Mandatory Change Order Sample Clauses

Mandatory Change Order. Contractor shall be entitled to an adjustment in the Contract Price in the event of an Owner-Caused Delay and an adjustment in the Construction Schedule (including to any Guaranteed Dates) as set forth below upon the occurrence of any of the following events: (a) an Owner-Caused Delay or (b) a Force Majeure Event, in each case as and only to the extent permitted by Article 10. Contractor shall only be entitled to a Change Order if and to the extent it can demonstrate that the occurrence of a preceding event had an actual and demonstrable adverse impact (i) on Contractor’s Direct Costs or (ii) when taken together with all other delays caused by the events described in (a) and (b) above of which Contractor has timely provided notice to Owner in accordance with this Agreement, on Contractor’s ability to perform any Contractor Critical Path Item necessary for the achievement of any Guaranteed Date and, in such event, the Contractor Critical Path Items shall be correspondingly extended by the period of time (if any) that Contractor is actually and demonstrably delayed in the performance of such Contractor Critical Path Item as a result of the impact of such event (such period, the “Actual Delay”).
Sample 1Sample 2See All (4)
AutoNDA by SimpleDocs
Mandatory Change Order. Contractor shall be entitled to an adjustment in the Contract Price as set forth in this Agreement and an adjustment in the Construction Schedule (including to any Guaranteed Block Substantial Completion Date, Guaranteed Facility Substantial Completion Date or Guaranteed Final Completion Date) as set forth below upon the occurrence of any of the following events: ***.
Sample 1Sample 2
Mandatory Change Order. Contractor shall be entitled to an adjustment in the Contract Price as set forth in this Agreement and an adjustment in the Construction Schedule (including to any Guaranteed Block Substantial Completion Date, Guaranteed Facility Substantial Completion Date or Guaranteed Final Completion Date) as set forth below upon the occurrence of any of the following events: (a) an Excusable Event (*** to the extent permitted by ***); (b) suspension of the Work pursuant to Section 19.3; (c) resumption of the Work after a suspension, in accordance with Section 19.4; (d) subject to Section 11.4(c) hereof, Change in Law; (e) Change in Project Agreement; (f) an Emergency (*** caused by an ***); (g) a Force Majeure Event (*** to the extent permitted by ***); or (h) Owner has failed to comply with its obligations under Section 3.33(d). Contractor shall only be entitled to a Change Order if and to the extent it can demonstrate that the *** of a *** had an *** and *** (i) on the Contract Price or (ii) when taken together with all *** caused by the events described in *** through *** which Contractor has timely provided notice to Owner in accordance with this Agreement, on Contractor's ability to perform any *** necessary for the achievement of any guaranteed date and in such event the *** shall be correspondingly extended by the period of time (if any) that Contractor is *** and *** in the performance of such *** as a result of the impact of such event. *** CONFIDENTIAL MATERIAL REDACTED AND SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION. Contractor shall not be entitled to any change in the Contract Price due to a Force Majeure Event. IT IS A CONDITION TO CONTRACTOR'S RIGHT TO RECEIVE AN EXTENSION OF TIME, AN INCREASE TO THE CONTRACT PRICE AND OTHER ADJUSTMENTS TO THE CONTRACT AND A CHANGE ORDER AS PROVIDED IN SECTION 10.3 THAT CONTRACTOR PROVIDE NOTICE TO OWNER WITHIN TEN (10) BUSINESS DAYS OF THE DATE CONTRACTOR BECAME AWARE OF THE FACTS OR CIRCUMSTANCES THAT PERMIT CONTRACTOR TO SEEK A CHANGE ORDER UNDER SECTION 10.3; IN THE EVENT CONTRACTOR DOES NOT PROVIDE NOTICE WITHIN TEN (10) BUSINESS DAYS OF THE DATE CONTRACTOR BECAME AWARE OF THE FACTS OR CIRCUMSTANCES THAT PERMIT CONTRACTOR TO SEEK A CHANGE ORDER UNDER SECTION 10.3, CONTRACTOR SHALL NOT BE ENTITLED TO A CHANGE ORDER UNDER THIS ARTICLE 10 OR ANY OTHER RELIEF HEREUNDER.
Sample 1
Mandatory Change Order. Pursuant to and to the extent specified in the provisions of this clause 15.3 (Mandatory Changes), the Contracting Entity shall issue a Change Order for a Mandatory Change within thirty (30) Days of the later of: 15.3.4.1 receipt from the Supplier of the Mandatory Change Notice (together with supporting documentation and evidence to the Contracting Entity's satisfaction) in respect of the Mandatory Change Event; and 15.3.4.2 the date of agreement of the matters described in clause 15.4 (Changes in Law) and/or 15.5 (Compensation Events) (if applicable).
Sample 1

Related to Mandatory Change Order

  • STATUTORY CHANGES All references to sections of the Exchange Act or the Code shall be deemed also to refer to any successor provisions to such sections.

