Outside Work All work necessary to the assembling, installation, erection, operation, maintenance, repair, control, in- spection and supervision of all electrical apparatus, devices, wires, cables, supports, insulators, conduc- tors, ducts and raceways when part of distributing systems outside of buildings, railroads and outside the directly related railroad property and yards. In- stalling and maintaining the catenary and trolley work on railroad property, and bonding of rails. All underground ducts and cables when they are in- stalled by and are part of the system of a distrib- uting company, except in power stations during new construction, including ducts and cables to adjacent switch racks or substations. All outdoor substations and electrical connections up to and including the setting of transformers and the connecting of the secondary buses thereto. Outside work to include renewable electrical energy sources such as solar photovoltaic, geothermal, wind, biomass, wave, etc., and other distributed en- ergy installations such as fuel cells, microturbines, etc.
Removal of Improvements All items of Landlord’s construction, all heating, ventilating and air conditioning equipment and all permanent improvements installed by Landlord shall be the property of Landlord and shall not be removed from the Leased Premises without the prior written consent of Landlord. All trade fixtures, furniture, furnishings and signs installed in the Leased Premises by Xxxxxx and paid for by Tenant shall remain the property of Tenant, and may be removed upon the expiration of the Term of this Lease, provided that: i. Tenant shall have fully performed all of the covenants, conditions and provisions to be performed by Tenant under this Lease; and ii. Tenant repairs any damage to the Leased Premises or the Building caused by such removal and restores the Leased Premises to the condition that existed on the commencement date of this Lease, reasonable wear and tear excepted. If Tenant fails to remove any such items from the Leased Premises within thirty (30) days after the expiration or earlier termination of this Lease, all such trade fixtures, furniture, furnishings and signs shall, at Landlord’s options, become the property of Landlord, unless Landlord elects to require their removal, in which case Tenant shall promptly remove the same and restore the Leased Premises to its prior condition. If Tenant fails to promptly remove the same, Landlord may remove and store such items at the expense of Tenant.
Project Work PURCHASER shall complete the following projects in accordance with the specifications provided in Exhibits B, C, D, E, and F and written instructions from STATE. Project locations are shown on Exhibit A unless otherwise described. PURCHASER shall furnish all material unless otherwise specified.
Tenant Improvements Tenants construction of the Tenant Improvements in the Suite 120 Premises shall be subject to the terms of the Work Letter attached to the Lease as Exhibit C, except that, notwithstanding anything to the contrary contained in the Work Letter: a. The Tenant Improvements in the Suite 120 Premises shall be constructed pursuant to the space plans attached to this First Amendment as Exhibit B (the “Suite 120 Space Plans”) and the tenant improvement specifications attached to this First Amendment as Exhibit C (the “Suite 120 TI Specifications”), which have been approved by both Landlord and Tenant, and the TI Construction Drawings for the Tenant Improvements for the Suite 120 Premises shall be prepared substantially in accordance with the Suite 120 Space Plans and the Suite 120 TI Specifications (and Landlord may not disapprove any matter in connection therewith that is consistent with the Suite 120 Space Plans and the Suite 120 TI Specifications). b. The Tenant Improvement Allowance and the Additional Tenant Improvement Allowance provided for in Section 6(b) of the Work Letter shall not apply with respect to the Suite 120 Premises and Landlord shall provide a tenant improvement allowance with respect to the Tenant Improvements in the Suite 120 Premises, as follows: (i) a “Suite 120 Tenant Improvement Allowance” in the maximum amount of $185.00 per rentable square foot in the Suite 120 Premises, which is included in the Base Rent set forth in the Lease; and (ii) an “Additional Suite 120 Tenant Improvement Allowance” in the maximum amount of $40.00 per rentable square foot in the Suite 120 Premises, which shall, to the extent used, result in Suite 120 TI Rent as set forth in Section 5(c) below. For the avoidance of doubt, (A) the definition of “TI Allowance” in the Work Letter shall include the Tenant Improvement Allowance, the Additional Tenant Improvement Allowance, the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance, as applicable, and (B) in connection with the Tenant Improvements in the Suite 120 Premises, Landlord shall be entitled to Administrative Rent equal to 1.5% of the “hard” TI Costs incurred in connection with such Tenant Improvements and a fee shall be payable to Tenant’s third party project manager, Xxxxxxxxx XxxXxxx of Xxxxx Xxxx LaSalle, not to exceed 1.5% of the “hard” TI Costs of such Tenant Improvements, which amounts shall be payable out of the TI Fund. Landlord and Tenant acknowledge and agree that the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance, to the extent utilized, must be used toward the cost of Tenant Improvements in the Suite 120 Premises. c. Pursuant to the terms of the Work Letter (as amended by this First Amendment), Landlord shall, subject to the terms of the Work Letter (as amended by this First Amendment), make available to Tenant the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance. Commencing on the Rent Commencement Date and continuing thereafter on the first day of each month during the Base Term, Tenant shall pay the amount necessary to fully amortize the portion of the Additional Suite 120 Tenant Improvement Allowance actually funded by Landlord, if any, in equal monthly payments with interest at a rate of 7% per annum over the Base Term, which interest shall begin to accrue on the date that Landlord first disburses such Additional Suite 120 Tenant Improvement Allowance or any portion(s) thereof (“Suite 120 TI Rent”). Any outstanding and unamortized Suite 120 TI Rent remaining unpaid as of the expiration or earlier termination of the Lease shall be paid to Landlord in a lump sum at the expiration or earlier termination of this Lease. For the avoidance of doubt, Landlord and Tenant acknowledge and agree that Suite 120 TI Rent, if any, shall not be subject to adjustment pursuant to Section 4(a) of the Lease during the Term.
