Landlord Delay Landlord’s (a) failure to comply with any time requirements expressly set forth in Paragraph 2.d. above with respect to Landlord’s obligation to provide notice of approval or disapproval of the Space Plan, Working Drawings or Change Orders, or (b) Landlord’s unreasonable interference with the completion of Tenant Improvements, including any failure or refusal of Landlord or Landlord’s agents or contractors to permit Tenant, its agents or contractors, access to and use of the Building or any Building facilities or services (including hoists, elevators, and loading docks) which access or use is reasonably required for the orderly and continuous performance of the work necessary to complete Tenant Improvements, are referred to collectively herein as “Landlord Delay” (provided that no Landlord Delay as described in clause (b) above will be deemed to have occurred unless and until Tenant has notified Landlord of the event which Tenant claims constitutes a Landlord Delay and Landlord has failed to cure such event within five (5) Business Days thereafter). Tenant will use commercially reasonable efforts to mitigate its damages and/or construction delays in the event of an alleged Landlord Delay. Notwithstanding anything to the contrary in this Paragraph 2, if and to the extent Tenant reasonably incurs a net increased cost (taking into account any cost saving Landlord might have facilitated by its actions, including any Landlord Delay) of design or construction of the Tenant Improvements as a direct result of any Landlord Delay (as reasonably evidenced by Tenant, with supporting documentation), Landlord will be responsible for such reasonable increased costs and Landlord’s Allowance will be increased by the amount of such reasonable increased cost. Further, when determining whether a particular Landlord Delay delayed Substantial Completion of the Tenant Improvements, the subject Landlord Delay shall be offset by any action or response by Landlord that achieved a reduction in Tenant’s construction schedule (each day saved in Tenant’s construction schedule being a “Schedule Saving Day”) and any aggregate Landlord Delay as described in this Paragraph 2.f. shall first be offset against, and reduced on a day-for-day basis by, the aggregate number of Schedule Saving Days. In the event of a disagreement between Landlord and Tenant as to whether a Landlord Delay has occurred and/or as to the application of this grammatical paragraph, either party may submit the issue to the dispute resolution procedure set forth in Paragraph 2.j. below. This Paragraph 2.f. is inapplicable to delays in Delivery, whether caused by Landlord, Landlord’s Contractor or otherwise (such delays being expressly covered by Paragraph 2.a. above) and this Paragraph 2.f. only applies to delays in the commencement or Substantial Completion of the Tenant Improvements following Delivery.
Tenant Estoppels (a) Each Seller shall prepare and deliver to each Tenant at such Seller’s Property an estoppel certificate in the form of Exhibit A attached hereto (the “Tenant Estoppel”) and request each such Tenant to execute and deliver the Tenant Estoppel to such Seller. Each Seller shall use commercially reasonable efforts to obtain the prompt return of the executed Tenant Estoppels in substantially the same form as Exhibit A attached hereto from each Tenant at such Seller’s Property prior to the Closing, without the obligation to make any payments or grant any concessions under the Leases. If a Tenant returns an executed Tenant Estoppel (or Lease Required Estoppel or Statement of Lease as defined below) to such Seller, such Seller shall promptly deliver to the Buyer, or make available on Seller’s transaction website, a copy of such executed Tenant Estoppel (or Lease Required Estoppel or Statement of Lease, if applicable) following such Seller’s receipt of such Tenant Estoppel (or Lease Required Estoppel or Statement of Lease, if applicable).
Landlord Waiver Coast shall have received duly executed
Landlord Repairs Notwithstanding anything contrary herein, Landlord shall repair, replace and restore the foundation, exterior and interior load-bearing walls, roof structure and roof covering and tuckpointing of the Property; provided, however, that (i) all costs and expenses so incurred by Landlord to repair, replace and restore the above items shall constitute Operating Expenses; provided, however, that with respect to any costs incurred in the replacement context, those costs shall not constitute an Operating Expense except to the extent that such costs so qualify under SECTION 3.1.1(vii); and (ii) notwithstanding (i) above, in the event that any such repair, replacement or restoration is necessitated by any or all of the matters set forth in SECTIONS 13.1(a) through (d) above (collectively, "TENANT NECESSITATED REPAIRS"), then Tenant shall be required to reimburse Landlord for all costs and expenses that Landlord incurs in order to perform such Tenant Necessitated Repairs, and such reimbursement shall be paid, in full, within 10 days after Landlord's delivery of demand therefor. Landlord agrees to commence the repairs, replacements or restoration described in this SECTION 13.2 within a reasonable period of time after receiving from Tenant written notice of the need for such repairs.