  • Regulatory Changes If any legislative, regulatory, judicial or other legal action (other than an Amendment to the Act, which is provided for in Section 29.3) materially affects the ability of a Party to perform any material obligation under this Agreement, a Party may, on thirty (30) days written notice to the other Party (delivered not later than thirty (30) days following the date on which such action has become legally binding), require that the affected provision(s) be renegotiated, and the Parties shall renegotiate in good faith such mutually acceptable new provision(s) as may be required; provided that such affected provisions shall not affect the validity of the remainder of this Agreement.

  • Regulatory Change Without limiting the effect of the provisions of Section 5.01(a), in the event that at any time (by reason of any Regulatory Change or any other circumstances arising after the Closing Date affecting (A) any Lender, (B) the London interbank market or (C) such Lender’s position in such market), the Adjusted LIBOR, as determined in good faith by such Lender, will not adequately and fairly reflect the cost to such Lender of funding its LIBOR Loans, then, if such Lender so elects, by notice to the Borrower and the Administrative Agent, the obligation of such Lender to make additional LIBOR Loans shall be suspended until such Regulatory Change or other circumstances ceases to be in effect (in which case the provisions of Section 5.04 shall be applicable).

  • Change Order The Change Order is then submitted to the Project Manager who immediately processes the CO with OPC as required by Bulletin 3.5 and BGS’ Contracting Plan.

  • Increased Costs Capital Adequacy (a) If after the date of this Agreement the adoption of or any change in any law or regulation or in the interpretation or application thereof by any Governmental Authority or application thereof or compliance by any Bank with any request or directive (whether or not having the force of law) from any central bank or other Governmental Authority made subsequent to the date of this Agreement: (i) shall impose, modify or hold applicable any reserve, special deposit, compulsory loan or similar requirement against assets held by, deposits or other liabilities in or for the account of, advances, loans or other extensions of credit by, or any other acquisition of funds by, any office of such Bank that is not otherwise included in the determination of the LIBOR Rate hereunder (except for amounts covered by Section 3.4 or any other Section hereof); or (ii) shall impose on such Bank any other condition; and the result of any of the foregoing is to increase the actual cost to such Bank, by an amount that such Bank deems to be material, of making, converting into, continuing or maintaining LIBOR Rate Loans or issuing or participating in Letters of Credit or to reduce any amount receivable hereunder in respect thereof, then, in any such case, the Borrower shall promptly pay such Bank, upon its demand in the manner set forth in Section 4.8(b), any additional amounts, computed by such Bank in accordance with Section 4.8(a), necessary to compensate such Bank for such actual increased cost or reduced amount receivable that is attributable to Loans or Commitments (to the extent that such Bank has not already been compensated or reimbursed for such amounts pursuant to any other provision of this Agreement). If any Bank becomes entitled to claim any additional amounts pursuant to this Section 4.1(a) from the Borrower, it shall promptly notify the Borrower, through the Administrative Agent, of the event by reason of which it has become so entitled in the manner set forth in Section 4.8(b). (b) If any Bank determines in good faith that the introduction of or any change in or in the interpretation or application by any Governmental Authority of any law or regulation regarding capital adequacy after the date of this Agreement or compliance by such Bank or any corporation controlling such Bank with any law or regulation or any guideline or request from any central bank or other Governmental Authority (whether or not having the force of law) made or issued after the date of this Agreement does or shall have the effect, as a result of such Bank’s obligations under this Agreement or under any Letter of Credit, of reducing the rate of return on such Bank’s or such corporation’s capital to a level below that which such Bank or such corporation could have achieved but for such change or compliance (taking into consideration such Bank’s or such corporation’s policies with respect to capital adequacy) by an amount deemed by such Bank to be material, the Borrower shall pay to the Administrative Agent for the account of such Bank, from time to time as specified by such Bank in the manner set forth in Section 4.8(b), additional amounts, computed by such Bank in accordance with Section 4.8(a), sufficient to compensate such Bank or such corporation in the light of such circumstances, to the extent that such Bank reasonably determines such reduction in rate of return is allocable to the existence of such Bank’s obligations hereunder. (c) The agreements contained in this Section 4.1 shall survive the termination of this Agreement and the payment of all amounts payable hereunder; provided, however, that in no event shall the Borrower be obligated to reimburse or compensate any Bank for amounts contemplated by this Section 4.1 for any period prior to the date that is 90 days prior to the date upon which such Bank requests in writing such reimbursement or compensation from the Borrower.

