Construction Management Services a. A-E may be required to review and recommend approval of submittals, shop drawings, Request for Information (RFI) and/or calculations for temporary structures such as trench shoring, false work and other temporary structural forms.
b. A-E may be required to review and advise the County Representative on the overall project schedule, including staging and completion dates, duration, milestones, and interfaces. Immediately notify Representative if the proposed work schedule does not conform to the contract documents, including the plans, specifications, and permits or that may require special inspection or testing, or work stoppage.
c. Review on a monthly basis the project schedule and/or Critical Path Method (CPM) schedule submitted by the Construction Contractor. Make recommendations concerning the Construction Contractor’s adherence thereto. Recommend possible solutions to scheduling problems so as to complete the project on time, within budget, and in accordance with the contract drawings and specifications.
d. Review scope of work and identify potential contract change orders. Prepare independent cost estimates for any changes resulting from design revisions or change in field conditions. Prepare and recommend for approval all contract change orders.
e. Evaluate the merit of any potential claims or requests for equitable adjustment submitted by the Construction Contractor. Prepare analysis of potential claims include recommendations regarding settlement of the claims.
f. Assist County staff in project related issues with other Agencies, or departments, engineering and material testing support firms, CEQA consultants, utilities agencies, etc.
g. Assist in community outreach meetings and media relations
h. Review for acceptance/approval of Storm Water Pollution Prevention Plan (SWPPP) in accordance with the general Permit of Discharges of Storm Water Associated with Construction Activity (Construction General Permit, including dewatering/diversion plans per the State’s DeMinimus Permit).
Case Management Prompt resolution of any dispute is important to both parties; and the parties agree that the arbitration of any dispute shall be conducted expeditiously. The arbitrators are instructed and directed to assume case management initiative and control over the arbitration process (including scheduling of events, pre-hearing discovery and activities, and the conduct of the hearing), in order to complete the arbitration as expeditiously as is reasonably practical for obtaining a just resolution of the dispute.
Asset Management Services (i) Real Estate and Related Services:
(a) Investigate, select and, on behalf of the Company, engage and conduct business with (including enter contracts with) such Persons as the Advisor deems necessary to the proper performance of its obligations as set forth in this Agreement, including but not limited to consultants, accountants, lenders, technical advisors, attorneys, brokers, underwriters, corporate fiduciaries, escrow agents, depositaries, custodians, agents for collection, insurers, insurance agents, developers, construction companies, Property Managers and any and all Persons acting in any other capacity deemed by the Advisor necessary or desirable for the performance of any of the foregoing services;
(b) Negotiate and service the Company’s debt facilities and other financings;
(c) Monitor applicable markets and obtain reports (which may be prepared by the Advisor or its Affiliates) where appropriate, concerning the value of investments of the Company;
(d) Monitor and evaluate the performance of each asset of the Company and the Company’s overall portfolio of assets, provide daily management services to the Company and perform and supervise the various management and operational functions related to the Company’s investments;
(e) Formulate and oversee the implementation of strategies for the administration, promotion, management, operation, maintenance, improvement, financing and refinancing, marketing, leasing and disposition of Properties, Loans and other Permitted Investments on an overall portfolio basis;
(f) Consult with the Company’s officers and the Board and assist the Board in the formulation and implementation of the Company’s financial policies, and, as necessary, furnish the Board with advice and recommendations with respect to the making of investments consistent with the investment objectives and policies of the Company and in connection with any borrowings proposed to be undertaken by the Company;
(g) Oversee the performance by the Property Managers of their duties, including collection and proper deposits of rental payments and payment of Property expenses and maintenance;
(h) Conduct periodic on-site property visits to some or all (as the Advisor deems reasonably necessary) of the Properties to inspect the physical condition of the Properties and to evaluate the performance of the Property Managers;
(i) Review, analyze and comment upon the operating budgets, capital budgets and leasing plans prepared and submitted by each Property Manager and aggregate these property budgets into the Company’s overall budget;
(j) Coordinate and manage relationships between the Company and any co-venturers or partners; and
(k) Consult with the Company’s officers and the Board and provide assistance with the evaluation and approval of potential asset dispositions, sales and refinancings.
