Seller Performance Security Sample Clauses

Seller Performance Security. ‌‌ (a) As a condition to the occurrence of the Effective Date, Seller shall have furnished to Buyer one or more letters of credit issued by Qualified Issuers in the form attached hereto as Appendix E, as such form may be modified with the consent of Buyer (not to be unreasonably withheld or delayed) to reflect the reasonable requests of the Qualified Issuer, in the aggregate amount of $2,500,000, which shall secure all of Seller’s obligations to pay liquidated damages under Sections 3.7(a) and 3.7(b) (“Project Development Security”). From and after the Effective Date, Seller shall maintain such Project Development Security until Seller posts the Delivery Term Security pursuant to Section 5.9(b) below, or until Buyer is required to return the Project Development Security under Section 5.9(c) below.‌ (b) As a condition to the achievement of Commercial Operation, Seller shall have furnished to Buyer one or more letters of credit issued by Qualified Issuers, or guarantees from a Qualified Guarantor, or a combination of both, in the form attached hereto as Appendix G, as such form may be modified with the consent of Buyer (not to be unreasonably withheld or delayed) to reflect the reasonable requests of the Qualified Guarantor, as applicable, and in the aggregate amount of $8,000,000, which shall guarantee Seller’s obligations under this Agreement, following the Commercial Operation Date (“Delivery Term Security”); provided that Seller may elect to apply the Project Development Security toward the Delivery Term Security. From and after the Commercial Operation Date, Seller shall maintain such Delivery Term Security until the end of the Agreement Term or until Buyer is required to return the Delivery Term Security to Seller as set forth in Section 5.9(d) below, provided that Seller may, from time to time, replace a letter of credit with a guarantee and vice versa so long as such replacement letter of credit or guarantee shall comply with the applicable provisions of this Agreement and the aggregate amount required above is maintained.‌ (c) If after the Commercial Operation Date no damages or other amounts are due and owing to Buyer under this Agreement, or if this Agreement terminates prior to the occurrence of the Commercial Operation Date while the Project Development Security is outstanding, then Seller shall no longer be required to maintain the Project Development Security, and Buyer shall return to Seller the Project Development Security, less any amounts ...
AutoNDA by SimpleDocs
Seller Performance Security. If at any xxxx Xxxxxx (or Seller’s Guarantor) has Insufficient Credit Status, Seller shall deliver to Buyer within two (2) Business Days following the commencement of such Insufficient Credit Status either (a) a Letter of Credit; (b) a guaranty from a Seller’s Guarantor (substantially in the form attached hereto as Exhibit E) (so long as such Insufficient Credit Status is not with respect to such Seller’s Guarantor) or (c) other collateral in form and substance reasonably acceptable to Buyer, in each case in an amount equal to [**], which amount shall escalate at [**] per annum on January 1, 2024 and on January 1st of each year thereafter until the end of the Term; provided, that if Seller has Insufficient Credit Status as of the date of execution of this Agreement, then Seller shall be obligated to provide Seller Performance Security as of the date of execution of this Agreement. Costs of a Letter of Credit posted hereunder shall be borne by the applicant for such Letter of Credit.
Seller Performance Security. If at any xxxx Xxxxxx (or Seller's Guarantor) has Insufficient Credit Status, Seller shall deliver to Buyer within two (2) Business Days following the commencement of such Insufficient Credit Status either (a) a Letter of Credit; (b) a guaranty from a Seller's Guarantor (substantially in the form attached hereto as Exhibit E) (so long as such Insufficient Credit Status is not with respect to such Seller's Guarantor) or (c) other collateral in form and substance reasonably acceptable to Buyer, in each case in an amount equal to $100,000,000, which amount shall escalate at 3% per annum on January 1, 2024 and on January 1st of each year thereafter until the end of the Term; provided, that if Seller has Insufficient Credit Status as of the date of execution of this Agreement, then Seller shall be obligated to provide Seller Performance Security as of the date of execution of this Agreement. Costs of a Letter of Credit posted hereunder shall be borne by the applicant for such Letter of Credit.
Seller Performance Security. Seller will provide on the Effective Date (as defined below) replacement Eligible Collateral for the Seller Performance Security in accordance with the terms of the PPA. Upon receipt of such replacement Eligible Collateral, GPC will release the existing Eligible Collateral for the Seller Performance Security.
Seller Performance Security. (a) Within thirty (30) days following the date that the Project Participant Approval has been received, Seller shall have furnished to Buyer a letter of credit issued by a Qualified Issuer substantially in the form of Appendix E, as such form may be modified with the consent of Buyer (not to be unreasonably withheld, conditioned or delayed), in an amount equal to which shall secure all of Seller’s obligations to pay liquidated damages under
Seller Performance Security. Upon execution of this Agreement, Seller shall deliver to Buyer Eligible Collateral in an amount [***] (the “Seller Performance Security”). The Seller Performance Security shall be reduced to (a) [***] as of the first Day of the [***] Annual Period, (b) [***] as of the first Day of the [***] Annual Period, and (c) [***] as of the first Day of the [***] Annual Period. The parties agree that the initial Seller Performance Security shall be in the form of a Seller Guaranty from Duke Capital Corporation. In the event that a Material Adverse Change occurs in respect of Seller, upon two (2) Business Days prior written notice from Buyer, Seller shall deliver to Buyer replacement Seller Performance Security in the form of Eligible Collateral. Seller shall endeavor to give Buyer prompt written notice of any Material Adverse Change in respect of Seller but the failure to do so shall not be a Default or Event of Default hereunder.