  • Capital Adequacy Adjustment In the event that any Lender (which term shall include Issuing Bank for purposes of this Section 2.19(b)) shall have reasonably determined that the adoption, effectiveness, phase in or applicability after the Third Restatement Date of any Applicable Law regarding capital or liquidity adequacy, reserve requirements or similar requirements, or any change therein or in the interpretation, application or administration thereof by any Governmental Authority, central bank or comparable agency charged with the interpretation or administration thereof, or compliance by any Lender (or its applicable lending office) with any Applicable Law regarding capital or liquidity adequacy, reserve requirements or similar requirements (whether or not having the force of law) of any such Governmental Authority, has or would have the effect of reducing the rate of return on the capital of such Lender or any corporation controlling such Lender as a consequence of, or with reference to, such Lender’s Loans or Revolving Commitments or Letters of Credit, or participations therein or other obligations hereunder with respect to the Loans or the Letters of Credit to a level below that which such Lender or such controlling corporation could have achieved but for such adoption, effectiveness, phase in, applicability, change or compliance (taking into consideration the policies of such Lender or such controlling corporation with regard to capital adequacy); provided that, notwithstanding anything herein to the contrary, (x) the Xxxx-Xxxxx Xxxx Street Reform and Consumer Protection Act and all requests, rules, guidelines or directives thereunder or issued in connection therewith and (y) all requests, rules, guidelines or directives promulgated by the Bank for International Settlements, the Basel Committee on Banking Supervision (or any successor or similar authority) or the United States regulatory authorities, in each case pursuant to Basel III, shall in each case be deemed a change of law, regardless of the date enacted, adopted or issued, then from time to time, within five Business Days after receipt by Borrower from such Lender of the statement referred to in the next sentence, Borrower shall pay to such Lender such additional amount or amounts as will compensate such Lender or such controlling corporation on an after tax basis for such reduction. Such Lender shall deliver to Borrower (with a copy to Administrative Agent) a written statement, setting forth in reasonable detail the basis for calculating the additional amounts owed to Lender under this Section 2.19(b), which statement shall be conclusive and binding upon all parties hereto absent manifest error.

