Overtime Work A. Overtime pay is to be paid at the rate of one and one- half (1½) times the basic hourly straight-time rate.
B. Overtime shall be paid to employees for work performed only after eight (8) hours on duty in any one (1) service day or forty (40) hours in any one (1) service week. Nothing in this Section shall be construed by the parties or any reviewing authority to deny the payment of overtime to employees for time worked outside of their regularly scheduled work week at the request of the Employer.
C. Penalty overtime pay is to be paid at the rate of two
Assignment of Overtime Work (a) Subject to the operational requirements, the Employer shall make every reasonable effort to avoid excessive overtime and to offer overtime work on an equitable basis among readily available qualified employees.
(b) Except in cases of emergency, call-back, or mutual agreement with the employee, the Employer shall, wherever possible, give at least four (4) hours’ notice of any requirement for overtime work.
Banked Overtime (a) Compensating time off shall not be given in lieu of overtime pay unless the employee so chooses. Employees who wish to bank overtime must confirm same in writing to the Company between March 1st and March 15th and again between September 1st and September 15th of each calendar year. Employees shall be entitled to cancel their decision to bank overtime at any time. In such cases, the employee shall provide the Company with a written notice confirming same, and shall not be eligible to resume banking overtime until the following March 1st or September 1st, as the case may be.
(b) Accumulated banked overtime hours shall be shown on the employee's weekly pay stub until implementation of the Workbrain System, at which point such information will be available for review through that System.
(c) Banked overtime shall accumulate at the rate of one and one-half (1½) or two (2) hours of paid time off, as the case may be, for each hour of overtime worked. Employees shall only bank overtime exceeding one (1) hour. If overtime worked does not exceed one hour, such overtime shall be paid out.
(d) Employees shall have the option of cashing in all or any portion of said banked overtime at any time he or she chooses. Banked overtime that is subsequently cashed in by an employee shall be paid to the employee at the regular hourly rate of pay said employee was being paid at that time. All banked overtime must be used or cashed in by the end of the calendar year in which it was earned, unless otherwise mutually agreed to between the employee concerned and the Company. Separate cheques will not be issued for banked overtime but, when paid out, the banked overtime amount will be itemized separately on the employee’s pay record.
(e) Subject to the following paragraph, each employee shall decide when his or her compensating time off is to be taken except that no such time off can be taken on the working day immediately preceding and following a general holiday without the prior approval of the Company. Compensating time off shall be granted to employees on a first come first served basis. Seniority shall only apply and be the governing factor in situations where on the same day, too many employees put in a request to take compensating time off at the same time. A maximum of four (4) employees per day shall be entitled to use their banked overtime. These amounts may be increased from time to time at the discretion of the Company.
(f) All banked time off requests must be submitted by the Monday of the week preceding the requested time off. The minimum amount of such time off that can be taken at any one time shall be four (4) hours. The Employer agrees to respond to the employee’s request within twenty-four (24) hours. Should no response be given by the Employer, then permission for the time off will be deemed to have been granted
(g) For the purpose of using banked overtime for regularly scheduled days off (excluding shut downs), each employee shall have the ability to use a maximum of forty (40) hours while working eight (8) hour shifts and forty-eight (48) hours while working continental shifts per calendar year. All other overtime banked shall be paid out to employees upon request. Should an employee want to take off more than the maximum hours off noted above per calendar year, a written request will be submitted to the Company for consideration and will be approved at the Company’s discretion.
(h) No requests for time banked time off for regularly scheduled days off, between April 15th – December 31st of each year will be approved until after the vacation planner has been finalized for the year. Once the planner has been finalized all requests will be granted on a first come first serve basis.
(i) No employees will have the ability to request regularly scheduled days off (excluding shut downs) during the prime time vacation period for the use of banked overtime.
(j) All employees hired after April 15, 2015 will not be eligible to bank overtime.