Related to Seller Performance Security

  • Performance Security 47.1 Within twenty-one (21) days of the receipt of Letter of Acceptance from the Procuring Entity, the successful Tenderer, if required, shall furnish the Performance Security in accordance with the GCC 18, using for that purpose the Performance Security Form included in Section X, Contract Forms. If the Performance Security furnished by the successful Tenderer is in the form of a bond, it shall be issued by a bonding or insurance company that has been determined by the successful Tenderer to be acceptable to the Procuring Entity. A foreign institution providing a bond shall have a correspondent financial institution located in Kenya, unless the Procuring Entity has agreed in writing that a correspondent financial institution is not required. 47.2 Failure of the successful Tenderer to submit the above-mentioned Performance Security or sign the Contract shall constitute sufficient grounds for the annulment of the award and forfeiture of the Tender Security. In that event the Procuring Entity may award the Contract to the Tenderer offering the next lowest Evaluated Tender. 47.3 Performance security shall not be required for a contract, if so specified in the TDS.

  • Release of Performance Security (i) The Authority shall return the Performance Security to the Contractor within 60 (sixty) days of the expiry of the Maintenance Period or the Defects Liability Period, whichever is later, under this Agreement. Notwithstanding the aforesaid, the Parties agree that the Authority shall not be obliged to release the Performance Security until all Defects identified during the Defects Liability Period have been rectified. (ii) The Authority shall return the Additional Performance Security to the Contractor within 28 (twenty eight) days from the date of issue of Completion Certificate under Article 12 of this Agreement. (iii) The Authority shall be liable to pay interest @ 9% (nine per cent) per annum for any delay in the return of Performance Security and Additional Performance Security, if any, beyond the period prescribed above for the period of delay.

  • Appropriation of Performance Security (i) Upon occurrence of a Contractor’s Default, the Authority shall, without prejudice to its other rights and remedies hereunder or in law, be entitled to encash and appropriate the relevant amounts from the Performance Security as Damages for such Contractor’s Default. (ii) Upon such encashment and appropriation from the Performance Security, the Contractor shall, within 30 (thirty) days thereof, replenish, in case of partial appropriation, to its original level the Performance Security, and in case of appropriation of the entire Performance Security provide a fresh Performance Security, as the case may be, and the Contractor shall, within the time so granted, replenish or furnish fresh Performance Security as aforesaid failing which the Authority shall be entitled to terminate the Agreement in accordance with Article 23. Upon replenishment or furnishing of a fresh Performance Security, as the case may be, as aforesaid, the Contractor shall be entitled to an additional Cure Period of 30 (thirty) days for remedying the Contractor’s Default, and in the event of the Contractor not curing its default within such Cure Period, the Authority shall be entitled to encash and appropriate such Performance Security as Damages, and to terminate this Agreement in accordance with Article 23.

