REMEDIES AND DAMAGES (A) If any Event of Default shall occur, or this Lease and the Term shall expire and come to an end as provided in Article 16 hereof: (1) Tenant shall quit and peacefully surrender the Premises to Landlord, and Landlord and its agents may, after the date upon which this Lease and the Term shall expire and come to an end, re-enter the Premises or any part thereof, without Notice, either by summary proceedings, or by any other applicable action or proceeding or otherwise, and may repossess the Premises and dispossess Tenant and any other persons from the Premises by summary proceedings or otherwise and remove any and all of their property and effects from the Premises (and Tenant shall remain liable for damages as provided herein or pursuant to law); and (2) Landlord, at Landlord's option, may relet the whole or any part or parts of the Premises from time to time, either in the name of Landlord or otherwise, to such tenant or tenants, for such term or terms ending before, on or after the Fixed Expiration Date, at such rent or rentals and upon such other conditions, which may include concessions and free rent periods, as Landlord may determine; provided, however, that Landlord shall exercise reasonable efforts to mitigate any damages related to liability of Tenant under this Lease. (B) In the event of a breach or threatened breach by Tenant, or any persons claiming through or under Tenant, of any term, covenant or condition of this Lease, Landlord shall have the right to enjoin such breach. (A) If this Lease and the Term shall expire and come to an end as provided in Article 2 hereof, or by or under any summary proceeding or any other action or proceeding, or if Landlord shall re-enter the Premises as provided in Section 17.1 hereof, or by or under any summary proceeding or any other action or proceeding, then, in any of said events: (1) Tenant shall pay to Landlord all Fixed Rent, Additional Rent and other items of Rental payable under this Lease by Tenant to Landlord to the date upon which this Lease and the Term shall have expired and come to an end or to the date of re-entry upon the Premises by Landlord, as the case may be; (2) if Landlord has not terminated the Lease, but only Tenant's right of possession to the Premises, Tenant also shall be liable for and shall pay to Landlord, as damages, any deficiency ("Deficiency") between the Rental for the period which is the unexpired portion of the Term and the net amount, if any, of rents collected under any reletting effected pursuant to the provisions of Section 17.1(A)(2) for any part of such period (after first deducting from the rents collected under any such reletting all of Landlord's reasonable and actual expenses in connection with the termination of Tenant's right of possession, Landlord's re-entry upon the Premises and such reletting including, but not limited to, all repossession costs, brokerage commissions, attorneys' fees and disbursements, alteration costs and other expenses of preparing the Premises for such reletting, to the extent the same are allocable to the remaining Term); any such Deficiency shall be paid in monthly installments by Tenant on the days specified in this Lease for payment of installments of Fixed Rent; Landlord shall be entitled to recover from Tenant each monthly Deficiency as the same shall arise, and no suit to collect the amount of the Deficiency for any month shall prejudice Landlord's right to collect the Deficiency for any subsequent month by a similar proceeding; and (3) alternatively, if Landlord has terminated the Lease, Landlord shall be entitled to recover from Tenant, and Tenant shall pay to Landlord, on demand, and as and for liquidated and agreed final damages, a sum equal to the amount by which the present value (calculated using the Base Rate as the discount rate) of the unpaid Rental for the period which otherwise would have constituted the unexpired portion of the Term exceeds the present value (calculated using the Base Rate as the discount rate) of the then fair and reasonable rental value of the Premises for the same period, taking into consideration reasonable costs incurred to relet the Premises; if, before presentation of proof of such liquidated damages to any court, commission or tribunal, the Premises, or any part thereof, are relet by Landlord on a fair and arms-length basis for the period which otherwise would have constituted the unexpired portion of the Term, or any part thereof, the amount of rent reserved upon such reletting shall be deemed, prima facie, to be the fair and reasonable rental value for the part or the whole of the Premises so relet during the term of the reletting. (B) Tenant shall in no event be entitled to any rents collected or payable under any reletting, whether or not such rents exceed the Fixed Rent reserved in this Lease. Nothing contained in this Article 17 shall be deemed to limit or preclude the recovery by Landlord from Tenant of the maximum amount allowed to be obtained as damages by any statute or rule of law, or of any sums or damages to which Landlord may be entitled in addition to the damages set forth in this Section 17.2.