  • Additional Costs Capital Adequacy (a) If any new law, rule or regulation, or any change after the date hereof in the interpretation or administration of any Applicable Law, rule or regulation by any governmental authority, central bank or comparable agency charged with the interpretation or administration thereof, or compliance by any Bank or its Applicable Lending Office with any request or directive (whether or not having the force of law) of any such authority, central bank or comparable agency in connection therewith issued, promulgated or enacted after the date hereof shall: (i) subject any Bank (or its Applicable Lending Office) to any Tax with respect to its Loans, its Note or its Commitment, in each case with respect to any Borrower, or shall change the basis of taxation of payments to any Bank (or its Applicable Lending Office) by such Borrower of the principal of or interest on its Loans or any other amounts due under this Agreement or its Commitment, in each case except for any (A) Covered Tax, or (B) Tax described in clauses (a)(2), (b), (c), or (d) of the definition of Excluded Taxes; or (ii) impose, modify or deem applicable any reserve (including, without limitation, any such requirement imposed by the Board of Governors of the Federal Reserve System), special deposit, insurance assessment or similar requirement against assets of, deposits with or for the account of, or credit extended by, any Bank (or its Applicable Lending Office) or shall impose on any Bank (or its Applicable Lending Office) any other condition affecting its Loans, its Note or its Commitment, in each case with respect to such Borrower; or (iii) impose on any Bank any other conditions or requirements with respect to this Agreement, the other Loan Documents, the Loans or such Bank’s Commitment, in each case with respect to such Borrower; and the result of any of the foregoing is to increase the cost to such Bank (or its Applicable Lending Office) of making, funding, issuing, renewing, extending or maintaining any Loan to such Borrower or such Bank’s Commitment in favor of such Borrower, or to reduce the amount of any sum received or receivable by such Bank (or its Applicable Lending Office) from such Borrower under this Agreement or under its Note with respect thereto, by an amount deemed by such Bank to be material, then, promptly upon demand by such Bank (and in any event within thirty (30) days after demand by such Bank) and delivery to such Borrower of the certificate required by clause (c) of this Section (with a copy to the Agent), such Borrower shall pay to such Bank the additional amount or amounts as will compensate such Bank for such increased cost or reduction. (b) If any Bank shall determine that any change after the date hereof in any existing Applicable Law, rule or regulation or any new law, rule or regulation regarding liquidity or capital adequacy, or any change therein, or any change after the date hereof in the interpretation or administration thereof by any governmental authority, central bank or comparable agency charged with the interpretation or administration thereof, or any new request or directive of general applicability regarding liquidity or capital adequacy (whether or not having the force of law) of any such authority, central bank or comparable agency issued, promulgated or enacted after the date hereof, has or would have the effect of reducing the rate of return on capital of such Bank (or its parent corporation) as a consequence of such Bank’s Loans to a Borrower or obligations to such Borrower hereunder to a level below that which such Bank (or its parent corporation) could have achieved but for such law, change, request or directive (taking into consideration its policies with respect to liquidity and capital adequacy) by an amount deemed by such Bank to be material, then from time to time, promptly upon demand by such Bank (with a copy to the Agent) (and in any event within thirty (30) days after demand by such Bank) such Borrower shall pay to such Bank such additional amount or amounts as will compensate such Bank (or its parent corporation) for such reduction. (c) Each Bank will promptly notify each Borrower and the Agent of any event of which it has knowledge, occurring after the date hereof, which will entitle such Bank to compensation from such Borrower pursuant to this Section and, upon the written request of the Borrowers, will designate a different Applicable Lending Office if such designation will avoid the need for, or reduce the amount of, such compensation and will not, in the judgment of such Bank, be otherwise disadvantageous to such Bank. A certificate of any Bank claiming compensation under this Section and setting forth in reasonable detail the additional amount or amounts to be paid to it hereunder and the calculations used in determining such additional amount or amounts shall be conclusive in the absence of manifest error. In determining such amount, such Bank may use any reasonable averaging and attribution methods. (d) Failure or delay on the part of any Bank to demand compensation pursuant to this Section shall not constitute a waiver of such Bank’s right to demand such compensation; provided that the Borrowers shall not be required to compensate a Bank pursuant to this Section for any increased costs or reductions incurred more than nine months prior to the date that such Bank notifies the Borrowers of the change giving rise to such increased costs or reductions and of such Bank’s intention to claim compensation therefor; provided further that, if the change giving rise to such increased costs or reductions is retroactive, then the nine month period referred to above shall be extended to include the period of retroactive effect thereof.

  • Change Orders Any alteration or deviation from the Services mentioned or any other contractual specifications that result in a revision of this Agreement shall be executed and attached to this Agreement as a change order (“Change Order”).