Tenant’s Work Landlord and Tenant acknowledge and agree that certain work required for Tenant's occupancy of the Leased Premises, including but not limited to the procurement and installation of furniture, fixtures, equipment, artwork and interior signage are beyond the scope of the Tenant Improvements and shall be performed by Tenant or its contractors at Tenant's sole cost and expense. All such work ("Tenant's Work") shall be subject to Landlord's prior written approval. Tenant shall adopt a construction schedule for Tenant's Work in conformance with the Contractor's schedule, and shall perform Tenant's Work in such a way as not to hinder or delay the operations of Landlord or the Contractor in the Building. Any costs incurred by Landlord as a result of any interference with Landlord's operations by Tenant or its contractors shall be promptly paid by Tenant to Landlord upon demand. Landlord shall make all reasonable efforts to notify Tenant of any such interference of which Landlord has actual knowledge, but failure to provide such notice shall in no way limit Landlord's right to demand payment for such costs. Tenant's contractors shall be subject to Landlord's prior written approval, and to the administrative supervision of the Contractor. Tenant's Work shall comply with all of the following requirements: (a) Tenant's Work shall not proceed until Landlord has approved in writing: (i) Tenant's contractors, (ii) proof of the amount and coverage of public liability and property damage insurance carried by Tenant's contractors in the form of an endorsed insurance certificate naming Landlord, the Contractor, and the agents of Landlord and the Contractor as additional insureds, in an amount not less than two million dollars, and (iii) complete and detailed plans and specifications for Tenant's Work. (b) Tenant's Work shall be performed in conformity with a valid permit when required, a copy of which shall be furnished to Landlord before such work is commenced. In any event, all Tenant's Work shall comply with all applicable laws, codes and ordinances of any governmental entity having jurisdiction over the Building. Landlord shall have no responsibility for Tenant's failure to comply with such applicable laws. Any and all delay in obtaining a certificate of occupancy due to Tenant's vendors is the responsibility of Tenant and shall be a Tenant Delay. (c) In connection with Tenant's Work (e.g., delivering or installing furniture or equipment to the second floor of the Leased Premises), Tenant or its contractors shall arrange for any necessary hoisting or elevator service with Landlord and shall pay such reasonable costs for such services as may be charged by Landlord. (d) Tenant shall promptly pay Landlord upon demand for any extra expense incurred by Landlord by reason of faulty work done by Tenant or its contractors, by reason of damage to existing work caused by Tenant or its contractors, or by reason of inadequate cleanup by Tenant or its contractors.
Additional Work If changes in the work seem merited by Consultant or the City, and informal consultations with the other party indicate that a change is warranted, it shall be processed in the following manner: a letter outlining the changes shall be forwarded to the City by Consultant with a statement of estimated changes in fee or time schedule. An amendment to this Agreement shall be prepared by the City and executed by both Parties before performance of such services, or the City will not be required to pay for the changes in the scope of work. Such amendment shall not render ineffective or invalidate unaffected portions of this Agreement.