Limitation of Remedies and Damages 8.1 Liability Cap. EXCEPT WITH RESPECT TO: (A) EITHER PARTY'S OBLIGATIONS UNDER SECTION 9 8.2 EXCEPT FOR CUSTOMER’S INFRINGEMENT OF SYSDIG’S INTELLECTUAL PROPERTY RIGHTS, IN NO EVENT SHALL EITHER PARTY, OR SYSDIG’S AFFILIATES OR ITS LICENSORS BE LIABLE FOR ANY CONSEQUENTIAL, INCIDENTAL, SPECIAL, INDIRECT, PUNITIVE OR EXEMPLARY DAMAGES, INCLUDING WITHOUT LIMITATION LOST PROFITS, LOSS OF USE, BUSINESS INTERRUPTIONS, LOSS OF DATA, REVENUE, GOODWILL, PRODUCTION, ANTICIPATED SAVINGS, COSTS OF PROCUREMENT OF SUBSTITUTE GOODS OR SERVICES, IN CONNECTION WITH OR ARISING OUT OF THE PERFORMANCE OF OR FAILURE TO PERFORM THIS AGREEMENT, WHETHER ALLEGED AS A BREACH OF CONTRACT OR TORTIOUS CONDUCT, INCLUDING NEGLIGENCE, EVEN OF A PARTY HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES. 8.3 Limitations Fair and Reasonable. EACH PARTY ACKNOWLEDGES THAT THE LIMITATIONS OF LIABILITY SET FORTH IN THIS SECTION 8 REFLECT THE ALLOCATION OF RISK BETWEEN THE PARTIES UNDER THIS AGREEMENT, AND THAT IN THE ABSENCE OF SUCH LIMITATIONS OF LIABILITY, THE ECONOMIC TERMS OF THIS AGREEMENT WOULD BE SIGNIFICANTLY DIFFERENT.
Breach of Contract and Liquidated Damages A. Where OGS determines that the Contractor is not in compliance with the requirements of subsection 4.7 of this Contract, and the Contractor refuses to comply with such requirements, or if it is found to have willfully and intentionally failed to comply with the MWBE participation goals set forth in the Contract, the Contractor shall be obligated to pay liquidated damages to OGS. B. Such liquidated damages shall be calculated as an amount equaling the difference between: 1. All sums identified for payment to MWBEs had the Contractor achieved the contractual MWBE goals; and 2. All sums actually paid to MWBEs for work performed or materials supplied under the Contract. C. If OGS determines that Contractor is liable for liquidated damages and such identified sums have not been withheld by OGS, Contractor shall pay such liquidated damages to OGS within sixty (60) days after they are assessed. Provided, however, that if the Contractor has filed a complaint with the Director of the Division of Minority and Women’s Business Development pursuant to 5 NYCRR § 142.12, liquidated damages shall be payable only in the event of a determination adverse to the Contractor following the complaint process.
Payment of Liquidated Damages If you supply all or some of your milk to a third party during a Month you must, if required by DFMC, immediately pay to DFMC liquidated damages for that Month calculated as follows: $X = W cents x (Y – Z) Where: $X is the amount payable by you to DFMC for the relevant Month. If $X is a negative amount, no amount is payable by you. Y is the average monthly litres you have supplied to DFMC based on the 12 months immediately preceding the relevant Month (or in the event you have not supplied DFMC for 12 months, the average monthly litres you have supplied to DFMC during the period you have supplied DFMC). Z is the number of litres supplied to DFMC by you for the relevant Month.
Withholding for unpaid wages and liquidated damages The FHWA or the contacting agency shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (2.) of this section.