Tenant Estoppel Certificates (a) Seller agrees from and after receipt of the Assumption Approval as set forth in Section 9.1 and provided this Agreement is in full force and effect, within five (5) business days after being requested by Purchaser to do so, to deliver to all tenants of the Property a request for an estoppel certificate in the form of EXHIBIT D attached hereto, which form may be revised if so requested by the Existing Lender. The parties agree that, subject to the provisions of subparagraph (b) below, it shall be a condition to Purchaser's obligation to close under this Agreement that an estoppel certificate either substantially in the form of EXHIBIT D or in the form required by a tenant's Lease, dated not earlier than ten (10) business days prior to the Closing Date, be delivered to Purchaser no later than five (5) business days before Closing from tenants under the Leases occupying, in the aggregate, not less than 75% of the rentable area of the Property, including all tenants occupying at least a full floor or more of space (a "TENANT ESTOPPEL"), Seller agrees to use good faith efforts to obtain such Tenant Estoppels, provided however, Seller shall not be obligated to pay tenants in order to do so. Notwithstanding the foregoing, if at Closing Seller delivers such Tenant Estoppels from tenants occupying at least 60% of the rentable area of the Property, Seller may execute and deliver to Purchaser, at Closing, its own certificate with respect to tenants occupying up to an additional 15% of the rentable area of the Property (substantially in the form of EXHIBIT D or in the form required by a tenant's Lease, appropriately modified to reflect that they are certificates of Seller and made to Seller's knowledge; hereinafter, the "SELLER'S ESTOPPEL CERTIFICATE") and the statements of Seller contained therein shall survive the Closing until the earlier of (a) one hundred and eighty (180) days after Closing, or (b) the date Purchaser obtains an estoppel certificate from a tenant for whom Seller delivered a Seller's Estoppel Certificate.
TENANT'S ESTOPPEL CERTIFICATE From time to time, upon written request of Landlord, Tenant shall execute, acknowledge and deliver to Landlord or its designee, a written certificate stating (a) the date this Lease was executed, the Commencement Date of the Term and the date the Term expires; (b) the date Tenant entered into occupancy of the Premises; (c) the amount of Rent and the date to which such Rent has been paid; (d) that this Lease is in full force and effect and has not been assigned, modified, supplemented or amended in any way (or, if assigned, modified, supplemented or amended, specifying the date and terms of any agreement so affecting this Lease); (e) that this Lease represents the entire agreement between the parties with respect to Tenant’s right to use and occupy the Premises (or specifying such other agreements, if any); (f) that all obligations under this Lease to be performed by Landlord as of the date of such certificate have been satisfied (or specifying those as to which Tenant claims that Landlord has yet to perform); (g) that all required contributions by Landlord to Tenant on account of Tenant’s improvements have been received (or stating exceptions thereto); (h) that on such date there exist no defenses or offsets that Tenant has against the enforcement of this Lease by Landlord (or stating exceptions thereto); (i) that no Rent or other sum payable by Tenant hereunder has been paid more than one (1) month in advance (or stating exceptions thereto); (j) that a currently valid Letter of Credit has been deposited with Landlord, stating the original amount thereof and any increases or decreases thereto; and (k) any other matters evidencing the status of this Lease that may be required either by a lender making a loan to Landlord to be secured by a deed of trust covering the Building or the Project or by a purchaser of the Building or the Project. Any such certificate delivered pursuant to this Paragraph 30 may be relied upon by a prospective purchaser of Landlord’s interest or a mortgagee of Landlord’s interest or assignee of any mortgage upon Landlord’s interest in the Premises. If Tenant shall fail to provide such certificate within ten (10) days of receipt by Tenant of a written request by Landlord as herein provided, such failure shall, at Landlord’s election, constitute a Default under this Lease, and Tenant shall be deemed to have given such certificate as above provided without modification and shall be deemed to have admitted the accuracy of any information supplied by Landlord to a prospective purchaser or mortgagee.
Landlord’s Option to Repair Notwithstanding the terms of Section 11.1 of this Lease, Landlord may elect not to rebuild and/or restore the Premises, Building and/or Project, in which event this Lease shall terminate, by notifying Tenant in writing of such termination within sixty (60) days after the date of discovery of the damage, such notice will include a termination date giving Tenant sixty (60) days to vacate the Premises, but this Lease may be so terminated Landlord may so elect only if the Building or Project shall be damaged by fire or other casualty or cause, whether or not the Premises are affected, and one or more of the following conditions is present: (i) in Landlord’s reasonable judgment, repairs cannot reasonably be completed within one hundred eighty (180) days after the date of discovery of the damage (when such repairs are made without the payment of overtime or other premiums); (ii) the holder of any mortgage on the Building or Project or ground lessor with respect to the Building or Project shall require that the insurance proceeds or any portion thereof be used to retire the mortgage debt, or shall terminate the ground lease, as the case may be; (iii) the damage is not fully covered by Landlord’s insurance policies or that portion of the proceeds from Landlord’s insurance policies allocable to the Building or the Project, as the case may be; (iv) Landlord decides to rebuild the Building or Common Areas so that they will be substantially different structurally or architecturally; (v) the damage occurs during the last twelve (12) months of the Lease Term; or (vi) any owner of any other portion of the Project, other than Landlord, does not intend to repair the damage to such portion of the Project; provided, however, that if such fire or other casualty shall have damaged the Premises or a portion thereof or Common Areas necessary to Tenant’s occupancy and as a result of such damage the Premises are unfit for occupancy, and provided that Landlord does not elect to terminate this Lease pursuant to Landlord’s termination right as provided above, and either (a) the repairs cannot, in the reasonable opinion of Landlord’s contractor, be completed within two hundred seventy (270) days after being commenced, or (b) the damage occurs during the last twelve months of the Lease Term and will reasonably require in excess of ninety (90) days to repair, Tenant may elect, no earlier than sixty (60) days after the date of the damage and not later than ninety (90) days after the date of such damage, to terminate this Lease by written notice to Landlord effective as of the date specified in the notice, which date shall not be less than thirty (30) days nor more than sixty (60) days after the date such notice is given by Tenant.
