Shift Workers All shift workers (i.e. workers whose shift commences at or after the end of the ordinary day work hours) presenting for work when the temperature is at or over 35°C will remain on site in air conditioned amenities for a minimum two hours, holding themselves available to commence work should the temperature fall below 35°C.
Shiftworkers 35.1 Shiftworker for the purposes of this clause is defined as an Employee who performs Shiftwork and who starts or finishes a shift outside of the ordinary hours set out at clause 34.2 above.
35.2 A Shiftworker shall be paid at the rate of double time for all hours worked.
35.3 An Employee who has to work Shiftwork shall be given at least 48 hours of notice of the requirements to work shift work.
Independent Contractor; Workers’ Compensation Insurance The Contractor is performing as an independent entity under this Contract. No part of this Contract shall be construed to represent the creation of an employment, agency, partnership or joint venture agreement between the parties. Neither party will assume liability for any injury (including death) to any persons, or damage to any property, arising out of the acts or omissions of the agents, employees or subcontractors of the other party. The Contractor shall provide all necessary unemployment and workers’ compensation insurance for the Contractor’s employees, and shall provide the State with a Certificate of Insurance evidencing such coverage prior to starting work under this Contract.
Workers' Compensation Leave A. When an injury is determined to be job related in accordance with Article XII, a regular, limited-term or probationary employee shall be placed on Workers'
Workers’ Compensation The Contractor acknowledges the State of California requires every employer to be insured against liability for workers’ compensation or to undertake self-insurance in accordance with the provisions of the Labor Code. If Contractor has employees, a copy of the certificate evidencing such insurance, a letter of self-insurance, or a copy of the Certificate of Consent to Self-Insure shall be provided to County prior to commencement of work.
Labor Harmony The parties acknowledge that it is of the utmost importance to City, Tenant, and all those occupying or to occupy space in the Domestic and International Terminals that there be no interruption in the progress of the construction work. Accordingly, City and Tenant agree as follows:
(a) In any contract or undertaking which Tenant may make with a contractor for work in the Premises, provision shall be made for the dismissal from the job of workmen whose work is unskilled or otherwise objectionable, in the Director’s (and, for this purpose, “the Director” shall include a reference to the Airport’s Architect) reasonable judgment. Tenant shall cause any such workmen to be discharged from the project within twenty-four (24) hours after Director shall give notice to Tenant requiring such discharge.
(b) Tenant shall use, and Tenant shall require its contractor and subcontractors to use, their respective best efforts to prevent work stoppages on the Premises, and/or elsewhere on the Airport, to the extent attributable to work being performed on the Premises, irrespective of the reason of any such stoppage. In the event that the conduct or presence of any employee(s) of Tenant or Tenant’s contractor(s) or subcontractor(s) causes a labor dispute or work stoppage, Tenant shall have such employee(s) immediately removed from the Airport upon Director’s request.
(c) Tenant shall include, and shall cause its contractor to include, the following clause in all contracts with its general contractors and subcontractors: There shall be no manifestations on the project of any dispute between any labor organization and any Tenant contractor or subcontractor, including but not limited to, any area standards picketing against said contractor or subcontractor. Should there be any manifestation of a labor dispute between any Tenant contractor or subcontractor and any union, which results in a stoppage of work on the part of said contractor or subcontractor’s employees or the employees of any other employer or supplier on the project or at the Airport, which in the sole judgment of the Director will cause, or is likely to cause, unreasonable delay in the progress of construction or operation of any business at the Airport, then upon written notice from Director, Tenant shall declare the contractor or subcontractor in default of its contract, and upon such notice, Tenant shall have the right to take such steps as are necessary to finish the uncompleted portion of the work to be performed by the contractor or subcontractor.
(d) Without limiting the generality of indemnities elsewhere in this Lease, Tenant shall indemnify, defend, and hold harmless City and each City Entity for any and all Losses which arise from the actions taken pursuant to this Section 7.9.
Coordination with Workers' Compensation When an employee has incurred an on-the- job injury or an on-the-job disability and has filed a claim for workers' compensation, medical costs connected with the injury or disability shall be paid by the employee's health plan, pursuant to M.S. 176.191, Subdivision 3.
Workers' compensation and employer's liability insurance endorsements The following are required:
(i) CANCELLATION endorsement which provides that the District is entitled to 30 days prior written notice of cancellation or nonrenewal of the policy, or reduction in coverage, by certified mail, return receipt requested.
(ii) WAIVER OF SUBROGATION endorsement which provides that the insurer will waive its right of subrogation against the District, its Trustees, and their officials, employees, volunteers, and agents with respect to any losses paid under the terms of the workers' compensation and employer's liability insurance policy which arise from work performed by the Named Insured for the District.
Industrial Relations Training Leave Union Delegate/Employee Representative shall have access to industrial relations training in accordance with Appendix E hereof.
Workers’ Compensation Claims The Responding Member is responsible for providing worker’s compensation benefits and administering worker’s compensation for its employees. The Requesting Member is responsible for providing worker’s compensation benefits and administering worker’s compensation for its employees.
