Review of Design Documentation Sample Clauses

Review of Design Documentation i. Review of the Contracts for the design and construction of the Construction Works and for Operation and Maintenance of the Project and make recommendations to FBR and the Concessionaire for amendments which, in its opinion, should be made to the Contracts with Design Firm to avoid conflicts between those contracts and the Concession Contract. ii. Audit the Preliminary Design and any amendments thereto for compliance with all the standards and specifications specified in the Agreement applicable to the Preliminary Design and make recommendations to the FBR for approval by the FBR of the Preliminary Design or provide the FBR and the Concessionaire with details of the non-compliance within 21 days of receipt of the Preliminary Design. iii. Audit the Detailed Design and any amendments thereto for compliance with all the applicable standards and specifications specified in the Agreement as applicable to the Detailed Design and notify the Concessionaire and the FBR as to whether the Detailed Design complies with the standards specified in the Agreement and, if not, provide details of the non-compliance and suggest improvements to the Detailed Design to the Concessionaire and the FBR within 21 days of receipt of such Detailed Design. iv. Determine any extension of time, amount of monetary compensation or relief from penalties to which the Concessionaire is entitled on suspension or variation of any Construction Works by the FBR pursuant to the Concession Contract. Conduct a general overview of the programme for completion of the Detailed Design insofar as it relates to the obligations of the FBR and inform the FBR of those obligations. v. Receive from the designers and Contractors (as relevant) certificates confirming that due care was exercised by them in carrying out the Preliminary Design or Detailed Design (as relevant).
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Review of Design Documentation. (a) It is acknowledged by the State, the Company and the Trustee that the Independent Reviewer, the Company and the Trustee may consult and confer with each other as to the proposed Design Documentation prior to the formal submission of the Design Documentation by the Company and the Trustee to the Independent Reviewer under clause 7.5. (b) The Independent Reviewer shall review the proposed Design Documentation (by general overview and reasonable checking) within: (i) 5 Business Days of receipt of the initial proposed Design Documentation; and (ii) 5 Business Days of receipt of other proposed Design Documentation, or a proposed change under clause 2.4(d) and (e), to form an opinion as to whether it complies with the Project Scope and Technical Requirements. (c) Within 2 Business Days after the end of the relevant period specified under paragraph (b), the Independent Reviewer may give notice to the Company and the Trustee and the State of the Independent Reviewer's opinion as to whether the proposed Design Documentation or proposed change complies with the Project Scope and Technical Requirements for reasons which the Independent Reviewer specifies. (d) If the Independent Reviewer forms the opinion that implementation of the proposed Design Documentation or the proposed change will be unsafe to members of the public or to workers involved in carrying out the Works, the Independent Reviewer shall specify those matters in a notice given under paragraph (c), together with the reasons for that opinion. (e) If the Company or the Trustee disagree with any opinion of the Independent Reviewer under paragraph (c) they may at their own risk proceed with construction in accordance with the design to which the opinion relates. Alternatively, if the Company and Trustee prepare further proposed Design Documentation, they shall resubmit it under clause 7.5(d).
Sample 1

Related to Review of Design Documentation

  • Release of Design Plan The Engineer (1) will not release any roadway design plan created or collected under this contract except to its subproviders as necessary to complete the contract; (2) shall include a provision in all subcontracts which acknowledges the State’s ownership of the design plan and prohibits its use for any use other than the project identified in this contract; and (3) is responsible for any improper use of the design plan by its employees, officers, or subproviders, including costs, damages, or other liability resulting from improper use. Neither the Engineer nor any subprovider may charge a fee for the portion of the design plan created by the State.

  • Schematic Design Documents In accordance with the approved Preliminary Design and Construction Schedule and based upon approval of and comments made by the Owner regarding the Concept Design Studies, the Design Professional shall prepare and submit to the Owner Schematic Design Documents, including drawings and outline specifications. These documents shall represent a further development of the approved design concept, providing additional detail and specificity regarding the intended design solution. Typically, all such documents shall be drawn to scale, indicating materials and assemblies, as appropriate, to convey the design intent and to illustrate the Project’s basic elements, scale and relationship to the Site. All major pieces of furniture and equipment to be fixed or supplied by the CM/GC shall be illustrated to scale. (See ASTM Standard Practice E 1804-02, August 2007, Sections 6.3, 8.2 and 8.3 for guidance on information which is generally developed in Schematic Design.)