  • CONTRACTOR PERFORMANCE AUDIT The Contractor shall allow the Authorized User to assess Contractor’s performance by providing any materials requested in the Authorized User Agreement (e.g., page load times, response times, uptime, and fail over time). The Authorized User may perform this Contractor performance audit with a third party at its discretion, at the Authorized User’s expense. The Contractor shall perform an independent audit of its Data Centers, at least annually, at Contractor expense. The Contractor will provide a data owner facing audit report upon request by the Authorized User. The Contractor shall identify any confidential, trade secret, or proprietary information in accordance with Appendix B, Section 9(a), Confidential/Trade Secret Materials.

  • Portfolio Expense and Performance Data The Trust shall provide such data regarding each Portfolio’s expense ratios and investment performance as the Company shall reasonably request, to facilitate the registration and sale of the Variable Contracts. Without limiting the generality of the forgoing, the Trust shall provide the following Portfolio expense and performance data on a timely basis to facilitate the Company’s preparation of its annually updated registration statement for the Variable Contracts (and as otherwise reasonably requested by the Company), but in no event later than 10 calendar days after the close of each Portfolio’s fiscal year: (a) The gross “Annual Portfolio Company Expenses” for each Portfolio calculated in accordance with Item 3 of Form N-1A, before any expense reimbursements or fee waiver arrangements (and in accordance with (i) Instruction 16 to Item 4 of Form N-4, and (ii) Instruction 4(a) to Item 4 of Form N-6); (b) The net “Annual Portfolio Company Expenses” (aka “Total Annual Fund Operating Expenses”) for each Portfolio calculated in accordance with Item 3 of Form N-1A, that include any expense reimbursements or fee waiver arrangements (and in accordance with (i) Instruction 17 to Item 4 of Form N-4, (ii) Instruction 4 to Item 17 of Form N-4, (iii) Instruction 4(b) to Item 4 of Form N-6, and (iv) Instruction 4 to Item 18 of Form N-6), and the period for which the expense reimbursements or fee waiver arrangement is expected to continue and whether it can be terminated by the Portfolio (or Fund); and (c) The “Average Annual Total Returns” for each Portfolio (before taxes) as calculated pursuant to Item 4(b)(2)(iii) of Form N-1A (for the 1, 5, and 10 year periods, and in accordance with (i) Instruction 7 to Item 17 of Form N-4, and (ii) Instruction 7 to Item 18 of Form N-6).

  • Excuse for Nonperformance or Delayed Performance Except with respect to defaults of subcontractors, Contractor/Vendor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor/Vendor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor/Vendor has notified the Commission or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Contractor/Vendor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Contractor to meet the contract requirements. Upon request of Contractor, the Commission or designee shall ascertain the facts and extent of such failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, Contractor’s progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause entitled (in fixed-price contracts, “Termination for Convenience,” in cost-reimbursement contracts, “Termination”). (As used in this Paragraph of this clause, the term “subcontractor” means subcontractor at any tier).

  • Continuity of Service and Performance Unless otherwise agreed in writing, the Parties shall continue to provide service and honor all other commitments under this Agreement during the course of a Dispute with respect to all matters not subject to such Dispute.

  • Quarterly Contractor Performance Reporting Customers shall complete a Contractor Performance Survey (Exhibit I) for each Contractor on a Quarterly basis. Customers will electronically submit the completed Contractor Performance Survey(s) to the Department Contract Manager no later than the due date indicated in Contract Exhibit D, Section 17, Additional Special Contract Conditions. The completed Contractor Performance Survey(s) will be used by the Department as a performance-reporting tool to measure the performance of Contractors. The Department reserves the right to modify the Contractor Performance Survey document and introduce additional performance-reporting tools as they are developed, including online tools (e.g. tools within MyFloridaMarketPlace or on the Department's website).

  • Software Performance HP warrants that its branded software products will conform materially to their specifications and be free of malware at the time of delivery. HP warranties for software products will begin on the date of delivery and unless otherwise specified in Supporting Material, will last for ninety (90) days. HP does not warrant that the operation of software products will be uninterrupted or error-free or that software products will operate in hardware and software combinations other than as authorized by HP in Supporting Material.

  • Performance Obligations The Purchaser shall have performed in all respects all obligations required to be performed by it under this Agreement at or prior to the Closing.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!