been completed successfully assist COUNTY Project Manager or designee to determine completion date and coordinate project close out. a. Coordinate the preparation, acceptance and distribution of project closeout documents in accordance with COUNTY Project Manager or designee procedures to clients.

  • Effectiveness and Events Requiring Notice to the Representatives The Company will use its best efforts to cause the Registration Statement to remain effective and will notify the Representatives immediately and confirm the notice in writing: (i) of the effectiveness of the Registration Statement and any amendment thereto; (ii) of the issuance by the Commission of any stop order suspending the effectiveness of the Registration Statement or any post-effective amendment thereto or preventing or suspending the use of any Preliminary Prospectus or the Prospectus or of the initiation, or the threatening, of any proceeding for that purpose; (iii) of the issuance by any foreign or state securities commission of any proceedings for the suspension of the qualification of the Public Securities for offering or sale in any jurisdiction or of the initiation, or the threatening, of any proceeding for that purpose; (iv) of the mailing and delivery to the Commission for filing of any amendment or supplement to the Registration Statement or Prospectus; (v) of the receipt of any comments or request for any additional information from the Commission; and (vi) of the happening of any event that, in the reasonable judgment of the Company, makes any statement of a material fact made in the Registration Statement or the Prospectus untrue or that requires the making of any changes in the Registration Statement or the Prospectus in order to make the statements therein, and in light of the circumstances under which they were made, not misleading. If the Commission or any foreign or state securities commission shall enter a stop order or suspend such qualification at any time, the Company will make every reasonable effort to obtain promptly the lifting of such order.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!