Review of Project Costs Sample Clauses

Review of Project Costs. Tenant shall have the right, at its sole cost and expense, to review Landlord’s records related to the calculation of New Building Project Costs within thirty (30) days after receipt of Landlord’s written notice computing New Building Project Costs and Basic Rent. If Tenant provides Landlord with written notice of what Tenant believes are errors in Landlord’s calculation of New Building Project Costs or the Basic Rent during such thirty (30) day period, the parties shall meet within fourteen (14) days of such objection (the “Reconciliation Period”) by Tenant to reasonably reconcile the calculation of New Building Project Costs and the Basic Rent to their mutual satisfaction. If the parties are unable to resolve the discrepancy in the calculation of New Building Project Costs or the Basic Rent within the Reconciliation Period, Tenant shall have the right to refer the matter to a mutually acceptable independent certified public accountant with at least five (5) years of experience performing commercial real estate audits (the “Arbiter”), who shall work in good faith with Landlord and Tenant to resolve the discrepancy in the calculation of the New Building Project Costs and/or the Basic Rent and who shall not be compensated on a contingency basis; provided if Tenant shall not notify Landlord of Tenant’s intent to engage the Arbiter (the “Arbiter Notice”) within five (5) business days following the end of the Reconciliation Period, Landlord’s calculation of New Building Project Costs and the Basic Rent, as adjusted by any agreements reached in writing between the parties during the Reconciliation Period, shall be deemed final and accepted by Tenant. Tenant shall deliver to the Arbiter Landlord’s notice of its calculation of the New Building Project Costs and the Basic Rent and the Commencement Date, together with the reasonable supporting documentation of the costs associated with such New Building Project Costs and the Basic Rent provided by Landlord, and the Arbiter shall deliver its calculation of New Building Project Costs and the Basic Rent to Landlord and Tenant within twenty-one (21) days of its selection. The fees and costs of any such Arbiter shall be borne by Tenant. The decision of the Arbiter with respect to the calculation of New Building Project Costs and the Basic Rent shall be final and binding in all respects. Notwithstanding the foregoing, Tenant shall pay Basic Rent on the basis of Landlord’s determination of the New Building Project Costs p...
Sample 1
AutoNDA by SimpleDocs

Related to Review of Project Costs

  • Project Costs The Project costs are true and accurate estimates of the costs necessary to complete the Improvements in a good and workmanlike manner according to the Plans and Specifications presented by Borrower to Lender, and Borrower shall take all steps necessary to prevent the actual cost of the Improvements from exceeding the Project costs.

  • Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shal] submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the genera] conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over- Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (1), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease. 4.2.2

  • Completion of Project The Project shall have been completed per the Plans and Specifications and a Completion Certificate shall have been obtained;

  • Construction Budget Administrative Agent shall have received each of the Construction Budget in form and substance reasonably satisfactory to Administrative Agent (in consultation with the Independent Engineer).

  • Periodic Review of Costs of Environmental Compliance In the ordinary course of its business, the Company conducts a periodic review of the effect of Environmental Laws on the business, operations and properties of the Company and its subsidiaries, in the course of which it identifies and evaluates associated costs and liabilities (including, without limitation, any capital or operating expenditures required for clean-up, closure of properties or compliance with Environmental Laws or any permit, license or approval, any related constraints on operating activities and any potential liabilities to third parties). On the basis of such review and the amount of its established reserves, the Company has reasonably concluded that such associated costs and liabilities would not, individually or in the aggregate, result in a Material Adverse Change.

  • Construction of Project Purchaser shall (i) perform the Final Assembly Work which is set forth in Exhibit P hereto, (ii) perform all civil works (including roads, grading, maintenance facilities, meteorological towers and other items); (iii) perform all electrical works (including collection lines, Electrical Infrastructure, Transmission Facilities, Interconnection Facilities and other items); (iv) provide and install a remote terminal unit and cabling to the Substation, meteorological towers, and communications lines for the SCADA System to the Substation; and (v) provide any other items required for the operation of the Project; and

  • Project Budget The budget approved by Member Consent for the acquisition, construction, development, marketing and financing of the Project. The initial Project Budget is attached hereto as Exhibit G.

