PERFORMANCE, DELAYS AND EXTENSIONS OF TIME Sample Clauses

PERFORMANCE, DELAYS AND EXTENSIONS OF TIME. 8.2.1 The Contractor shall begin the Work on the Date of Commencement and shall carry the Work forward expeditiously with adequate forces.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
PERFORMANCE, DELAYS AND EXTENSIONS OF TIME. 8.2.1 The Contractor shall begin the Work on the Date of Commencement and shall carry the Work forward expeditiously with adequate forces. 8.2.2 The Contractor shall not commence construction work until all insurance (other than property insurance) is effective. The Contract Time shall not be extended as a result of the Contractor’s failure to obtain insurance. 8.2.3 If in the sole opinion of the State, the Contractor fails to commence work on the project or to complete the Work within agreed-upon the time limits, or to perform the Work in such a manner that it appears that the completion date can be assured, the State shall have the right to notify the Contractor and surety, if any, by Certified Mail that the terms of the Contract have been violated, and that within seven (7) days the Contract will be terminated and that the State has the right to and in fact will take over and attend to completion of the Project without prejudice to the State’s remedies for any losses sustained. 8.2.4 If the Contractor is delayed at any time in the progress of the Work by any act or failure to act by the State, or by any State employee, or by any separate Contractor of the State, or by changes ordered in the Work, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, or any causes beyond the Contractor's control, or by delay authorized by the State pending alternative dispute resolution proceedings, or by any other cause which may justify the delay, then the Contract Time shall be extended by Change Order for such reasonable time as agreed upon by the Contractor and Project Manager. 8.2.5 Any claim for extension of time shall be made in writing to the Project Manager not more than twenty days after the commencement of the delay; otherwise it shall be waived. In the case of a continuing delay only one claim is necessary. The Contractor shall provide an estimate of 8.2.6 This Paragraph 8.2 does not exclude the recovery of damages for delay by either party under other provisions of the Contract Documents.
Sample 1

Related to PERFORMANCE, DELAYS AND EXTENSIONS OF TIME

  • DELAYS AND EXTENSIONS OF TIME 8.3.1 If the Contractor is delayed at any time in the progress of the Work by any act or failure to act by the State or the Architect, or by any employee of either, or by any separate contractor employed by the State, or by changes ordered in the Work, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, or any causes beyond the Contractor's control, or by delay authorized by the State pending alternative dispute resolution proceedings, or by any other cause which may justify the delay, then the Contract Time shall be extended by Change Order for such reasonable time as recommended by the Architect and approved by the State.

  • Delays and Extension of Time If the Contractor is delayed at any time in the progress of providing goods and/or services by an act or neglect of the District, or by changes ordered in the work, or by labor disputes, strikes, insurrections, fire, acts of God; unusual but well documented and excusable delays in performance, or other causes beyond the Contractor’s control, or by delay authorized by the District, then the contract Term of service may be extended by a contract amendment for such reasonable time as the District and the Contractor may agree.

  • Delays and Extensions The CONSULTANT agrees that no charges or claim for damages shall be made by it for any minor delays from any cause whatsoever during the progress of any portion of the Services specified in this Contract. Such delays, if any, shall be compensated for by an extension of time for such period as may be determined by the LPA subject to the CONSULTANT's approval, it being understood, however, that permitting the CONSULTANT to proceed to complete any services, or any part of them after the date to which the time of completion may have been extended, shall in no way operate as a waiver on the part of the LPA of any of its rights herein. In the event of substantial delays or extensions, or change of any kind, not caused by the CONSULTANT, which causes a material change in scope, character or complexity of work the CONSULTANT is to perform under this Contract, the LPA at its sole discretion shall determine any adjustments in compensation and in the schedule for completion of the Services. CONSULTANT must notify the LPA in writing of a material change in the work immediately after the CONSULTANT first recognizes the material change.

  • Extensions of Time 34.1 If at any time during performance of the Contract, the Supplier or its subcontractors should encounter conditions impeding timely delivery of the Goods or completion of Related Services pursuant to GCC Clause 13, the Supplier shall promptly notify the Procuring Entity in writing of the delay, its likely duration, and its cause. As soon as practicable after receipt of the Supplier's notice, the Procuring Entity shall evaluate the situation and may at its discretion extend the Supplier's time for performance, in which case the extension shall be ratified by the parties by amendment of the Contract.

  • MODIFICATIONS AND INTERRUPTIONS We reserve the right to change, modify, or remove the contents of the Services at any time or for any reason at our sole discretion without notice. However, we have no obligation to update any information on our Services. We will not be liable to you or any third party for any modification, price change, suspension, or discontinuance of the Services. We cannot guarantee the Services will be available at all times. We may experience hardware, software, or other problems or need to perform maintenance related to the Services, resulting in interruptions, delays, or errors. We reserve the right to change, revise, update, suspend, discontinue, or otherwise modify the Services at any time or for any reason without notice to you. You agree that we have no liability whatsoever for any loss, damage, or inconvenience caused by your inability to access or use the Services during any downtime or discontinuance of the Services. Nothing in these Legal Terms will be construed to obligate us to maintain and support the Services or to supply any corrections, updates, or releases in connection therewith.

  • Extension of Time If the Executive shall be in violation of any provision of this Article 6, then each time limitation set forth in this Article 6 shall be extended for a period of time equal to the period of time during which such violation or violations occur. If the Company seeks injunctive relief from such violation in any court, then the covenants set forth in this Article 6 shall be extended for a period of time equal to the pendency of such proceeding including all appeals by the Executive.

  • No Extension of Time If Owner’s determination proves valid that good cause existed to believe a violation had occurred, Contractor is not entitled to an extension of time for any delay arising directly or indirectly from the arbitration procedures.

  • Definitions and Other Provisions of General Application SECTION 101.

  • Definitions of General Application For purposes of this Agreement, unless otherwise specified: Agreement means the Free Trade Agreement between the Government of the People's Republic of China and the Government of the Republic of Peru; Commission means the Free Trade Commission established under Article 170 (Free Trade Commission) of Chapter 14 (Administration of the Agreement);

  • Definitions and Interpretations The terms "specifically approved at least annually," "vote of a majority of the outstanding voting securities," "assignment," "affiliated person," and "interested person," when used in this Agreement, shall have the respective meanings specified, and shall be construed in a manner consistent with, the Investment Company Act of 1940 and the rules and regulations promulgated thereunder. Any question of interpretation of any term or provision of this Agreement having a counterpart in or otherwise derived from a term or provision of the Investment Company Act of 1940, the Investment Advisers Act of 1940, the Securities Act of 1933, or the Securities Exchange Act of 1934 (collectively, the "Federal Securities Acts") shall be resolved by reference to such term or provision of the Federal Securities Acts and to interpretations thereof, if any, by United States federal courts or, in the absence of any controlling decisions of any such court, by rules or regulations of the Securities and Exchange Commission. Where the effect of a requirement of the Federal Securities Acts reflected in any provision of this Agreement is revised by rule or regulation of the Securities and Exchange Commission, such provisions shall be deemed to incorporate the effect of such rule or regulation.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!