Daily Overtime All employees shall be paid the applicable overtime rate of time and one-half (1-1/2) for all time worked in excess of eight (8) hours per day.
Overtime Meal Allowance Employees required to work more than two (2) hours overtime consecutive with a shift shall be provided with a meal by the Employer.
Scheduled Overtime Scheduled overtime is overtime which is assigned by the end of the employee's last worked shift prior to the overtime assignment and which does not immediately precede or immediately follow a scheduled work shift. Unless notified otherwise in advance of the scheduled starting time of the scheduled overtime assignment, any employee who is scheduled to report for work and who reports as scheduled shall be assigned at least two (2) hours work. If work is not available, the employee may be excused from duty and paid for two (2) hours at the employee's appropriate rate. If the employee begins work but is excused from duty before completing two (2) hours of work, the employee shall be paid for two (2) hours at the employee's appropriate rate.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Landlord’s Work Prior to the execution of the Lease, Landlord and Tenant have approved the detailed description of base, shell and core work for the Phase I Premises and Phase II Premises attached hereto as Exhibit B-1 (the “Base, Shell and Core Description”). Based upon and in conformity with the Base Shell and Core Description, Landlord shall cause its architect and engineers, at Landlord’s sole cost and expense, to prepare and deliver to Tenant, for Tenant’s approval, detailed specifications and engineered working drawings in CAD format, which shall include, without limitation, ADA path of travel, restroom locations and counts, exit lighting plans for the Phase I Work (the “Base Building Working Drawings”) by no later than June 1, 2019. Within seven (7) days after Tenant’s and Landlord’s receipt of the Base Building Working Drawings, Tenant and Landlord shall approve or disapprove the same, which approval shall not be unreasonably withheld; provided, however, that Tenant may only disapprove the Base Building Working Drawings to the extent such Base Building Working Drawings are inconsistent with the Base, Shell and Core Description and only if Tenant delivers notice thereof to Landlord within such seven (7) day period. If any specific changes proposed by Tenant to rectify any inconsistencies with the Base, Shell and Core Description are timely and properly proposed by Tenant, Landlord shall cause its architect and engineers to revise the Base Building Working Drawings to incorporate such revisions and submit the same for Tenant’s approval in accordance with the foregoing provisions, and the parties shall follow the foregoing procedures for approving the Base Building Working Drawings until the same are finally approved by Landlord and Tenant. Upon Landlord’s and Tenant’s approval of the Base Building Working Drawings, the same shall be referred to as the “Approved Working Drawings for Landlord’s Phase I Work”. Based upon and in conformity with the Base, Shell and Core Description, Landlord shall cause its architect and engineers, at Landlord’s sole cost and expense, to prepare and deliver to Tenant, for Tenant’s approval, detailed specifications and engineered working drawings in CAD format, which shall include, without limitation, ADA path of travel, restroom locations and counts, exit lighting plans for the Phase II Work (the “Phase II Base Building Working Drawings”) by no later than October 1, 2019. Within seven (7) days after Tenant’s and Landlord’s receipt of the Phase II Base Building Working Drawings, Tenant and Landlord shall approve or disapprove the same, which approval shall not be unreasonably withheld; provided, however, that Tenant may only disapprove the Phase II Base Building Working Drawings to the extent such Phase II Base Building Working Drawings are inconsistent with the Base, Shell and Core Description and only if Tenant delivers notice thereof to Landlord within such seven (7) day period. If any specific changes proposed by Tenant to rectify any inconsistencies with the Base, Shell and Core Description are timely and properly proposed by Tenant, Landlord shall cause its architect and engineers to revise the Phase II Base Building Working Drawings to incorporate such revisions and submit the same for Tenant’s approval in accordance with the foregoing provisions, and the parties shall follow the foregoing procedures for approving the Phase II Base Building Working Drawings until the same are finally approved by Landlord and Tenant. Upon Landlord’s and Tenant’s approval of the Phase II Base Building Working Drawings, the same shall be referred to as the “Approved Working Drawings for Landlord’s Phase II Work”. The improvements shown on the Approved Working Drawings for Landlord’s Phase I Work and the Approved Working Drawings for Landlord’s Phase II Work are hereby collectively referred to as “Landlord’s Work”. The Approved Working Drawings for Landlord’s Phase I Work and the Approved Working Drawings for Landlord’s Phase II Work are sometimes collectively referred to herein as the “Approved Working Drawings for Landlord’s Work”.