Creative Work The Executive agrees that all creative work and work product, including but not limited to all technology, business management tools, processes, software, patents, trademarks, and copyrights developed by the Executive during the term of this Agreement, regardless of when or where such work or work product was produced, constitutes work made for hire, all rights of which are owned by the Employer. The Executive hereby assigns to the Employer all rights, title, and interest, whether by way of copyrights, trade secret, trademark, patent, or otherwise, in all such work or work product, regardless of whether the same is subject to protection by patent, trademark, or copyright laws.
THE WORK The Work comprises the completed construction required by the Contract Documents and includes all labor necessary to produce such construction, and all materials and equipment incorporated or to be incorporated in such construction.
Extra Work At any time during the Term of this Agreement, City may request that Consultant perform Extra Work. As used herein, “Extra Work” means any work which is determined by City to be necessary for the proper completion of the Project, but which the Parties did not reasonably anticipate would be necessary at the execution of this Agreement. Consultant shall not perform, nor be compensated for, Extra Work without written authorization from City’s Representative.
Initial Improvements (a) On the Commencement Date, Tenant shall accept the Premises in its “as is” condition. All improvements, alterations and betterments (an “Alteration”) shall be performed by Tenant at Tenant’s expense in accordance with the terms of this Article 5. (b) Tenant may improve the Premises for Tenant’s initial occupancy in accordance with detailed specifications and working drawings to be prepared by Tenant’s engineers and architects. The detailed specifications and working drawings are hereinafter referred to as “Tenant’s Plans”, and the work shown by the Tenant’s Plans is hereinafter referred to as “Tenant’s Initial Improvements”. Tenant’s Initial Improvements shall include, and Landlord shall have no liability to tenant for not performing, the work specified on Exhibit H. (c) Tenant shall proceed forthwith to cause Tenant’s Plans to be prepared by an architect licensed as such in the State of New York. Tenant’s Plans, including structural and mechanical drawings and specifications, shall be prepared at Tenant’s sole cost and expense. Tenant shall submit five (5) sets of Tenant’s Plans and two (2) CAD discs which shall contain such Tenant’s Plans in CAD format to Landlord for Landlord’s approval. Landlord agrees to review Tenant’s Plans and to approve the same or make written exceptions thereto within fifteen (15) Business Days from the date of the submission of the plans. Landlord agrees not to unreasonably withhold or delay its approval of Tenant’s Plans, and failure by Landlord to provide the written exceptions within the fifteen (15) Business Day period aforesaid shall be deemed approval of Tenant’s Plans; provided, however, that five (5) Business Days prior to the expiration of such fifteen (15) Business Day period, Tenant shall send a second notice to Landlord with the phrase “FAILURE TO APPROVE OR DISAPPROVE TENANT’S PLANS WITHIN FIVE (5) BUSINESS DAYS AFTER THE DATE HEREOF SHALL RESULT IN THE DEEMED APPROVAL OF TENANT’S PLANS” in bold lettering at the top of such notice. If Landlord disapproves Tenant’s Plans, Tenant shall revise them and re-submit them to Landlord for approval. Any disapproval given by Landlord shall be accompanied by a statement in reasonable detail of the reasons for such disapproval, itemizing those portions of the plans so disapproved. Landlord shall advise Tenant within fifteen (15) Business Days following receipt of Tenant’s revised plans of Landlord’s approval or disapproval of the revised plans or portions thereof, and shall set forth its reasons for any such further disapproval in writing and in reasonable detail. If Landlord fails to approve or disapprove such revised plans within such fifteen (15) Business Day period, Landlord shall be deemed to have approved such revised plans or such portions thereof; provided, however, that five (5) Business Days prior to the expiration of such fifteen (15) Business Day period, Tenant shall send a second notice to Landlord with the phrase “FAILURE TO APPROVE OR DISAPPROVE TENANT’S PLANS, AS REVISED, WITHIN FIVE (5) BUSINESS DAYS AFTER THE DATE HEREOF SHALL RESULT IN THE DEEMED APPROVAL OF TENANT’S PLANS, AS REVISED” in bold lettering at the top of such notice. Any dispute regarding the reasonableness of Landlord’s withholding of its consent to Tenant’s Plans shall be submitted to expedited arbitration pursuant to Section 9.19 hereof. Upon approval by Landlord of Tenant’s Plans, Tenant shall submit the same to the New York City Department of Buildings for approval and for issuance of a building permit to perform the Improvements. Landlord agrees, at Tenant’s cost and expense, to reasonably cooperate with Tenant and Tenant’s independent licensed architect and engineer in providing information needed for the preparation of Tenant’s Plans, the application for a building permit