  • Capital Adequacy; Increased Costs; Illegality (a) If any Lender shall have determined that any law, treaty, governmental (or quasi-governmental) rule, regulation, guideline or order regarding capital adequacy, reserve requirements or similar requirements or compliance by any Lender with any request or directive regarding capital adequacy, reserve requirements or similar requirements (whether or not having the force of law), in each case, adopted after the Closing Date, from any central bank or other Governmental Authority increases or would have the effect of increasing the amount of capital, reserves or other funds required to be maintained by such Lender and thereby reducing the rate of return on such Lender's capital as a consequence of its obligations hereunder, then Borrower shall from time to time upon written demand by such Lender (with a copy of such demand to Agent) pay to Agent, for the account of such Lender, additional amounts sufficient to compensate such Lender for such reduction; provided, that Borrower shall not be obligated to pay any such amount or amounts which are attributable to any period of time occurring more than 120 days prior to the date of receipt by Borrower of such written demand; provided, further, that such Lender shall disclose to Borrower the calculations of the amount necessary to compensate for any shortfall in the rate of return. A certificate as to the amount of that reduction and showing the basis of the computation thereof submitted by such Lender to Borrower and to Agent shall, absent manifest error, be final, conclusive and binding for all purposes. (b) If, due to either (i) the introduction of or any change in any law or regulation (or any change in the interpretation thereof) or (ii) the compliance with any guideline or request from any central bank or other Governmental Authority (whether or not having the force of law), in each case adopted after the Closing Date, there shall be any increase in the cost to any Lender of agreeing to make or making, funding or maintaining any Loan, then Borrower shall from time to time, upon written demand by such Lender (with a copy of such demand to Agent), pay to Agent for the account of such Lender additional amounts sufficient to compensate such Lender for such increased cost; provided, that Borrower shall not be obligated to pay any such amount or amounts which are attributable to any period of time occurring more than 120 days prior to the date of receipt by Borrower of such written demand; provided, further, that such Lender shall disclose to Borrower the calculations of the amount necessary to compensate for such increased cost. A certificate as to the amount of such increased cost, submitted to Borrower and to Agent by such Lender, shall be conclusive and binding on Borrower for all purposes, absent manifest error. Each Lender agrees that, as promptly as practicable after it becomes aware of any circumstances referred to above which would result in any such increased cost, the affected Lender shall, to the extent not inconsistent with such Lender's internal policies of general application, use reasonable commercial efforts to minimize costs and expenses incurred by it and payable to it by Borrower pursuant to this Section 1.16(b). (c) Notwithstanding anything to the contrary contained herein, if the introduction of or any change in any law or regulation (or any change in the interpretation thereof) shall make it unlawful, or any central bank or other Governmental Authority shall assert that it is unlawful, for any Lender to agree to make or to make or to continue to fund or maintain any LIBOR Loan, then, unless that Lender is able to make or to continue to fund or to maintain such LIBOR Loan at another branch or office of that Lender without, in that Lender's opinion, adversely affecting it or its Loans or the income obtained therefrom, on notice thereof and demand therefor by such Lender to Borrower through Agent, (i) the obligation of such Lender to agree to make or to make or to continue to fund or maintain LIBOR Loans shall terminate and (ii) Borrower shall forthwith prepay in full all outstanding LIBOR Loans owing to such Lender, together with interest accrued thereon, unless Borrower, within 5 Business Days after the delivery of such notice and demand, converts all LIBOR Loans into Index Rate Loans. (d) Within 15 days after receipt by Borrower of written notice and demand from any Lender (an "Affected Lender") for payment of additional amounts or increased costs as provided in Sections 1.15(a), 1.16(a) or 1.16(b), Borrower may, at its option, notify Agent and such Affected Lender of its intention to replace the Affected Lender. So long as no Default or Event of Default has occurred and is continuing, Borrower, with the consent of Agent, may obtain, at Borrower's expense, a replacement Lender ("Replacement Lender") for the Affected Lender, which Replacement Lender must be reasonably satisfactory to Agent. If Borrower obtains a Replacement Lender within 90 days following notice of their intention to do so, the Affected Lender must sell and assign its Loans and Commitments to such Replacement Lender for an amount equal to the principal balance of all Loans held by the Affected Lender and all accrued interest and Fees with respect thereto through the date of such sale; provided, that Borrower shall have reimbursed such Affected Lender for the additional amounts or increased costs that it is entitled to receive under this Agreement through the date of such sale and assignment. Notwithstanding the foregoing, Borrower shall not have the right to obtain a Replacement Lender if the Affected Lender rescinds its demand for increased costs or additional amounts within 15 days following its receipt of Borrower's notice of intention to replace such Affected Lender. Furthermore, if Borrower gives a notice of intention to replace and does not so replace such Affected Lender within 90 days thereafter, Borrower's rights under this Section 1.16

  • Benchmark Replacement Conforming Changes In connection with the use, administration, adoption or implementation of a Benchmark Replacement, the Administrative Agent will have the right to make Conforming Changes from time to time and, notwithstanding anything to the contrary herein or in any other Loan Document, any amendments implementing such Conforming Changes will become effective without any further action or consent of any other party to this Agreement or any other Loan Document.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!