  • Construction Costs Tenant shall pay for all construction costs, including, but not limited to permits, costs of materials and labor, sales tax, construction management fees and the like except to the extent of the Tenant Improvement Allowance which shall be paid by Landlord. The term “Tenant Improvement Allowance” shall mean the sum of $316,020.00 (or $15.00 per square foot of rentable area times 21,068 square feet of rentable area) which Landlord agrees to pay towards the construction costs. Landlord agrees to pay architectural fees and design services up to $1.25 per rentable square foot. Any services performed by the architect above the $1.25 per rentable square foot shall be the responsibility of the Tenant and may be paid out of the Tenant Improvement Allowance to the extent funds are available. Notwithstanding anything to the contrary, provided there is any unused portion of the Tenant Improvement Allowance, up to 20% of the allowance can be used by the Tenant as a moving allowance or for communications costs for cabling and data. Tenant must submit invoices for such allowances for Landlord to pay. Xxxxxx Development will act as General Contractor for the construction of tenant improvements, competitively bidding each trade to at least three subcontractors, the typical five percent (5%) construction management fee will not be charged to Tenant or deducted from the Tenant Improvement Allowance. Landlord shall obtain bids based on the Approved Pricing Plans and construct the Work as described in the Approved Pricing Plans. If after finalizing the Approved Working Drawings, it is determined that the construction costs will exceed the amount of the Tenant Improvement Allowance (an “Excess”), then Tenant shall pay to Landlord the amount of such Excess within ten (10) days of written request from Landlord. Notwithstanding anything to the contrary, if Tenant fails to pay any Excess timely, Landlord shall not be obligated to commence construction of the Work and such delay shall constitute a Tenant Delay for each day beyond the ten (10) day period until the Excess is paid to Landlord. If Tenant elects not to use Xxxxxx Development as the General Contractor, Tenant understands that Landlord, or its designated agent, shall serve as construction manager for all of Tenant’s refurbishment and renovations in the refurbishment and renovations in the Premises and the fee for such service is 5% of the total cost of all work performed in connection with such refurbishment and renovations. Tenant agrees to cooperate with Landlord in completing any such improvements on a timely basis and Tenant has approved the preliminary space plan and pricing documentation. Additional space on the 3rd floor which Tenant elects to lease pursuant [****] = CERTAIN CONFIDENTIAL INFORMATION CONTAINED IN THIS DOCUMENT, MARKED BY BRACKETS, HAS BEEN OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO RULE 406 OF THE SECURITIES ACT OF 1933, AS AMENDED. to a right hereunder shall be finished out by Landlord pursuant to mutually agreed upon plans and Tenant shall receive an allowance of $15.00 per square foot of rentable area provided, however, Tenant acknowledges that Landlord is improving the entire third (3rd) floor prior to commencement of the Lease and Tenant shall not be entitled to any additional tenant finish when Tenant leases the remainder of the third floor.

  • Development Costs With respect to activities prior to the Amendment Effective Date, each Party was to pay [*] of the total Direct Development Costs of a Product incurred in accordance with the Development Budget (as defined in the Original Agreement). Notwithstanding anything in this Article 6 of this Agreement or in any other provision of this Agreement to the contrary, with respect to activities on and after the Amendment Effective Date, subject to Sections 3.1.2, Alimera will be solely responsible for, and shall pay one hundred percent (100%) of, all development costs of a Product, including Direct Development Costs. Notwithstanding anything in this Article 6 of this Agreement or in any other provision of this Agreement to the contrary, (i) all payments owing by CDS hereunder with respect to development activities prior to the Amendment Effective Date are hereby deemed fully paid by CDS (or waived, to the extent such waiver may be required), including any Development Payments, Compounded Development Payments, Determined Disputed Costs and Compounded Disputed Costs (as all defined in the Original Agreement), further including any penalties and interest which might have accrued with respect thereto, and further including all CDS payments deferred pursuant to that February 11, 2008 letter agreement sent by CDS and executed by CDS and Alimera regarding deferral of payments under the Original Agreement as of such date; (ii) all payments owing by Alimera hereunder with respect to development activities prior to the Amendment Effective Date are hereby deemed fully paid by Alimera (or waived, to the extent such waiver may be required), including any Development Payments, Compounded Development Payments, Determined Disputed Costs and Compounded Disputed Costs (as all defined in the Original Agreement), and further including any penalties and interest which might have accrued with respect thereto; and (iii) subject to Sections 3.1.1 and 3.1.2, from and after the Amendment Effective Date, CDS will have no liability whatsoever hereunder for any past, present or future development costs, including Direct Development Costs (which includes those incurred before, on and after the Amendment Effective Date), and instead Alimera shall have sole liability therefor.

  • Tenant Repairs and Maintenance Tenant shall, at its expense, throughout the Term, (i) maintain and preserve, in first-class condition (subject to normal and customary wear and tear), the Premises and the fixtures and appurtenances therein (including, but not limited to, the Premises' plumbing and HV AC systems, all doors, overhead or otherwise, glass and levelers located in the Premises or otherwise available in the Property for Tenant's sole use; and excluding, however, those components of the Premises for which Landlord is expressly responsible under Section 13.2); and (ii) maintain, in full force and effect, a preventative maintenance and service contract with a reputable 'service provider for maintenance of the HV AC systems of the Premises. Tenant shall also be responsible for all cost and expenses incurred to perform any and all repairs and replacements (whether structural or non-structural; interior or exterior; and ordinary or extraordinary), in and to the Premises and the Property and the facilities and systems thereof, if and to the extent that the need for such repairs or replacements arises directly or indirectly from any or all of: (a) the performance or existence of any Alterations, (b) the installation, use or operation of Tenant's Property in the Premises, (c) the moving of Tenant's Property in or out of the Property, and (d) any act, omission, misuse, or neglect of Tenant, any of its subtenants, or others entering into the Premises by act or omission of Tenant or any subtenant. Any repairs or replacements required to be made by Tenant to any or all of the structural components of the property and the :mechanical, electrical, sanitary; HVAC, or other systems of the Property or Premises shall be performed by appropriately licensed contractors approved by Landlord, which approval shall not be unreasonably withheld. All such repairs or replacements shall be subject to the supervision and control of Landlord, and all repairs and replacements shall be made with materials of equal or better quality than the items being repaired or replaced.

Time is Money Join Law Insider Premium to draft better contracts faster.