General Responsibilities of the Parties 1. The Parties will work together in a spirit of cooperation and partnership, with the responsibilities and accountabilities set out in this Agreement, to implement the Programme Documents in full in a timely, efficient, and effective, manner.
2. The Parties agree to carry out their respective responsibilities in accordance with the provisions of this Agreement, including the Programme Documents.
3. The Parties shall keep each other informed of all relevant activities pertaining to the implementation of the Programme Documents, and shall hold consultations when either Party considers it appropriate, including any circumstance that may affect the achievement of the results of the Programme and the Programme Documents.
4. The Parties shall fulfill their commitments with the fullest regard for the terms and conditions of this Agreement and the principles of the United Nations.
Additional Responsibilities This paragraph applies to all phases of Architect's work.
(a) Architect shall be responsible for the professional quality, technical accuracy, timely completion and coordination of all of Architect's work, including that performed by Architect's consultants, and including designs, Drawings, Specifications, reports and other services, irrespective of Owner's approval or acquiescence in same. Architect shall, without additional compensation, correct or revise any errors, omissions or other deficiencies in his work.
(b) Architect shall be responsible, in accordance with applicable law, to Owner for all loss or damage to Owner caused by Architect's negligent act or omission; except that Architect hereby irrevocably waives and excuses Owner and its attorneys from compliance with any requirement to obtain a certificate of review as a condition precedent to commencement of an action, including any such requirements set forth in Section 00-00-000, C.R.S. or similar statute.
(c) Architect's professional responsibility shall comply with the standard of care applicable to the type of engineering and architectural services provided, commensurate with the size, scope and nature of the Project.
(d) Architect shall be completely responsible for the safety of Architect's employees in the execution of work under this Agreement, shall provide all necessary safety equipment for said employees, and shall hold harmless and indemnify and defend Owner from any and all claims, suits, loss or injury to Architect's employees.
(e) Architect acknowledges that, due to the nature of architectural and related professional services and the impact of same on the Project, the Owner has a substantial interest in the personnel and consultants to whom Architect assigns principal responsibility for services performed under this Agreement. Consequently, Architect represents that Architect has selected and intends to employ or assign the key personnel and consultants identified in Appendix C - "Identification of Personnel, Subcontractors and Task Responsibility", attached hereto for the Project assignments and areas of responsibility stated therein. Within 10 days of execution of this Agreement, Owner shall have the right to object in writing to employment on the Project of any such key person, consultant or assignment of principal responsibility, in which case Architect will employ alternate personnel for such function or reassign such responsibility to another to whom Owner has no reasonable objection. Thereafter, Architect shall not assign or reassign Project work to any person to whom Owner has reasonable objection. Within 5 days of execution of this Agreement, Architect shall designate in writing a Project representative who shall have complete authority to bind Architect, and to whom Owner should address communications.
(f) Promptly after execution of this Agreement and upon receipt of authorization from Owner to proceed, Architect shall submit to Owner for approval a schedule showing the order in which Architect proposes to accomplish his work, with dates on which he will commence and complete each major work item. The schedule shall provide for performance of the work in a timely manner so as to not delay Owner's time table for achievement of interim tasks and final completion of Project work, provided however, the Architect will not be responsible for delays beyond his control.
(g) Before undertaking any work which Architect considers beyond or in addition to the scope of work and services which Architect has contractually agreed to perform under the terms of this Agreement, Architect shall advise Owner in writing (i) that Architect considers the work beyond the scope of this Agreement, (ii) the reasons the Architect believes the out of scope or additional work should be performed, and (iii) a reasonable estimate of the cost of such work. Architect shall not proceed with such out of scope or additional work until authorized in writing by Owner. The compensation for such authorized work shall be negotiated, but in the event the parties fail to negotiate or are unable to agree as to compensation, then Architect shall be compensated for his direct costs and professional time at the rates set forth in Appendix B - "Fee Schedule".
Contractor’s General Responsibilities The Contractor, regardless of any delegation or subcontract entered by the Contractor, shall be responsible for the following when providing information technology staff augmentation services:
3.1 The Contractor is responsible for the comprehensive management of Staff. Staff shall not be deemed an employee of the State or deemed to be entitled to any benefits associated with such employment and the Contractor shall be responsible for the administration and maintenance of all employment and payroll records, payroll processing, remittance of payroll and taxes, and all administrative tasks required by state and federal law associated with payment of Staff.
