Maintenance Program LESSEE's Maintenance Program
Maintenance Programme (i) The Contractor shall prepare a monthly maintenance programme (the “Maintenance Programme”) in consultation with the Authority’s Engineer and submit the same to the Authority’s Engineer not later than 10 (ten) days prior to the commencement of the month in which the Maintenance is to be carried out. For this purpose a joint monthly inspection by the Contractor and the Authority’s Engineer shall be undertaken. The Maintenance Programme shall contain the following:
(a) The condition of the road in the format prescribed by the Authority’s Engineer;
(b) the proposed maintenance Works; and
(c) deployment of resources for maintenance Works.
Maintenance, Etc The Company will maintain, preserve and keep, and will cause each Consolidated Subsidiary to maintain, preserve and keep, its properties which are used in the conduct of its business (whether owned in fee or a leasehold interest) in good repair and working order, ordinary wear and tear excepted, and from time to time will make all necessary repairs, replacements and renewals as the Company may determine to be appropriate to the conduct of its business.
Maintenance Outages If Seller reasonably determines that it is necessary to schedule a Maintenance Outage, Seller shall notify Buyer of the proposed Maintenance Outage at least five (5) days before the outage begins (or such shorter period to which Buyer may reasonably consent in light of then existing conditions). Upon such notice, the Parties shall plan the Maintenance Outage to mutually accommodate the reasonable requirements of Seller and the service obligations of Buyer; provided, however, that, unless Buyer otherwise consents, such consent not to be unreasonably withheld, no Maintenance Outage may be scheduled between the hour ending 0700 through the hour ending 2200, Monday through Saturday, during the time period commencing on May 15 and concluding on September 15. Notice of a proposed Maintenance Outage shall include the expected start date and time of the outage, the amount of Capacity of the Facility that will not be available, and the expected completion date and time of the outage. Seller shall give Buyer notice of the Maintenance Outage as soon as Seller determines that the Maintenance Outage is necessary. Buyer shall promptly respond to such notice and may request reasonable modifications in the schedule for the outage. Seller shall use all reasonable efforts to comply with any request to modify the schedule for a Maintenance Outage. Seller shall notify Buyer of any subsequent changes in Capacity available to Buyer or any changes in the Maintenance Outage completion date and time. As soon as practicable, any notifications given orally shall be confirmed in writing. Seller shall take all reasonable measures and exercise its best efforts in accordance with Prudent Electrical Practices to minimize the frequency and duration of Maintenance Outages.
Maintenance & Repairs 5.1 Lessee shall at all times be responsible for maintaining at its own expense the leased premises in a clean, orderly and safety condition, except as hereinafter provided. Lessee shall be responsible, at its own expense, to clean and maintain all trade fixtures, machinery and equipment furnished by Lessee within the leased premises. Lessee shall be responsible to deposit normal office waste and rubbish at a location at the Central School as designated by Lessor.
5.2 Lessee shall be responsible to perform all repairs the need for which is caused by Xxxxxx's use of the premises except that Lessor shall be responsible to perform major repairs of a structural nature. Lessor shall be responsible to arrange for removal of waste and rubbish from the location designated as the deposit location for lessees. All costs incurred by Lessor pursuant to the obligations of this Paragraph shall be included within "operating costs".
5.3 Lessor shall provide custodian services for the common areas of Central School. Costs incurred by Lessor in providing such custodian services shall be included within "operating costs".
Maintenance Training 16.8.1 The Seller will provide maintenance training for the Buyer’s ground personnel as further set forth in Appendix A to this Clause 16. The available courses will be as listed in the Seller’s Customer Services Catalog current at the time of the course. The practical training provided in the frame of maintenance training will be performed on the training devices in use in the Seller’s Training Centers.
Maintenance Scheduling The NTO shall schedule maintenance of its facilities designated as NTO Transmission Facilities Under ISO Operational Control and schedule any outages (other than forced transmission outages) of said transmission system facilities in accordance with outage schedules approved by the ISO. The NTO shall comply with maintenance schedules coordinated by the ISO, pursuant to this Agreement, for NTO Transmission Facilities Under ISO Operational Control. The NTO shall be responsible for providing notification of maintenance schedules to the ISO for NTO Transmission Facilities Requiring ISO Notification. The NTO shall provide notification of maintenance schedules to affected Transmission Owners for NTO Transmission Facilities Requiring ISO Notification and Local Area Transmission Facilities pursuant to Section 3.5.3 of the ISO Services Tariff.
Maintenance Period During the Maintenance Period the Developer shall at its own expense maintain repair and otherwise keep the Works in good working order and repair to the reasonable satisfaction of xxx Xxxxxxxxxx unless xxx Xxxxxxxxxx shall declare that any required maintenance and/or repair is an emergency in which case the Developer shall carry out the said maintenance and/or repair immediately
Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
MAINTENANCE & REPAIR Tenant agrees that if there is any delay in maintenance or repairs for reasons beyond Landlord's control, this shall have no effect on Tenant's obligations under this lease.
