Notice of Acceptability of the Work Sample Clauses

Notice of Acceptability of the Work. Conduct a final visit to the Project to determine if the Work is complete and acceptable so that Engineer may recommend, in writing, final payment to Contractor. Accompanying the recommendation for final payment, Engineer shall also provide a notice to Owner and Contractor that the Work is acceptable to the best of Engineer’s knowledge, information, and belief, and based on the extent of the services provided by Engineer under this Agreement.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Notice of Acceptability of the Work. Conduct a final site visit to determine if the completed Work of Contractor is generally in accordance with the Contract Documents and the final punch list so that KHA may recommend, in writing, final payment to Contractor. Accompanying the recommendation for final payment, KHA shall also provide a notice that the Work is generally in accordance with the Contract Documents to the best of KHA’s knowledge, information, and belief and based on the extent of the services provided by KHA under this Agreement and based upon information provided to KHA upon which it is entitled to rely. Limitation of Responsibilities. KHA shall not be responsible for the acts or omissions of any Contractor, or of any of their subcontractors, suppliers, or of any other individual or entity performing or furnishing the Work. KHA shall not have the authority or responsibility to stop the work of any Contractor.
Sample 1
Notice of Acceptability of the Work. ENGINEER will conduct a final site visit to determine if the completed Work of Contractor is generally in accordance with the Contract Documents and the final punch list. · Four (4) site visits are assumed. · Two (2) submittal reviews are assumed. · Five (5) RFI’s are assumed.
Sample 1
Notice of Acceptability of the Work. Xxxxxx-Xxx will conduct a final site visit to determine if the completed Work of Contractor is generally in accordance with the Contract Documents and the final punch list so that Xxxxxx-Xxx may recommend final payment to Contractor. Accompanying the recommendation for fina! payment, Xxxxxx-Xxx shall also provide a notice that the Work is generally in accordance with the Contract Documents to the best of Xxxxxx-Xxxx'x knowledge, information, and belief based on the extent of its services and based upon information provided to Xxxxxx-Xxxx.
Sample 1
Notice of Acceptability of the Work. In company with City’s representative, CONSULTANT shall conduct a final inspection to determine if the completed work of Contractor is acceptable so that CONSULTANT may recommend, in writing, final payment to Contractor. Accompanying the recommendation for final payment, CONSULTANT shall also provide a Notice of Acceptability of work that the work is acceptable to the best of CONSULTANT’s knowledge, information, and belief and based on the extent of the services provided by CONSULTANT under this Agreement. Provide necessary certifications to City, DEQ and any permitting authority regarding completion of the work in accordance with approved plans and specifications. CONSULTANT shall not be responsible for the acts or omissions of any Contractor, or of any subcontractors, suppliers, or other individuals or entities performing or furnishing any of the work. CONSULTANT shall not be responsible for the failure of any Contractor to perform or furnish the work in accordance with the Contract Documents.
Sample 1
Notice of Acceptability of the Work. In company with City’s representative, CONSULTANT shall conduct a final inspection to determine if the completed work of Contractor is acceptable so that CONSULTANT may recommend, in writing, final payment to Contractor. Accompanying the recommendation for final payment, CONSULTANT shall also provide a Notice of Acceptability of work that the work is acceptable to the best of CONSULTANT’s knowledge, information, and belief and based on the extent of the services provided by CONSULTANT under this Agreement. Provide necessary certifications to City, DEQ and any permitting authority regarding completion of the work in accordance with approved plans and specifications. CONSULTANT shall not be responsible for the acts or omissions of any Contractor, or of any subcontractors, suppliers, or other individuals or entities performing or furnishing any of the work. CONSULTANT shall not be responsible for the failure of any Contractor to perform or furnish the work in accordance with the Contract Documents. Upon City’s request and upon completion of signed amendment to cover additional scope and fee, CONSULTANT shall furnish or obtain from others additional services of the types listed below: ● Additional or extended services during construction made necessary by (1) emergencies or acts of God endangering the work, (2) the presence at the Site of any constituent of concern, (3) work damaged by fire or other cause during construction, (4) a significant amount of defective, neglected, or delayed work by Contractor, (5) acceleration of the progress schedule involving services beyond normal working hours, or (6) default by Contractor. ● Providing assistance in responding to the presence of any constituent of concern at the site, in compliance with current laws and regulations. ● Services in connection with any partial utilization of any part of the work by the City prior to Substantial Completion. ● Evaluating an unreasonable claim or an excessive number of claims submitted by Contractor or others in connection with the work. ● Preparing to serve or serving as a consultant or witness for the City in any litigation, arbitration, or other dispute resolution process related to the Project.
Sample 1
Notice of Acceptability of the Work. Conduct a final inspection to determine if the completed Work of the Contractor is acceptable so that ENGINEER may recommend, in writing, final payment to Contractor. Accompanying the recommendation for final payment, ENGINEER shall also provide a notice that the Work is acceptable to the best of ENGINEER’s knowledge, information, and belief and based on the extent of the services provided by ENGINEER under this Scope of Services.
Sample 1
AutoNDA by SimpleDocs