3.2 The Contractor shall provide Staff in accordance with Customer Requests for Quote (RFQ), and as described in Contract Exhibit J, Job Family Descriptions document. Customers may include detailed scopes of work, specific requirements of the work to be performed, and any requirements of Staff within the Request for Quote.
3.3 The Contractor shall possess the professional and technical staff necessary to allocate, outsource, and manage qualified Staff to perform the services requested by the Customer.
3.4 The Contractor shall provide Customers with Staff who have sufficient skill and experience to perform the services assigned to them.
3.5 The Contractor is responsible for ensuring that all information technology staff augmentation services furnished under the Contract meet the professional standards and quality that prevails among information technology professionals in the same discipline and of similar knowledge and skill engaged in related work throughout Florida under the same or similar circumstances.
3.6 The Contractor shall provide, at its own expense, training necessary for keeping Contractor’s Staff abreast of industry advances and for maintaining proficiency in equipment and systems that are available on the commercial market.
3.7 The Contractor shall, at its own expense, be responsible for adhering to the Contract background screening requirements, testing, evaluations, advertising, recruitment, and disciplinary actions of Contractor’s Staff.
3.8 The Contractor, throughout the term of the Contract, shall maintain all licenses, permits, qualifications, insurance, and approvals of whatever nature that are legally required for Contractor and Staff to perform the information technology staff augmentation services.
3.9 Contractor shall be responsible for all costs associated with the administration of this Contract.
3.10 The Contractor shall adhere to all work policies, procedures, and standards established by the Department and Customer.
3.11 The Contractor shall ensure that Staff conform with the Customer’s policies in all respects while on the Customer’s premises, and is responsible for obtaining all rules, regulations, policies, etc.
3.12 Contractor shall only provide information technology staff augmentation services for those Job Titles awarded to the Contractor and shall be paid on an hourly basis. Contracts resulting from this solicitation should not be structured as fixed-price agreements or used for any services requiring authorization for payment of milestone tasks.
Mutual Responsibilities It is recognized by this Agreement to be the duty of the Company to explain fully the terms of this Agreement to all its officers, foremen and others engaged in a supervisory capacity and it is recognized to be the duty of the Union to explain fully to its members, its and their responsibilities and obligations under this Agreement.
School Responsibilities Pursuant to §1002.33(8)(e), F.S., the School shall be dissolved under the provisions of law under which the School was organized. Student records and copies of all administrative, operational, and financial records of the School shall be provided to the Sponsor on the date the termination/non-renewal takes effect.
Cost Responsibility for Interconnection Facilities and Distribution Upgrades 4.1 Interconnection Facilities 4.2 Distribution Upgrades
Custodial Responsibilities (a) Each Custodian shall provide access to the Mortgage Loan Documents in possession of the applicable Custodian regarding the related Mortgage Loans and REO Property and the servicing thereof to the Trustee, the Certificateholders, the FDIC, and the supervisory agents and examiners of the FDIC, such access being afforded only upon reasonable prior written request and during normal business hours at the office of the applicable Custodian. Each Custodian shall allow representatives of the above entities to photocopy any of the records and documentation and shall provide equipment for that purpose at the expense of the person requesting such access.
(b) Each Custodian may resign from its obligations hereunder upon 60 days' prior written notice to the Trustee, the Depositor, the Securities Administrator and the Servicers. Such resignation shall take effect upon (i) the appointment of a successor Custodian reasonably acceptable to the Depositor within such 60 day period; and (ii) delivery of all Mortgage Loan Files to the successor Custodian. The Trustee shall have the right, but not the obligation, to become the successor Custodian. If no successor Custodian is appointed within 60 days after written notice of such Custxxxxx'x xesignation is received by the Trustee, the applicable Custxxxxx xxx petition a court of competent jurisdiction to appoint a successor Custodian. Upon such resignation and appointment of succesxxx Xxxxxdian, the applicable Custodian shall, at such Custodian's expense, xxxxxxxx transfer to the successor Custodian, as directed in writing by the Trustee, all applicable Mortgage Files being administered under this Agreement. Notwithstanding the foregoing, the Trust Fund, not the applicable Custodian, shall bear the costs relating to the transfer of Mortgage Files if such Custodian shall resign with cause (including such Custodian's resignation due to the failure of such Custodian to be paid xxx xxxx due to such Custodian hereunder).
