No Modifications The Servicer shall not amend or otherwise modify any Receivable such that the Amount Financed, the Annual Percentage Rate, or the number of originally scheduled due dates is altered or such that the last scheduled due date occurs after the Final Scheduled Distribution Date.
City’s Right to Suspend for Convenience City may suspend all or any portion of Contractor’s performance under this Contract at its sole option and for its convenience for a reasonable period of time not to exceed six (6) months. City must first give ten (10) days’ written notice to Contractor of such suspension. City will pay to Contractor a sum equivalent to the reasonable value of the goods and/or services satisfactorily provided up to the date of suspension. City may rescind the suspension prior to or at six (6) months by providing Contractor with written notice of the rescission, at which time Contractor would be required to resume performance in compliance with the terms and provisions of this Contract. Contractor will be entitled to an extension of time to complete performance under the Contract equal to the length of the suspension unless otherwise agreed to in writing by the Parties.
City’s Right to Reject The City reserves the right to reject a certificate of insurance if Contractor’s insurance company is widely regarded in the insurance industry as financially unstable. This would include but is not limited to insurance companies with no less than AVIII rating in the A.M. Best insurance rating guide.
Waiver of Right to Trial by Jury EACH PARTY TO THIS AGREEMENT HEREBY EXPRESSLY WAIVES ANY RIGHT TO TRIAL BY JURY OF ANY CLAIM, DEMAND, ACTION OR CAUSE OF ACTION ARISING UNDER ANY LOAN DOCUMENT OR IN ANY WAY CONNECTED WITH OR RELATED OR INCIDENTAL TO THE DEALINGS OF THE PARTIES HERETO OR ANY OF THEM WITH RESPECT TO ANY LOAN DOCUMENT, OR THE TRANSACTIONS RELATED THERETO, IN EACH CASE WHETHER NOW EXISTING OR HEREAFTER ARISING, AND WHETHER FOUNDED IN CONTRACT OR TORT OR OTHERWISE; AND EACH PARTY HEREBY AGREES AND CONSENTS THAT ANY SUCH CLAIM, DEMAND, ACTION OR CAUSE OF ACTION SHALL BE DECIDED BY COURT TRIAL WITHOUT A JURY, AND THAT ANY PARTY TO THIS AGREEMENT MAY FILE AN ORIGINAL COUNTERPART OR A COPY OF THIS SECTION WITH ANY COURT AS WRITTEN EVIDENCE OF THE CONSENT OF THE SIGNATORIES HERETO TO THE WAIVER OF THEIR RIGHT TO TRIAL BY JURY.
Right to suspend 2.1.1 Network Rail may serve a Suspension Notice where a Train Operator Event of Default has occurred and is continuing.
Waiver of Right to Appeal Provided the Judgment is consistent with the terms and conditions of this Agreement, specifically including the Class Counsel Fees Payment and Class Counsel Litigation Expenses Payment reflected set forth in this Settlement, the Parties, their respective counsel, and all Participating Class Members who did not object to the Settlement as provided in this Agreement, waive all rights to appeal from the Judgment, including all rights to post-judgment and appellate proceedings, the right to file motions to vacate judgment, motions for new trial, extraordinary writs, and appeals. The waiver of appeal does not include any waiver of the right to oppose such motions, writs or appeals. If an objector appeals the Judgment, the Parties’ obligations to perform under this Agreement will be suspended until such time as the appeal is finally resolved and the Judgment becomes final, except as to matters that do not affect the amount of the Net Settlement Amount.