Customer Service, Dispute Resolution If you have a question about your XOOM charges or service you may contact XOOM directly by calling 0-000-000-0000 Monday – Friday 8 (eight) a.m. to 11 (eleven)p.m.
Invoice Disputes If you believe any delivered software or service does not conform to the warranties in this Agreement, you will provide us with written notice within thirty (30) days of your receipt of the applicable invoice. The written notice must contain reasonable detail of the issues you contend are in dispute so that we can confirm the issue and respond to your notice with either a justification of the invoice, an adjustment to the invoice, or a proposal addressing the issues presented in your notice. We will work with you as may be necessary to develop an action plan that outlines reasonable steps to be taken by each of us to resolve any issues presented in your notice. You may withhold payment of the amount(s) actually in dispute, and only those amounts, until we complete the action items outlined in the plan. If we are unable to complete the action items outlined in the action plan because of your failure to complete the items agreed to be done by you, then you will remit full payment of the invoice. We reserve the right to suspend delivery of all SaaS Services, including maintenance and support services, if you fail to pay an invoice not disputed as described above within fifteen (15) days of notice of our intent to do so.
CENTRAL DISPUTE RESOLUTION PROCESS The following process pertains exclusively to disputes and grievances on central matters that have been referred to the central process. In accordance with the School Board Collective Bargaining Act, 2014 central matters may also be grieved locally, in which case local grievance processes will apply. In the event that central language is being grieved locally, the local parties shall provide the grievance to their respective central agents.
Termination Procedures and Compensation During Dispute 7.1. After a Change in Control and during the term of this Agreement, any purported termination of the Executive's employment (other than by reason of death) shall be communicated by written Notice of Termination from one party hereto to the other party hereto in accordance with Section 10 hereof. For purposes of this Agreement, a "Notice of Termination" shall mean a notice which shall indicate the specific termination provision in this Agreement relied upon and shall set forth in reasonable detail the facts and circumstances claimed to provide a basis for termination of the Executive's employment under the provision so indicated. Further, a Notice of Termination for Cause issued by the Company is required to include a copy of a resolution duly adopted by the affirmative vote of not less than three-quarters (3/4) of the entire membership of the Board at a meeting of the Board which was called and held for the purpose of considering such termination (after reasonable notice to the Executive and an opportunity for the Executive, together with the Executive's Counsel, to be heard before the Board) finding that, in the good faith opinion of the Board, the Executive engaged in conduct set forth in clause (i) or (ii) of the definition of Cause herein, and specifying the particulars thereof in detail.
Applicable Law; Dispute Resolution i. This Agreement, and all claims, disputes or disagreements arising out of or connected with this Agreement, its validity or any breach thereof, shall be governed by the laws in effect in the State of Texas (excluding conflicts of laws provisions), and to the extent applicable to maritime issues, the maritime laws of the United States (excluding conflict of laws provisions).
ii. PHA and Carrier desire to resolve any dispute, which may arise in connection with the Agreement in a timely and efficient manner. The parties therefore agree that the parties will attempt to resolve disputes arising hereunder in accordance with the following procedures.
iii. Either party may request the other to attend a meeting for the purpose of resolving any dispute or disagreement arising from the provisions specified in the Agreement. Said meeting shall be held either in person in Houston, Texas, or by telephone within five (5) business days of receipt of written request specifying a brief description of the dispute, the monetary amount involved if known, and the remedies sought.
iv. If the matter is not resolved in such meeting, or if such meeting is not held, either party may make written demand to attempt to resolve such dispute by non-binding mediation. Within seven (7) days after service of written notice on the other party demanding mediation, the parties in dispute shall jointly agree upon a mediator, and within thirty (30) days thereafter the parties shall undertake such mediation in Houston, Texas. In no event shall the parties be obligated to pursue mediation that does not resolve the issue within thirty
GRIEVANCE AND ARBITRATION PROCEDURES A. A grievance is a dispute, claim, or complaint arising under this Agreement, filed by either an authorized representative of or an employee in the Bargaining Unit, or the County, involving the interpretation or application of this Agreement. All discipline shall be for just cause.
B. Grievances will be processed in the following manner and strictly in accordance with the following stated time limits:
Step 1. The aggrieved employee shall be accorded fifteen (15) working days from the occurrence of the action or event or when the employee has knowledge or should have had knowledge of the action or the event giving rise to the complaint to seek resolution on an informal basis. The Employee must discuss his alleged grievance with the Airport Fire Chief and the Fire Rescue Division Director. If informal resolution is not accomplished, the employee, if a Union member, must present the proposed grievance in writing to a Union officer on or before the fifteenth (15th) working day for consideration by the Union Grievance committee. If, in the Committee's opinion, no reasonable grievance exists, no further action may be taken.
Step 2. If the Committee wishes to pursue the member's complaint, a written grievance shall be presented to the Director of the Fire Rescue Division or his designee within twenty (20) working days from the occurrence of the action or event giving rise to the grievance or from the date on which the employee reasonably should have had knowledge of that occurrence. A written grievance must be presented on a grievance form provided by the County in Appendix A. Upon receipt of a formal grievance or a class action submitted by the Union, the Fire Rescue Division Director or his designee shall investigate the facts and conduct a meeting within five (5) working days with the aggrieved employee and any other persons possessing knowledge considered critical by the Director. The aggrieved employee may be accompanied at this meeting by a local Union representative. The Fire Rescue Division Director or his designee shall notify the grievant of his decision no later than five (5) working days following the date of the meeting.