Related to Notice of Acceptability of the Work

  • Notice of Completion The Interconnection Customer shall notify the Transmission Provider and the Interconnected Transmission Owner in writing when it has completed construction of (i) the Customer Facility;

  • Inspection; Acceptance The Contractor (immixTechnology, Inc.) can only, and shall only tender for acceptance those items that substantially conform to the software manufacturer’s (“Qualtrics”) published specifications. Therefore, items delivered shall be considered accepted upon delivery. The Government reserves the right to inspect or test any supplies or services that have been delivered. The Government may require repair or replacement of nonconforming supplies or re-performance of nonconforming services at no increase in contract price. If repair/replacement or re-performance will not correct the defects or is not possible, the Government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights-(1) Within the warranty period; and (2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

  • Notice of Acceptance Notice of each Offeree’s intention to accept, in whole or in part, any Offer made shall be evidenced by a writing signed by such Offeree and delivered to the Company prior to the end of the 20-day period of such offer, setting forth such of the Offeree’s Basic Amount as such Offeree elects to purchase and, if such Offeree shall elect to purchase all of its Basic Amount, such Undersubscription Amount as such Offeree shall elect to purchase (the “Notice of Acceptance”). If the Basic Amounts subscribed for by all Offerees are less than the total Offered Securities, then each Offeree who has set forth Undersubscription Amounts in its Notice of Acceptance shall be entitled to purchase, in addition to the Basic Amounts subscribed for, all Undersubscription Amounts it has subscribed for; provided, however, that should the Undersubscription Amounts subscribed for exceed the difference between the Offered Securities and the Basic Amounts subscribed for (the “Available Undersubscription Amount”), each Offeree who has subscribed for any Undersubscription Amount shall be entitled to purchase only that portion of the Available Undersubscription Amount as the Undersubscription Amount subscribed for by such Offeree bears to the total Undersubscription Amounts subscribed for by all Offerees, subject to rounding by the Board of Directors to the extent it reasonably deems necessary.