(ii) Accounting and Other Administrative Services:
(a) Provide the day-to-day management of the Company and perform and supervise the various administrative functions reasonably necessary for the management of the Company;
(b) From time to time, or at any time reasonably requested by the Board, make reports to the Board on the Advisor’s performance of services to the Company under this Agreement;
(c) Make reports to the Conflicts Committee each quarter of the investments that have been made by other programs sponsored by the Advisor or any of its Affiliates, including KBS Realty Advisors LLC, as well as any investments that have been made by the Advisor or any of its Affiliates directly;
(d) Provide or arrange for any administrative services and items, legal and other services, office space, office furnishings, personnel and other overhead items necessary and incidental to the Company’s business and operations;
(e) Provide financial and operational planning services;
(f) Maintain accounting and other record-keeping functions at the Company and investment levels, including information concerning the activities of the Company as shall be required to prepare and to file all periodic financial reports, tax returns and any other information required to be filed with the SEC, the Internal Revenue Service and any other regulatory agency;
(g) Maintain and preserve all appropriate books and records of the Company;
(h) Provide tax and compliance services and coordinate with appropriate third parties, including the Company’s independent auditors and other consultants, on related tax matters;
(i) Provide the Company with all necessary cash management services;
(j) Manage and coordinate with the transfer agent the dividend process and payments to Stockholders;
(k) Consult with the Company’s officers and the Board and assist the Board in evaluating and obtaining adequate insurance coverage based upon risk management determinations;
(l) Provide the Company’s officers and the Board with timely updates related to the overall regulatory environment affecting the Company, as well as managing compliance with such matters, including but not limited to compliance with the Xxxxxxxx-Xxxxx Act of 2002;
(m) Consult with the Company’s officers and the Board relating to the corporate governance structure and appropriate policies and procedures related thereto;
(n) Perform all reporting, record keeping, internal controls and similar matters in a manner to allow the Company to comply with applicable law, including federal and state securities laws and the Xxxxxxxx-Xxxxx Act of 2002;
(o) Notify the Board of all proposed material transactions before they are completed; and
(p) Do all things necessary to assure its ability to render the services described in this Agreement.
Inpatient Services Hospital Rehabilitation Facility
Investment Management Services (a) The Manager shall manage the Fund’s assets subject to and in accordance with the investment objectives and policies of the Fund and any directions which the Trust’s Board of Trustees may issue from time to time. In pursuance of the foregoing, the Manager shall make all determinations with respect to the investment of the Fund’s assets and the purchase and sale of its investment securities, and shall take such steps as may be necessary to implement the same. Such determinations and services shall include determining the manner in which any voting rights, rights to consent to corporate action and any other rights pertaining to the Fund’s investment securities shall be exercised. The Manager shall render or cause to be rendered regular reports to the Trust, at regular meetings of its Board of Trustees and at such other times as may be reasonably requested by the Trust’s Board of Trustees, of (i) the decisions made with respect to the investment of the Fund’s assets and the purchase and sale of its investment securities, (ii) the reasons for such decisions and (iii) the extent to which those decisions have been implemented.
(b) The Manager, subject to and in accordance with any directions which the Trust’s Board of Trustees may issue from time to time, shall place, in the name of the Fund, orders for the execution of the Fund’s securities transactions. When placing such orders, the Manager shall seek to obtain the best net price and execution for the Fund, but this requirement shall not be deemed to obligate the Manager to place any order solely on the basis of obtaining the lowest commission rate if the other standards set forth in this section have been satisfied. The parties recognize that there are likely to be many cases in which different brokers are equally able to provide such best price and execution and that, in selecting among such brokers with respect to particular trades, it is desirable to choose those brokers who furnish research, statistical, quotations and other information to the Fund and the Manager in accordance with the standards set forth below. Moreover, to the extent that it continues to be lawful to do so and so long as the Board of Trustees determines that the Fund will benefit, directly or indirectly, by doing so, the Manager may place orders with a broker who charges a commission for that transaction which is in excess of the amount of commission that another broker would have charged for effecting that transaction, provided that the excess commission is reasonable in relation to the value of “brokerage and research services” (as defined in Section 28(e)(3) of the Securities Exchange Act of 1934) provided by that broker. Accordingly, the Trust and the Manager agree that the Manager shall select brokers for the execution of the Fund’s transactions from among:
(i) Those brokers and dealers who provide quotations and other services to the Fund, specifically including the quotations necessary to determine the Fund’s net assets, in such amount of total brokerage as may reasonably be required in light of such services; and
(ii) Those brokers and dealers who supply research, statistical and other data to the Manager or its affiliates which the Manager or its affiliates may lawfully and appropriately use in their investment management capacities, which relate directly to securities, actual or potential, of the Fund, or which place the Manager in a better position to make decisions in connection with the management of the Fund’s assets and securities, whether or not such data may also be useful to the Manager and its affiliates in managing other portfolios or advising other clients, in such amount of total brokerage as may reasonably be required.