Permission to Leave Work The Employer agrees that stewards shall not be hindered, coerced, restrained or interfered with in any way in the performance of their duties, while investigating disputes and presenting adjustments as provided in this Article. The Union recognizes that each xxxxxxx is employed by the Employer and that they will not leave their work during working hours except to perform their duties under this Agreement. Therefore, no xxxxxxx shall leave their work without permission of their supervisor, which will not be unreasonably withheld.
Landlord Work Landlord shall, at Landlord’s sole cost and expense, concurrently with Tenant’s construction of the Tenant Improvements, remove the existing demising wall and construct a Building standard demising wall at the Expansion Premises, which shall include studs, acoustical insulation and dry wall ready for finish on the Tenant side only and any necessary penetrations, fire dampers and sound traps (collectively, the “Demising Wall”), which Demising Wall shall be adjacent to the Expansion Premises as set forth on Exhibit A to this Amendment (collectively, the “Landlord Work”). Tenant may not change or alter the Landlord Work. Landlord shall use commercially reasonable efforts to Substantially Complete the Landlord Work no later than forty-five (45) days after the Expansion Delivery Date. In addition, Landlord shall, at Landlord’s sole cost and expense, to the extent required in order to allow Tenant to obtain a certificate of occupancy, or its legal equivalent, for the Expansion Premises for general office use assuming a normal and customary office occupancy density, cause the Landlord Work and the Building Common Areas (including the Base Building restrooms on the seventh (7th) floor of the Building), to comply with applicable building codes and other governmental laws, ordinances and regulations related to handicap access, which were enacted and enforced as of the date of this Amendment. Because Landlord shall be constructing the Landlord Work concurrently with Tenant’s construction of the Tenant Improvements, there will be a certain “overlap” period pursuant to which both Landlord’s representatives, employees, vendors and contractors and Tenant’s representatives, employees, vendors and contractors may be present and performing work in a portion of the Premises. During any such “overlap” period(s) when both parties and/or their respective employees, vendors, contractors or consultants are concurrently performing work in, or accessing, any portion of the Premises, neither party shall unreasonably interfere with or delay the work of the other party and/or its contractors or consultants, and both parties shall mutually coordinate and cooperate with each other, and shall cause their respective employees, vendors, contractors, and consultants to work in harmony with and to mutually coordinate and cooperate with the other’s employees, vendors, contractors and consultants, respectively, to minimize any interference or delay by either party with respect to the other party’s work. In addition, Landlord shall, and shall cause the other Landlord Parties to, use commercially reasonable efforts to minimize any interference with Tenant’s operations in the Existing Premises. Landlord shall have no obligation to move any furniture or other personal property of Tenant in the performance of Landlord Work. Tenant hereby agrees that the construction of the Landlord Work shall in no way constitute a constructive eviction of Tenant nor entitle Tenant to any abatement of rent. Except as otherwise expressly provided in the Lease (including this Tenant Work Letter), Landlord shall have no responsibility or for any reason be liable to Tenant for any direct or indirect injury to or interference with Tenant’s business arising from the Landlord Work, nor shall Tenant be entitled to any compensation or damages from Landlord for loss of the use of the whole or any part of the Premises or of Tenant’s personal property or improvements resulting from the Landlord Work or Landlord’s actions in connection with the Landlord Work, or for any inconvenience or annoyance occasioned by the Landlord Work or Landlord’s actions in connection with the Landlord Work.