Limitation of Remedies, Liability and Damages EXCEPT AS EXPRESSLY SET FORTH HEREIN, THERE IS NO WARRANTY OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE, AND ANY AND ALL IMPLIED WARRANTIES ARE DISCLAIMED. THE PARTIES CONFIRM THAT THE EXPRESS REMEDIES AND MEASURES OF DAMAGES PROVIDED IN THIS AGREEMENT SATISFY THE ESSENTIAL PURPOSES HEREOF. FOR BREACH OF ANY PROVISION FOR WHICH AN EXPRESS REMEDY OR MEASURE OF DAMAGES IS PROVIDED, SUCH EXPRESS REMEDY OR MEASURE OF DAMAGES SHALL BE THE SOLE AND EXCLUSIVE REMEDY, THE OBLIGOR’S LIABILITY SHALL BE LIMITED AS SET FORTH IN SUCH PROVISION AND ALL OTHER REMEDIES OR DAMAGES AT LAW OR IN EQUITY ARE WAIVED. IF NO REMEDY OR MEASURE OF DAMAGES IS EXPRESSLY PROVIDED HEREIN, THE OBLIGOR’S LIABILITY SHALL BE LIMITED TO DIRECT ACTUAL DAMAGES ONLY, SUCH DIRECT ACTUAL DAMAGES SHALL BE THE SOLE AND EXCLUSIVE REMEDY, AND ALL OTHER REMEDIES OR DAMAGES AT LAW OR IN EQUITY ARE WAIVED. UNLESS EXPRESSLY HEREIN PROVIDED, NEITHER PARTY SHALL BE LIABLE FOR CONSEQUENTIAL, INCIDENTAL, PUNITIVE, EXEMPLARY OR INDIRECT DAMAGES, LOST PROFITS OR OTHER BUSINESS INTERRUPTION DAMAGES, BY STATUTE, IN TORT OR CONTRACT, UNDER ANY INDEMNITY PROVISION OR OTHERWISE. TO THE EXTENT ANY DAMAGES REQUIRED TO BE PAID HEREUNDER ARE LIQUIDATED, THE PARTIES ACKNOWLEDGE THAT THE DAMAGES ARE DIFFICULT OR IMPOSSIBLE TO DETERMINE, OR OTHERWISE OBTAINING AN ADEQUATE REMEDY IS INCONVENIENT AND THE DAMAGES CALCULATED HEREUNDER CONSTITUTE A REASONABLE APPROXIMATION OF THE HARM OR LOSS.
Payment of Damages The indemnification required hereunder shall be made by periodic payments of the amount thereof during the course of the investigation or defense, within 10 days as and when reasonably specific bills are received or loss, liability, claim, damage or expense is incurred and reasonable evidence thereof is delivered. In calculating any amount to be paid by an indemnifying party by reason of the provisions of this Agreement, the amount shall be reduced by all reimbursements (including, without limitation, insurance proceeds) credited to or received by the other party related to the Damages.
Notice of Liquidated Damages System Agency will formally notify Grantee in writing when liquidated damages action is imposed, stating the nature of the action, the reasons for imposing, and the method of appealing. Grantee must submit a written appeal, within ten (10) calendar days of receipt of the notice, to the SUD email box, XxxxxxxxxXxxxx.Xxxxxxxxx@xxxx.xxxxx.xx.xx.
CONTRACT TIME AND LIQUIDATED DAMAGES (7-1-95) (Rev. 12-18-07) 108 SP1 G10 A The date of availability for this contract is April 25, 2016. The completion date for this contract is October 15, 2017. Except where otherwise provided by the contract, observation periods required by the contract will not be a part of the work to be completed by the completion date and/or intermediate contract times stated in the contract. The acceptable completion of the observation periods that extend beyond the final completion date shall be a part of the work covered by the performance and payment bonds. The liquidated damages for this contract are Two Thousand Dollars ($ 2,000.00) per calendar day.
Remedies are Cumulative Except as expressly provided in this Agreement, the rights and remedies contained in this Agreement are cumulative and not exclusive of any rights or remedies provided by law.