Specific District Rights. In addition to the following and other rights of the District enumerated in this PLA, the District expressly reserves its management rights and all the rights conferred on it by law and contract. The District's rights (and those of the Project Labor Coordinator on its behalf) include but are not limited to the right to:
(a) Inspect any construction site or facility to ensure that the Contractor follows the applicable safety and other work requirements; and
(b) Require Contractors to establish a different work week or shift schedule for particular employees as required to meet the operational needs of the Project Work at a particular location or in order to accommodate the instructional programs at various Project sites where school may be in session during periods of construction activity; and
(c) At its sole option, terminate, delay and/or suspend any and all portions of the Covered Work at any time; prohibit some or all work on certain days or during certain hours of the day to accommodate the ongoing operations of the District's educational facilities and/or to mitigate the effect of ongoing Project Work on businesses and residents in the neighborhood of the Project site; and/or require such other operational or schedule changes it deems necessary, in its sole judgment, to effectively maintain its primary mission and remain a good neighbor to those in the area of its facilities. (In order to permit the Contractors and Unions to make appropriate scheduling plans, the District will provide the Project Labor Coordinator, and the affected Contractor(s) and Union(s) with reasonable notice of any changes it requires pursuant to this section); and
(d) Approve any work methods, procedures and techniques used by Contractors whether or not these methods, procedures or techniques are part of industry practices or customs; and
(e) Investigate and process complaints, through its Project Labor Coordinator, in the matter set forth in Articles 10 and 12.
Specific District Rights. In addition to the following and other rights of the District enumerated in this Agreement, the District expressly reserves its management rights and all the rights conferred on it by law. The District’s rights (and those of the PLA Administrator on its behalf) include, but are not limited to, the right to:
(a) Inspect any construction site or facility to ensure that the Contractor follows the applicable safety and other work requirements;
(b) Require Contractors to establish a different work week or shift schedule for particular employees as required to meet the operational needs of the Project Work at a particular location;
(c) At its sole option, terminate, delay and/or suspend any and all portions of the covered work at any time; prohibit some or all work on certain days or during certain hours of the day to accommodate the ongoing operations of the District’s facilities and/or to mitigate the effect of ongoing Project Work on businesses and residents in the neighborhood of the Project site; and/or require such other operational or schedule changes it deems necessary, in its sole judgment, to effectively maintain its primary mission and remain a good neighbor to those in the area of its facilities. (In order to permit the Contractors and Unions to make appropriate scheduling plans, the District will provide the PLA Administrator, and the affected Contractor(s) and Union(s) with reasonable notice of any changes it requires pursuant to this section.);
(d) Approve any work methods, procedures and techniques used by Contractors whether or not these methods, procedures or techniques are part of industry practices or customs; and
(e) Investigate and process complaints in the manner set forth in Articles 7 and 10.
Specific District Rights. In addition to the following and other rights of the District enumerated in this Agreement, the District expressly reserves its management rights and all the rights conferred on it by law. The District’s rights (and those of the Contractor Administrator on its behalf) include but are not limited to the right to:
15.2.1 Inspect any construction site or facility to ensure that the Contractor follows the applicable safety and other work requirements;
Specific District Rights. In addition to the following and other rights of the District enumerated in this Agreement and in the District’s contract documents, the District expressly reserves its management rights and all the rights conferred on it by law or contract. The District’s rights include, but are not limited to, the right to:
(a) Inspect any construction site or facility to ensure that the Contractor follows the applicable safety and other work requirements;
(b) Require Contractors to establish a different work week or shift schedule for particular employees as required to meet the operational needs of the Project Work at a particular location, or in order to accommodate any difficulties with Project Work when schedules may interfere with District or resident requirements during construction activity;
(c) At its sole option, terminate, delay, or suspend any and all portions of Project Work at any time; prohibit some or all work on certain days or during certain hours of the day to accommodate the ongoing operations of the District’s facilities or to mitigate the effect of ongoing Project Work on businesses and residents in the neighborhood of the Project; and require such other operational or schedule changes it deems necessary, in its sole judgment, to effectively maintain its primary mission and remain a good neighbor to those in the area of its facilities. In order to permit the Contractors and Unions to make appropriate scheduling plans, the District will provide the affected Contractors and Unions with reasonable notice of any changes it requires pursuant to this Section, provided, however, that if notice is not provided in time to advise employees not to report for work, show-up pay shall be due pursuant to the provision of Section 6.6;
(d) Approve any work methods, procedures, and techniques used by Contractors whether or not these methods, procedures, or techniques are part of industry practices or customs; and
(e) Investigate and process complaints in the matter set forth in Articles 7 and 10.
Specific District Rights. This Agreement does not, in any way, restrict or otherwise infringe on the District’s absolute right to administer the work of the Project, its construction program and its general bond funds in any way it determines. The District expressly reserves its management rights and all the rights conferred on it by law and its contract with the Contractor.