Step 3. If the grievance is not resolved at the second step, the aggrieved employee shall present the written grievance within five (5) working days of the Step 2 decision to the Department Head. The Department Head or his designee shall investigate the facts and may conduct a hearing within five
Information About Your Right to Dispute Errors In case of errors or questions about your electronic transactions, call (000) 000-0000, contact Oxygen Support via the in-app messaging feature or send an email message to: xxxxxx@xxxxxxxxx.xxx as soon as you can, if you think your statement or receipt is wrong or if you need more information about a transaction listed on the statement or receipt. We must hear from you no later than 60 days after we sent the FIRST statement on which the problem or error appeared. You will need to tell us:
1. Your name, the Account number and/or 16-digit Card number;
2. Describe the error or the transfer you are unsure about, and explain why you believe there is an error or why you need more information: and
3. The dollar amount of the suspected error. If you provide this information orally, we may require that you send your complaint or question in writing within ten (10) business days. We will determine whether an error occurred within ten (10) business days after we hear from you and will correct any error promptly. If we need more time, however, we may take up to forty-five (45) days to investigate your complaint or question. If we decide to do this, we will credit your Account within ten (10) business days for the amount you think is in error, so that you will have use of the money during the time it takes to complete the investigation. If we ask you to put your complaint or question in writing and you do not provide it within ten (10) business days, we may not credit your Account. For errors involving a new Account, POS transactions, or foreign-initiated transactions, we may take up to ninety (90) days to investigate your complaint or question. For a new Account, we may take up to twenty
Informal Dispute Resolution Process 1. In the event there is a dispute under this Centralized Contract, the Contractor, OGS and Authorized User agree to exercise their best efforts to resolve the dispute as soon as possible. The Contractor, OGS and Authorized User shall, without delay, continue to perform their respective obligations under this Centralized Contract which are not affected by the dispute. Primary responsibility for resolving any dispute arising under this Centralized Contract shall rest with the Authorized User’s Contractor Coordinators and the Contractor’s Account Executive and the State & Local Government Regional General Manager.
2. In the event the Authorized User is dissatisfied with the Contractor’s Products provided under this Centralized Contract, the Authorized User shall notify the Contractor in writing pursuant to the terms of the Contract. In the event the Contractor has any disputes with the Authorized User, the Contractor shall so notify the Authorized User in writing. If either party notifies the other of such dispute, the other party shall then make good faith efforts to solve the problem or settle the dispute amicably, including meeting with the party’s representatives to attempt diligently to reach a satisfactory result through negotiation.
3. If negotiation between the Contractor and Authorized User fails to resolve any such dispute to the satisfaction of the parties within fourteen (14) business days or as otherwise agreed to by the Contractor and Authorized User, of such notice, then the matter shall be submitted to the State's Contract Administrator and the Contractor’s senior executive officer representative. Such representatives shall meet in person and shall attempt in good faith to resolve the dispute within the next fourteen (14) business days or as otherwise agreed to by the parties. This meeting must be held before either party may seek any other method of dispute resolution, including judicial or governmental resolutions. Notwithstanding the foregoing, this section shall not be construed to prevent either party from seeking and obtaining temporary equitable remedies, including injunctive relief.
4. The Contractor shall extend the informal dispute resolution period for so long as the Authorized User continues to make reasonable efforts to cure the breach, except with respect to disputes about the breach of payment of fees or infringement of its or its licensors’ intellectual property rights.
Dispute Resolution Process Any claim, dispute or other matter in question not resolved by the process identified in Paragraph
Arbitration Process Any arbitration will be conducted pursuant to the applicable rules (the “Arbitration Rules”) of the American Arbitration Association, as modified herein, to the extent such modifications are not prohibited by the Arbitration Rules. The arbitration will be conducted in Indianapolis, Indiana. The parties will select a single arbitrator, but in the event that the parties are unable to agree, the arbitrator will be appointed pursuant to the Arbitration Rules. The arbitrator will be a practicing attorney with significant expertise in litigating and/or presiding over cases involving the substantive legal areas involved in the dispute. The parties to the arbitration will not request, and the arbitrator will not order, that any discovery be taken or provided, including depositions, interrogatories or document requests, except to the extent the amount in controversy exceeds $50,000. The arbitration will be concluded within three months of the date the arbitrator is appointed. The arbitrator’s findings, reasoning, decision, and award will be stated in writing and based upon applicable law. Judgment on the arbitration award may be entered in any court having jurisdiction. In the event that the arbitration results in an award which imposes an injunction or contains a monetary award in excess of $100,000, the award will be reviewable on appeal initiated by filing notice of appeal with the AAA office within 30 days of the award, governed by the AAA Optional Appellate Arbitration Rules and conducted by a panel of three new arbitrators, ruling by majority, under the procedure for appointment from the national roster of arbitrators. Unless the applicable Arbitration Rules require otherwise, arbitration fees and costs will be shared equally by the claimant(s) and respondent(s), respectively, in any arbitration proceeding. Should the AAA be unavailable, unable or unwilling to accept and administer the arbitration of any claim under these arbitration provisions as written, the parties will agree on a substitute arbitration organization, such as JAMS, that will enforce the arbitration provisions as written. Because this Agreement memorializes a transaction in interstate commerce, the Federal Arbitration Act governs the interpretation and enforcement of these arbitration provisions. More information about arbitration, including the Arbitration Rules, is available at xxx.xxx.xxx or by calling 0-000-000-0000.