Landlord Work In accordance with the mutually acceptable space plan dated January 4, 2012 prepared by Xxxxxxxx Xxxx Xxxxxxx Architects (the “Approved Plan”) attached hereto, Landlord shall perform the following work (collectively, the “Landlord Work”): · Build out 4 offices · Install a door to connect Suites 205 and 230 · Provide appropriate surfaces and air handling · Investigate the addition of an 8’ hood in lab Landlord shall cause the Landlord Landlord shall use commercially reasonable efforts to cause the Landlord Work to be constructed in a good and workmanlike manner, substantially in accordance with the Approved Plan and in compliance with applicable laws and covenants, conditions and restrictions in effect as of the date of such completion, and in good condition and working order. The Landlord Work shall be performed by Landlord, at Landlord’s sole cost and expense. Tenant shall have the right, on not less than two (2) business days’ advance written notice to Landlord, and, if specified by Landlord at Landlord’s option, accompanied by a representative of Landlord, to inspect the construction of the Landlord Work; provided that no such inspections shall interfere with or otherwise delay Landlord’s completion of the Landlord Work. Tenant shall have the right to submit to Landlord a list of incomplete or defective items within sixty (60) days after Substantial Completion, and Landlord shall diligently repair or replace such items at Landlord’s sole cost and expense. Landlord shall use commercially reasonable efforts to cause its construction contract for the Landlord Work to contain a minimum one (1) year warranty period. EXHIBIT C ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE THIS ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE is entered into as of [ ], 2012, with reference to that certain Lease dated as of August 24, 2007, as amended by that certain First Amendment to Lease dated as of March 30, 2008, that certain Second Amendment to Lease (“Second Amendment”) dated as of May 11, 2009, which Second Amendment was amended and restated pursuant to that certain Amended and Restated Second Amendment to Lease dated as of September 15, 2009, and that certain Third Amendment to Lease dated as of December [ ], 2011 (“Third Amendment”) (collectively, and as the same may have been further amended, amended and restated, supplemented or modified from time to time, the “Lease”), by RECEPTOS, INC., a Delaware corporation (“Tenant”), in favor of BMR-10835 ROAD TO THE CURE LLC, a Delaware limited liability company (“Landlord”). All capitalized terms used herein without definition shall have the meanings ascribed to them in the Lease. Tenant hereby confirms the following:
Landlord's Waivers Any lessor of Tenant's Personal Property may, upon notice to Landlord and during reasonable hours, enter the Property and take possession of any of Tenant's Personal Property without liability for trespass or conversion upon a default by Tenant, provided that such lessor provide Landlord with the opportunity to cure the defaults of Tenant on terms and conditions satisfactory to such lessor and Landlord.
Landlord’s Repairs Landlord, as an Operating Expense, shall maintain all of the structural, exterior, parking and other Common Areas of the Project, including HVAC, plumbing, fire sprinklers, elevators and all other building systems serving the Premises and other portions of the Project (“Building Systems”), in good repair, reasonable wear and tear and uninsured losses and damages caused by Tenant, or by any of Tenant’s agents, servants, employees, invitees and contractors (collectively, “Tenant Parties”) excluded. Losses and damages caused by Tenant or any Tenant Party shall be repaired by Landlord, to the extent not covered by insurance, at Tenant’s sole cost and expense. Landlord reserves the right to stop Building Systems services when necessary (i) by reason of accident or emergency, or (ii) for planned repairs, alterations or improvements, which are, in the judgment of Landlord, desirable or necessary to be made, until said repairs, alterations or improvements shall have been completed. Landlord shall have no responsibility or liability for failure to supply Building Systems services during any such period of interruption; provided, however, that Landlord shall, except in case of emergency, make a commercially reasonable effort to give Tenant 24 hours advance notice of any planned stoppage of Building Systems services for routine maintenance, repairs, alterations or improvements. Tenant shall promptly give Landlord written notice of any repair required by Landlord pursuant to this Section, after which Landlord shall make a commercially reasonable effort to effect such repair. Landlord shall not be liable for any failure to make any repairs or to perform any maintenance unless such failure shall persist for an unreasonable time after Tenant’s written notice of the need for such repairs or maintenance. Tenant waives its rights under any state or local law to terminate this Lease or to make such repairs at Landlord’s expense and agrees that the parties’ respective rights with respect to such matters shall be solely as set forth herein. Repairs required as the result of fire, earthquake, flood, vandalism, war, or similar cause of damage or destruction shall be controlled by Section 18.