(c) The Manager shall render regular reports to the Trust, not more frequently than quarterly, of how much total brokerage business has been placed by the Manager, on behalf of the Fund, with brokers falling into each of the categories referred to above and the manner in which the allocation has been accomplished.
(d) The Manager agrees that no investment decision will be made or influenced by a desire to provide brokerage for allocation in accordance with the foregoing, and that the right to make such allocation of brokerage shall not interfere with the Manager’s paramount duty to obtain the best net price and execution for the Fund.
(e) Decisions on proxy voting shall be made by the Manager unless the Board of Trustees determines otherwise. Pursuant to its authority, the Manager shall have the power to vote, either in person or by proxy, all securities in which the Fund may be invested from time to time, and shall not be required to seek or take instructions from the Fund with respect thereto. The Manager shall not be expected or required to take any action other than the rendering of investment-related advice with respect to lawsuits involving securities presently or formerly held in the Fund, or the issuers thereof, including actions involving bankruptcy. In the case of class action suits involving issuers held in the Fund, the Manager may include information about the Fund for purposes of participating in any settlements.
EFT SERVICES If approved, you may conduct any one (1) or more of the EFT services offered by the Credit Union.
Management Services The Adviser shall perform (or arrange for the performance by its affiliates of) the management and administrative services necessary for the operation of the Fund. The Adviser shall, subject to the supervision of the Board of Trustees, perform various services for the Portfolio, including but not limited to: (i) providing the Portfolio with office space, equipment and facilities (which may be its own) for maintaining its organization; (ii) on behalf of the Portfolio, supervising relations with, and monitoring the performance of, custodians, depositories, transfer and pricing agents, accountants, attorneys, underwriters, brokers and dealers, insurers and other persons in any capacity deemed to be necessary or desirable; (iii) preparing all general shareholder communications, including shareholder reports; (iv) conducting shareholder relations; (v) maintaining the Fund's existence and its records; (vi) during such times as shares are publicly offered, maintaining the registration and qualification of the Portfolio's shares under federal and state law; and (vii) investigating the development of and developing and implementing, if appropriate, management and shareholder services designed to enhance the value or convenience of the Portfolio as an investment vehicle. The Adviser shall also furnish such reports, evaluations, information or analyses to the Fund as the Fund's Board of Trustees may request from time to time or as the Adviser may deem to be desirable. The Adviser shall make recommendations to the Fund's Board of Trustees with respect to Fund policies, and shall carry out such policies as are adopted by the Trustees. The Adviser shall, subject to review by the Board of Trustees, furnish such other services as the Adviser shall from time to time determine to be necessary or useful to perform its obligations under this Contract.
Utilization Management Contractor shall maintain a utilization management program that complies with applicable laws, rules and regulations, including Health and Safety Code § 1367.01 and other requirements established by the applicable State Regulators responsible for oversight of Contractor.
Development Services During the term of this Agreement, the Provider agrees to provide to or on behalf of the Port the professional services and related items described in Exhibit A (collectively, the “Development Services”) in accordance with the terms and conditions of this Agreement. The Provider specifically agrees to include at least one Port representative in any economic development negotiations or discussions in which the Provider is involved concerning (i) a port-related business prospect or (ii) a business transaction which will ultimately require Port involvement, financial or otherwise.
Disease Management If you have a chronic condition such as asthma, coronary heart disease, diabetes, congestive heart failure, and/or chronic obstructive pulmonary disease, we’re here to help. Our tools and information can help you manage your condition and improve your health. You may also be eligible to receive help through our care coordination program. This voluntary program is available at no additional cost you. To learn more about disease management, please call (000) 000-0000 or 0-000-000-0000. Our entire contract with you consists of this agreement and our contract with your employer. Your ID card will identify you as a member when you receive the healthcare services covered under this agreement. By presenting your ID card to receive covered healthcare services, you are agreeing to abide by the rules and obligations of this agreement. Your eligibility for benefits is determined under the provisions of this agreement. Your right to appeal and take action is described in Appeals in Section 5. This agreement describes the benefits, exclusions, conditions and limitations provided under your plan. It shall be construed under and shall be governed by the applicable laws and regulations of the State of Rhode Island and federal law as amended from time to time. It replaces any agreement previously issued to you. If this agreement changes, an amendment or new agreement will be provided.
