PROJECT ADMINISTRATION AND DELIVERABLES Sample Clauses

PROJECT ADMINISTRATION AND DELIVERABLES. The Recipient shall be responsible for the following: • Complete and obtain final project design, construction plans, and specifications; • Obtain all required permits, including right of access to the project sites, related to project construction and subsequent operation and maintenance of the completed work; • Assure compliance with all permits and permit conditions; • Provide procurement for project construction; • Perform supervision and inspection of construction; • Perform construction contract administration; • Assure compliance with cost accounting practices and procedures required for reimbursement of cost share funds expended. The Recipient shall provide the following to the District’s Project Manager: • Timely invoices for actual construction costs in accordance with this cost share agreement (i.e. quarterly, with appropriate substantiation that demonstrates that the applicant has paid for the total work cost and is seeking reimbursement up to the match amount) to enable proper review by the District’s Project Manager prior to payment authorization. Deliverables to be submitted with invoices include (as applicable): o Interim progress status summaries including inspections, meeting minutes and field notes and dated color photographs of the construction completed to include on-going work that represents the time-period being invoiced; o Final invoice submittals for completed construction including inspections and dated color photographs of the construction site prior to, during and immediately following completion of the construction task; o Construction plans, specifications, and contract documents for the site work must be made available upon request; o Written verification that the record drawings and any required final inspection reports for the project are received; o Quarterly progress reports identifying project progress to date, key milestones reached, overall project schedule versus time for project completion, an updated spend-down plan, key issues to be resolved, project construction photos with dates. Quarterly reports shall also be emailed to the District’s Budget Analyst at xxxxxxxx@xxxxxx.xxx. o Certification of construction completion by a Professional Engineer registered in the state of Florida. The Recipient shall ensure the task in the Task Identification section below is completed.
Sample 1See All (4)
AutoNDA by SimpleDocs

Related to PROJECT ADMINISTRATION AND DELIVERABLES

  • Project Administration The Contractor shall provide project administration for all Subcontractors, vendors, suppliers, and others involved in implementing the Work and shall coordinate administration efforts with those of the A/E and ODR in accordance with these Uniform General and Supplementary Conditions and provisions of Division 1 Specifications, and as outlined in the Pre- construction Conference.

  • Project Administration Designation Pursuant to Paragraph (B) of Rule 164-1-21 of the Administrative Code, the Recipient shall designate its Chief Executive Officer, Chief Fiscal Officer and Project Manager in Appendix B of this Agreement. Changes in these designations must be made in writing.

  • CONTRACT ADMINISTRATION & NOTICES Except for legal notices, the parties hereby designate the following contract administrators as the respective single points of contact for purposes of this Master Contract. Enterprise Services’ contract administrator shall provide Master Contract oversight. Contractor’s contract administrator shall be Contractor’s principal contact for business activities under this Master Contract. The parties may change contractor administrators by written notice as set forth below. Any notices required or desired shall be in writing and sent by U.S. mail, postage prepaid, or sent via email, and shall be sent to the respective addressee at the respective address or email address set forth below or to such other address or email address as the parties may specify in writing:

  • Agreement Administration SBBC has delegated authority to the Superintendent of Schools or his/her designee to take any actions necessary to implement and administer this Agreement.