  • Construction Document Phase 1.4.1 Based on the approved Design Development Documents, Guaranteed Maximum Price, coordinated models and any further adjustments in the scope or quality of the Project or in the Amount Available for the Construction Contract authorized by the Owner, the Architect/Engineer shall prepare, for approval by the Owner and review by the Construction Manager, Construction Documents consisting of Drawings, Schedules and Specifications derived from the model(s) in accordance with Owner’s written requirements setting forth in detail the requirements for construction of the Project, including, without limitation, the BIM Execution Plan and “Facility Design Guidelines”. The Plans, Drawings and Specifications for the entire Project shall be so prepared that same will call for the construction of the building and related facilities, together with its built-in permanent fixtures and equipment which will cost not more than the Guaranteed Maximum Price accepted by Owner, or the Amount Available for the Construction Contract established by Owner if no Guaranteed Maximum Price proposal has been accepted by Owner. The Architect/Engineer will be responsible for managing the design to stay within such Guaranteed Maximum Price proposal or Amount Available for the Construction Contract. The Architect/Engineer shall review the Construction Documents as they are being prepared at intervals appropriate to the progress of the Project with the Owner and Construction Manager at the Project site or other location specified by Owner in the State of Texas. The Architect/Engineer shall utilize the model(s) to support the review process during Construction Documents. The Architect/Engineer shall provide the Construction Manager with a compact disc containing documents and data files derived from the model to assist the Construction Manager in fulfilling its responsibilities to the Owner. 1.4.2 As a part of Construction Documents Phase, Architect/Engineer shall accomplish model coordination, aggregation and “clash detection” to remove conflicts in design between systems, structures and components. Architect/Engineer shall demonstrate and provide written assurance to Owner that all conflicts/collisions between models have been resolved. 1.4.3 The Architect/Engineer shall consult with the Owner and Construction Manager on matters such as construction phasing and scheduling, bid or proposal alternates, liquidated damages, the construction contract time period, and other construction issues appropriate for the Project. The Architect/Engineer shall assist the Owner and Construction Manager in the preparation of the necessary bidding information, bidding forms, RFP information, and RFP forms, and the Conditions of the Contract. 1.4.4 The Architect/Engineer shall assist the Owner in connection with the Owner’s responsibility and procedures for obtaining approval of all building and accessibility authorities having jurisdiction over the Project. 1.4.5 The Architect/Engineer shall provide coordination and inclusion of sequence of operations for all operable systems in the facility as defined by Owner during Design Development. 1.4.6 The Architect/Engineer shall review the Estimated Construction Cost prepared by the Construction Manager, and shall provide written comments. 1.4.7 The Architect/Engineer shall participate in a final review of the Construction Documents and model(s) with the Owner and Construction Manager at the Project location or other location specified by Owner in the State of Texas. Prior to the Owner’s approval of the Construction Documents, the Architect/Engineer shall incorporate such changes as are necessary to satisfy the Owner’s review comments. 1.4.8 Before proceeding into the Bidding and Proposal Phase, the Architect/Engineer shall obtain Owner’s written acceptance of the Construction Documents and approval of the Final Amount Available for the Construction Contract as approved by the Board of Regents.

  • Design Documents Prepare and submit the following documents to the DAS - Records Management Office with a copy of the transmittal letter submitted to the respective Project Manager: 1. City/State Approved Drawings (1) Original set 2. Bid Set Drawings (1) Set BOND PAPER (marked as “ORIGINAL”) (1) Set electronic file (DWG & PDF) 3. Project Manual (1) Set hard copy & Detail Manual (1) Set electronic file

  • Construction Documents Phase Bidding or Negotiation Phase:

  • Construction Documents The architectural and engineering documents setting forth the design for the Project prepared by the Design Professional. Construction Documents include, but are not limited to, the Specifications, the Drawings, the Supplementary Conditions, the General Conditions, and all Addenda.

  • MSAA Indicator Technical Specification Document This Agreement shall be interpreted with reference to the MSAA Indicator Technical Specifications document.

  • Certificate of Designation The Certificate of Designation shall have been duly filed with the Secretary of State of the State of Delaware.

  • Accuracy of Descriptions The statements made in the Registration Statement, the General Disclosure Package and the Prospectus (including in each case, the documents incorporated by reference therein) under the captions “Description of Capital Shares” and “Certain Provisions of New York Law and Our Certificate of Incorporation,” insofar as they purport to constitute a summary of the terms of the Company’s common shares, under the caption “Description of the Notes,” insofar as it purports to constitute a summary of the terms of the Securities, and under the captions “Prospectus Supplement Summary— Company Overview; -- Distribution Policy; - Restrictions Relating to Our Common Shares; - Emerging Growth Company Status and The Offering,” “Risk Factors,” “Dividends and Distribution Policy,” “Description of Common Shares,” “Certain Provisions of New York Law and our Certificate of Incorporation and Bylaws,” and “Certain U.S. Federal Income Tax Considerations” insofar as such statements constitute summaries of the terms of statutes, rules or regulations, legal matters or governmental proceedings or agreements, contracts and other documents, are accurate and fair summaries of the terms of such statutes, rules or regulations, legal matters or governmental proceedings or agreements, contracts and other documents in all material respects. All agreements between the Company or any of its Subsidiaries and any other party expressly referenced in the Registration Statement, the General Disclosure Package and the Prospectus are legal, valid and binding obligations of the Company or such Subsidiary, as applicable, enforceable against the Company or such Subsidiaries, as applicable, as appropriate, in accordance with their respective terms, except to the extent that enforceability may be limited by bankruptcy, insolvency, reorganization, fraudulent transfer, moratorium or similar laws affecting creditors’ rights generally and by general equitable principles and, with respect to equitable relief, the discretion of the court before which any proceeding therefor may be brought (regardless of whether enforcement is sought in a proceeding at law or in equity) and, with respect to any indemnification provisions contained therein, except as rights under those provisions may be limited by applicable law or policies underlying such law. The Company’s operating policies, investment guidelines and other policies described in the Registration Statement, General Disclosure Package and Prospectus accurately reflect in all material respects the current intentions of the Company with respect to the operation of its business, and no material deviation from such guidelines or policies is currently contemplated.

  • Effect of Designation (i) If notice designating an Early Termination Date is given under Section 6(a) or (b), the Early Termination Date will occur on the date so designated, whether or not the relevant Event of Default or Termination Event is then continuing. (ii) Upon the occurrence or effective designation of an Early Termination Date, no further payments or deliveries under Section 2(a)(i) or 2(e) in respect of the Terminated Transactions will be required to be made, but without prejudice to the other provisions of this Agreement. The amount, if any, payable in respect of an Early Termination Date shall be determined pursuant to Section 6(e).

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!