(c) For so long as reports are required to be filed with the Commission under the Exchange Act with respect to the Trust, each Custodian shall not utilize any Subcontractor for the performance of its duties hereunder if such Subcontractor would be "participating in the servicing function" within the meaning of Item 1122 of Regulation AB without the prior written consent of the Depositor, in its sole discretion.
(d) Each Custodian shall indemnify the Depositor, the Sponsor, the Securities Administrator and any director, officer, employee, agent and affiliate of the Depositor, the Sponsor or the Securities Administrator and hold them harmless against any and all claims, losses, damages, penalties, fines, forfeitures, reasonable and necessary legal fees and related costs, judgments, and any other costs, fees and expenses that any of them may sustain in any way related to (i) the failure of the applicable Custodian to deliver when required any assessment of compliance required to be delivered by the applicable Custodian or (ii) any material misstatement or omission contained in any assessment of compliance provided to be delivered by the applicable Custodian. This indemnity shall survive the termination of this Agreement or the earlier resignation or removal of the applicable Custodian.
(e) Notwithstanding anything in this Agreement to the contrary, no Custodian shall be required to deliver, or to cause to be delivered, an assessment of compliance or accountant's attestation report pursuant to Section 3.23 for any fiscal year of the Trust in which the Custodian's Weighted Average Percentage is 5% or less. The "Custodian's Weighted Average Percentage" means, for each fiscal year of the Trust and each Custodian, the quotient, expressed as a percentage, of (A) the aggregate of the Stated Principal Balance for each Distribution Date in such fiscal year of the Mortgage Loans for which such Custodian acted as Custodian divided by (B) the aggregate of the Pool Stated Principal Balance for each Distribution Date in such fiscal year.
General Responsibilities Issuer hereby engages Distributor to act as exclusive distributor of the shares of each class of the Funds. The Funds subject to this Agreement as of the date hereof are identified on SCHEDULE A, which may be amended from time to time in accordance with Section 11 below. Sales of a Fund's shares shall be made only to investors residing in those states in which such Fund is registered. After effectiveness of each Fund’s registration statement, Distributor will hold itself available to receive, as agent for the Fund, and will receive by mail, telex, telephone, or such other method as may be agreed upon between Distributor and Issuer, orders for the purchase of Fund shares, and will accept or reject such orders on behalf of the Fund in accordance with the provisions of the applicable Fund’s prospectus. Distributor will be available to transmit orders, as promptly as possible after it accepts such orders, to the Fund’s transfer agent for processing at the shares’ net asset value next determined in accordance with the prospectuses.
PROFESSIONAL RESPONSIBILITY (APPLIES TO RNS ONLY 19.01 The parties agree that resident care is enhanced if concerns relating to professional practice and workload are resolved in a timely and effective manner, as set out below; In the event that the Home assigns a number of residents or a workload to an individual employee or group of employees, such that she or they have cause to believe that she or they are being asked to perform more work than is consistent with proper resident care, she or they shall:
i) At the time the workload issue occurs, discuss the issue within the Home to develop strategies to meet resident care needs using current resources. If necessary, using established lines of communication, seek immediate assistance from an individual(s) identified by the Home who has responsibility for timely resolution of workload issues.
ii) Failing resolution at the time of occurrence of the workload issue, complain in writing to the Union-Management Committee within twenty (20) calendar days of the alleged improper assignment. The chairperson of the Union-Management Committee shall convene a meeting of the Union-Management Committee within twenty (20) calendar days of the filing of the complaint. The Union-Management Committee shall hear and attempt to resolve the complaint to the satisfaction of both parties. The Employer will provide a written response to the Union, with a copy to the ONA representation within ten (10) calendar days.
iii) Prior to the complaint being forwarded to the Independent Assessment Committee, the Union may forward a written report outlining the complaint and recommendations to the Director of Resident Care and/or the Administrator.