and all other permits required for the Improvements, and to promptly execute all documents reasonably necessary to be signed by Landlord. (d) Tenant agrees to hire a reputable general contractor, construction manager or subcontractors and materialmen (hereinafter “Contractor(s)”) to be approved by Landlord such approval not to be unreasonably withheld or delayed (other than with respect to Contractors performing connections to any Building systems which Contractors shall be those designated by Landlord provided such Contractors shall perform such work at market prices). For purposes of Tenant’s Initial Improvements, Xxxxx, Xxxx & Xxxxxx and Xxxxxx Xxxxxxxx Consulting Engineers are deemed approved by Landlord. Tenant shall cause its Contractor(s) to perform Tenant’s Initial Improvements in a good and workmanlike manner in accordance with (x) the approved Tenant’s Plans and any material amendments or additions thereto approved by Tenant and Landlord and all municipal authorities having jurisdiction; provided, however, that, with respect to any subsequent amendments, additions, change orders or modifications after Landlord’s approval of Tenant’s Plans, Landlord shall approve or disapprove of such changes within fifteen (15) Business Days of the receipt of such changes from Tenant and (y) all provisions of Laws and any and all permits and other requirements specified by any ordinance, law or public regulation. If Landlord fails to approve or disapprove such subsequent amendments, additions, change orders or modifications within such fifteen (15) Business Day period, Landlord shall be deemed to have approved such subsequent amendments, additions, change orders or modifications or such portions thereof; provided, however, that five (5) Business Days prior to the expiration of such fifteen (15) Business Day period, Tenant shall send a second notice to Landlord with the phrase “FAILURE TO APPROVE OR DISAPPROVE TENANT’S PLANS, AS REVISED, WITHIN FIVE (5) BUSINESS DAYS AFTER THE DATE HEREOF SHALL RESULT IN THE DEEMED APPROVAL OF TENANT’S PLANS, AS REVISED” in bold lettering at the top of such notice. Tenant shall cause the Contractor(s) to obtain and maintain throughout the work, Workers’ Compensation Insurance and New York State Disability Insurance in the amounts required under any applicable Laws and comprehensive general liability insurance, including contractual liability coverage, in an amount of not less than $2 million combined single limit for bodily injury or death for any one occurrence, and for property damage, plus a $10 million umbrella policy; provided, however, that any subcontractor or materialman shall only be required to carry such liability insurance as is being carried by prudent subcontractors or materialmen within such trade at the time such subcontractor or materialman is being employed by Tenant or its Contractors. The liability coverage shall name Landlord and Overlandlord as additional insured parties, and Tenant shall deliver to Landlord proper certificates of insurance confirming the coverages described above prior to commencement of Tenant’s Initial Improvements. If Tenant acts as its own General Contractor or Construction Manager, Tenant shall obtain and maintain such insurance. All Contractor(s) shall be members of a union affiliated with the building trades in the City of New York that has jurisdiction over the Building and Tenant’s Initial Improvements. Tenant shall pay Landlord, within thirty (30) days after being billed therefor, the actual out of pocket fees and disbursements paid by Landlord to architects, engineers and other technical advisors, other than the regular staff of Landlord for reviewing Tenant’s Plans, provided such fees are commercially reasonable. (e) Landlord shall pay to Tenant pursuant to Section 5.01(f) hereof Construction Costs and Softs Costs (as hereinafter defined) in an amount (the “Construction Allowance”) which shall not exceed $1,638,850.00, provided, however, that payments in respect of Soft Costs shall not in the aggregate exceed fifteen percent (15%) of the Construction Allowance. Tenant shall pay from its own funds, and Landlord shall have no obligation with respect to, (y) any and all costs which are not Construction Costs or Softs Costs and/or (z) any and all Construction Costs in excess of the Construction Allowance or Soft Costs in excess of the limitation described in the foregoing sentence. As used in this Lease, the term “Construction Costs” means amounts actually incurred and paid by Tenant and Tenant’s contractors, subcontractors and vendors in connection with Tenant’s Initial Improvements solely for the documented, bona fide cost of (i) construction supplies and materials which are physically installed in and made a part of the Premises, including the documented, bona fide costs of carpeting, wall coverings, partitions, any electric meter or submeter, and permit fees, and (ii) labor actually performed within the Premises. The term “Soft Costs” means amounts actually incurred and paid by Tenant in connection with Tenant’s Initial Improvements solely for the documented, bona fide cost of accounting, legal, architectural, engineering and other professional or consulting services.