Posting of Positions Notice of any opening for a promotional position shall be posted in all schools and departments by the Division of Human Resources & Equity.
Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.
Filling of Positions All eligible employees under Section 3 who have made a timely interest bid, and meet the minimum qualifications, shall be given consideration and may be appointed to the opening prior to the consideration of other non-interest bidding applicants and prior to filling the vacancy through other means. The Appointing Authority shall not be arbitrary, capricious, or discriminatory and must have a legitimate business reason to reject all of the interest bidders. Seniority of the interest bidders shall not be a factor in appointing employees from among the interest bidders. All interest bidders shall be notified orally or in writing, which may include electronic mailing, as to the status (either under consideration, acceptance, or rejection) of their interest bid in a timely manner. If the vacancy is not filled by an employee under this Section, then it shall be filled in the following order:
Determination of Position(s) The Appointing Authority shall determine the position(s) in the class or class option, if one exists, and employment condition and work location which is to be eliminated.
Notice of Possible Withholding Under FATCA The Issuer shall notify each Agent in the event that it determines that any payment to be made by an Agent under the Notes is a payment which could be subject to FATCA Withholding if such payment were made to a recipient that is generally unable to receive payments free from FATCA Withholding, and the extent to which the relevant payment is so treated, provided, however, that the Issuer's obligation under this Clause 14 shall apply only to the extent that such payments are so treated by virtue of characteristics of the Issuer, the Notes, or both.
Notice of Layoffs The County shall give reasonable notice to the Association before effecting any layoffs which materially affect employees represented under this Memorandum of Understanding. Upon receiving such notice, the Association may meet and confer regarding the effect of the layoff.
Notice of Special Matters The Corporation covenants with the Warrant Agent that, so long as any Warrant remains outstanding, it will give notice to the Warrant Agent and to the Registered Warrantholders of its intention to fix a record date that is prior to the Expiry Date for any matter for which an adjustment may be required pursuant to Section 4.1. Such notice shall specify the particulars of such event and the record date for such event, provided that the Corporation shall only be required to specify in the notice such particulars of the event as shall have been fixed and determined on the date on which the notice is given. The notice shall be given in each case not less than 14 days prior to such applicable record date. If notice has been given and the adjustment is not then determinable, the Corporation shall promptly, after the adjustment is determinable, file with the Warrant Agent a computation of the adjustment and give notice to the Registered Warrantholders of such adjustment computation.
Elimination of Positions Existing positions of special responsibility shall not be eliminated or changed without prior consultation with the Association.
NOTICE OF DELAYS Except as otherwise provided under this Contract, when either party has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this Contract, that party shall, within one (1) business day, give notice thereof, including all relevant information with respect thereto, to the other party.