iv) At any time during this process, the parties may agree to the use of a mediator to assist in the resolution of the Professional Practice issues.
v) Any settlement arrived at under 19.01 (a) i) – iii) shall be signed by the parties.
vi) Failing resolution of the complaint within twenty (20) calendar days of the meeting of the Union-Management Committee, the complaint shall be forwarded to an independent Assessment Committee composed of three (3) registered nurses; one chosen by the Ontario Nurses' Association, one chosen by the Home and one chosen from a panel of independent registered nurses who are well respected within the profession. The member of the Committee chosen from the panel of independent registered nurses shall act as Chairperson.
vii) The Independent Assessment Committee shall set a date to conduct a hearing into the complaint, within twenty (20) calendar days of its appointment, and shall be empowered to investigate as is necessary to properly assess the merits of the complaint. The Independent Assessment Committee shall report its findings, in writing, to the parties within twenty (20) calendar days following completion of its hearing.
(b) i) The list of Independent Assessment Committee Chairpersons is attached as Appendix “B”. The members of the panel shall sit in rotation as agreed by the parties. If a panel member is unable to sit within the time limit stipulated, the panel member next scheduled to sit will be appointed by the parties.
Requester and Approved User Responsibilities The Requester agrees through the submission of the DAR that the PI named has reviewed and understands the principles for responsible research use and data management of the genomic datasets as defined in the NIH Security Best Practices for Controlled-Access Data Subject to the GDS Policy. The Requester and Approved Users further acknowledge that they are responsible for ensuring that all uses of the data are consistent with national, tribal, and state laws and regulations, as appropriate, as well as relevant institutional policies and procedures for managing sensitive genomic and phenotypic data. The Requester certifies that the PI is in good standing (i.e., no known sanctions) with the institution, relevant funding agencies, and regulatory agencies and is eligible to conduct independent research (i.e., is not a postdoctoral fellow, student, or trainee). The Requester and any Approved Users may use the dataset(s) only in accordance with the parameters described on the study page and in the 1 If contractor services are to be utilized, PI requesting the data must provide a brief description of the services that the contractor will perform for the PI (e.g., data cleaning services) in the research use statement of the DAR. Additionally, the Key Personnel section of the DAR must include the name of the contractor’s employee(s) who will conduct the work. These requirements apply whether the contractor carries out the work at the PI’s facility or at the contractor’s facility. In addition, the PI is expected to include in any contract agreement requirements to ensure that any of the contractor’s employees who have access to the data adhere to the NIH GDS Policy, this Data Use Certification Agreement, and the NIH Security Best Practices for Controlled-Access Data Subject to the GDS Policy. Note that any scientific collaborators, including contractors, who are not at the Requester must submit their own DAR. Addendum to this Agreement for the appropriate research use, as well as any limitations on such use, of the dataset(s), as described in the DAR, and as required by law. Through the submission of this DAR, the Requester and Approved Users acknowledge receiving and reviewing a copy of the Addendum which includes Data Use Limitation(s) for each dataset requested. The Requester and Approved Users agree to comply with the terms listed in the Addendum. Through submission of the DAR, the PI and Requester agree to submit a Project Renewal or Project Close-out prior to the expiration date of the one (1) year data access period. The PI also agrees to submit an annual Progress Update prior to the one (1) year anniversary2 of the project, as described under Research Use Reporting (Term 10) below. By approving and submitting the attached DAR, the Institutional Signing Official provides assurance that relevant institutional policies and applicable local, state, tribal, and federal laws and regulations, as applicable, have been followed, including IRB approval, if required. Approved Users may be required to have IRB approval if they have access to personal identifying information for research participants in the original study at their institution, or through their collaborators. The Institutional Signing Official also assures, through the approval of the DAR, that other institutional departments with relevant authorities (e.g., those overseeing human subjects research, information technology, technology transfer) have reviewed the relevant sections of the NIH GDS Policy and the associated procedures and are in agreement with the principles defined. The Requester acknowledges that controlled-access datasets subject to the NIH GDS Policy may be updated to exclude or include additional information. Unless otherwise indicated, all statements herein are presumed to be true and applicable to the access and use of all versions of these datasets.