  • Delivery and Acceptance of the Manuscript The Author shall deliver the Contribution to the Editor (or, if requested by the Publisher, to the Publisher) on or before Delivery Date (the “Delivery Date”) electronically in the Publisher's standard requested format or in such other form as may be agreed in writing with the Publisher. The Author shall retain a duplicate copy of the Contribution. The Contribution shall be in a form acceptable to the Publisher (acting reasonably) and in line with the instructions contained in the Publisher’s guidelines as provided to the Author by the Publisher. The Author shall provide at the same time, or earlier if the Publisher reasonably requests, any editorial, publicity or other information (and in such form or format) reasonably required by the Publisher. The Publisher may exercise such additional quality control of the manuscript as it may decide at its sole discretion including through the use of plagiarism checking systems and/or peer review by internal or external reviewers of its choice. If the Publisher decides at its sole discretion that the final manuscript does not conform in quality, content, structure, level or form to the stated requirements of the Publisher, the Publisher shall be entitled to terminate this Agreement in accordance with the provisions of this Clause. The Author must inform the Publisher at the latest on the Delivery Date if the sequence of the naming of any co-authors entering into this Agreement shall be changed. If there are any changes in the authorship (e.g. a co-author joining or leaving), then the Publisher must be notified by the Author in writing immediately and the Parties will amend this Agreement accordingly. The Publisher shall have no obligation to consider publication under this Agreement in the absence of such agreed amendment. If the Author fails to deliver the Contribution in accordance with the provisions of this Clause above by the Delivery Date (or within any extension period given by the Publisher at its sole discretion) or if the Author (or any co-author) dies or becomes incapacitated or otherwise incapable of performing the Author’s obligations under this Agreement, the Publisher shall be entitled to either: (a) elect to continue to perform this Agreement in accordance with its terms and the Publisher may commission an appropriate and competent person (who, in the case of co-authors having entered into this Agreement, may be a co-author) to complete the Contribution; or (b) terminate this Agreement with immediate effect by written notice to the Author or the Author's successors, in which case all rights granted by the Author to the Publisher under this Agreement shall revert to the Author/Author's successors (subject to the provisions of the Clause "Termination"). The Author agrees, at the request of the Publisher, to execute all documents and do all things reasonably required by the Publisher in order to confer to the Publisher all rights intended to be granted under this Agreement. The Author warrants that the Contribution is original except for any excerpts from other works including pre-published illustrations, tables, animations, text quotations, photographs, diagrams, graphs or maps, and whether reproduced from print or electronic or other sources ("Third Party Material") and that any such Third Party Material is in the public domain (or otherwise unprotected by copyright/other rights) or has been included with written permission from or on behalf of the rights holder (and if requested in a form prescribed or approved by the Publisher) at the Author's expense unless otherwise agreed in writing, or is otherwise used in accordance with applicable law. On request from the Publisher, the Author shall in writing indicate the precise sources of these excerpts and their location in the manuscript. The Author shall also retain the written permissions and make them available to the Publisher on request.

  • NOTICE OF ACCIDENTS 20.01 Tenant shall give notice to Landlord, promptly after Tenant learns thereof, of (i) any accident in or about the Demised Premises for which Landlord might be liable, (ii) all fires in the Demised Premises, (iii) all damages to or defects in the Demised Premises, including the fixtures, equipment and appurtenances thereof, for the repair of which Landlord might be responsible, and (iv) all damage to or defects in any parts or appurtenances of the Building’s sanitary, electrical, heating, ventilating, air-conditioning, elevator and other systems located in or passing through the Demised Premises or any part thereof.

  • CAFA Notice Pursuant to 28 U.S.C. § 1715, not later than ten (10) days after the Agreement is filed with the Court, the Settlement Administrator shall cause to be served upon the Attorneys General of each U.S. State in which Settlement Class members reside, the Attorney General of the United States, and other required government officials, notice of the proposed settlement as required by law, subject to Paragraph 5.1 below.

  • Response to Notice Within ten business days of receiving the Claim Notice, the Respondent must notify the Claimant of its representative to negotiate the dispute.

  • Required Acceptance of Daily Load Deliveries and Notification If the State is harmed by purchaser’s refusal to accept up to 10 truck deliveries of any one sort per day, Purchaser will be in breach of contract and subject to damages as per the D-026.2 and D-027.2 clauses. A truck delivery is all the wood delivered including sorts on super trucks, mule trains and pups brought to the delivery point by a single truck. The Purchaser shall notify the Contract Administrator at least 48 hours in advance if: 1. Purchaser intends to limit the number of truck deliveries accepted on any day to less than that listed above, or 2. Purchaser intends to limit the number of truck deliveries accepted on any day to the number listed above.

  • Payment for Material Completion The Contractor may request payment of the remaining contract balance, including retainage, less amounts credited the Owner or incurred as liquidated damages, and less amounts withheld for the Punchlist by reason of Minor Items or Permitted Incomplete Work (See Paragraph 6.5.3.2). Payment for Material Completion shall be made by a check payable jointly to the Contractor and Surety and shall be mailed to the Surety.

  • Agreement Exceptions/Deviations Explanation If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!