  • Contract Administration The Delegate shall cause that the foreign custody arrangements with an Eligible Foreign Custodian shall be governed by a written contract that the Delegate has determined will provide reasonable care for Fund assets based on the standards applicable to custodians in the relevant market. Each such contract shall, except as set forth in the last paragraph of this subsection (b), include provisions that provide: (i) For indemnification or insurance arrangements (or any combination of the foregoing) such that the Fund will be adequately protected against the risk of loss of assets held in accordance with such contract; (ii) That the Fund's Assets will not be subject to any right, charge, security interest, lien or claim of any kind in favor of the Eligible Foreign Custodian or its creditors except a claim of payment for their safe custody or administration or, in the case of cash deposits, liens or rights in favor of creditors of such Custodian arising under bankruptcy, insolvency or similar laws; (iii) That beneficial ownership of the Fund's Assets will be freely transferable without the payment of money or value other than for safe custody or administration; (iv) That adequate records will be maintained identifying the Fund's Assets as belonging to the Fund or as being held by a third party for the benefit of the Fund; (v) That the Fund's independent public accountants will be given access to those records described in (iv) above or confirmation of the contents of such records; and (vi) That the Delegate will receive sufficient and timely periodic reports with respect to the safekeeping of the Fund's Assets, including, but not limited to, notification of any transfer to or from the Fund's account or a third party account containing the Fund's Assets. Such contract may contain, in lieu of any or all of the provisions specified in this Section 3(b), such other provisions that the Delegate determines will provide, in their entirety, the same or a greater level of care and protection for the Fund's Assets as the specified provisions, in their entirety.

  • Information Systems Acquisition Development and Maintenance a. Client Data – Client Data will only be used by State Street for the purposes specified in this Agreement.

  • Responsibility for Contract Administration The Servicer will have the sole obligation to manage, administer, service and make collections on the Contracts and perform or cause to be performed all contractual and customary undertakings of the holder of the Contracts to the Obligor. The Owner Trustee, at the written request of a Servicing Officer, shall furnish the Servicer with any powers of attorney or other documents necessary or appropriate in the opinion of the Owner Trustee to enable the Servicer to carry out its servicing and administrative duties hereunder. The Servicer is hereby appointed the servicer hereunder until such time as any Service Transfer may be effected under Article VIII.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Agreement Administration and Communications A. Under this Agreement, either of the representatives of the Judicial Council identified below will monitor the Work and act as the Judicial Council’s liaisons with the Contractor: i. The Meeting Planner will be MPname. B. The Judicial Council may reallocate funds between the estimated amounts set forth in Exhibit G, without an Amendment to this Agreement, as long as the total amount to be paid under this Agreement does not exceed the Contract Amount. C. All requests and communications about the Work to be performed under this Agreement, including signing of any BEO’s, shall be made through the Meeting Planner or his or her designee or successor. D. Any Notice from the Contractor to the Judicial Council shall be delivered to the following address: MP name, Meeting Planner Judicial Council of California 000 Xxxxxx Xxxx Xxxxxx Xxx Xxxxxxxxx, XX 00000-0000 E. Notice to the Contractor shall be directed to the Contractor’s liaison, Attn, or his or her designee or successor, at the following address: Attn: Ktr DifferentAddress1 DifferentAddress2

  • SUPERVISION AND CONSTRUCTION PROCEDURES 4.3.1 The Contractor shall supervise and direct the Work, using his / her best skill and attention. The Contractor shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under the Contract. All aspects of the Project shall be subject to the inspection and approval of the State. Contractor guarantees to repair, replace, re-execute or otherwise correct any defect in workmanship, materials, or the like that fails to conform to the requirements of this Contract or that appears during the progress of the Work or within one year of final acceptance by the State. 4.3.2 The Contractor shall be responsible to the State for the acts and omissions of his / her employees, Subcontractors and their agents and employees, and other persons performing any of the Work under a contract with the Contractor. 4.3.3 The Contractor shall not be relieved from his / her obligations to perform the Work in accordance with the Contract Documents either by the activities or duties of the Architect in his / her administration of the Contract, or by inspections, tests or approvals required or performed under Paragraph 7.7 by persons other than the Contractor. 4.3.4 The Contractor shall acquaint himself (herself / itself) with the limits of the property or right- of-way of the State and shall not trespass on other property. The Contractor shall adequately protect the project, adjacent property and the public, and shall be responsible for any damage or injury due to the Contractor’s act or neglect, and shall save the State harmless in respect thereto. 4.3.5 All work shall be done in such a manner as not to interfere with the State’s operating functions. Contractor and his employees shall familiarize themselves and comply with all rules and regulations applicable to the project. 4.3.6 The Contractor shall keep the premises free from liens arising out of or from the Project. Contractor shall obtain and submit waivers of liens with a request for a progress or final payment.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!